Agreement 1/8/1996
CITY HALL 1700.cONVENiION CENTER DRIVE MIAMI BEACH FLORIDA 33139
CITY OF MIAMI BEACH
March 12, 1996
OFFICE OF THE PURCHASING AGENT
1700 CONVENTION CENTER DRIVE
MIAMI BEACH. FLORIDA 33139
TELEPHONE, (305) 673-7490
SUNCOM: (305) 933-7490
FAX, (305) 673-7851
Mr, Calixto Octa, Pres,
MIAMI HARDWOODS & PLYWOOD CORP,
4238 N,W, 37th Avenue
Miami, FL. 33142
NOTICE TO PROCEED
RE: FILE REFERENCE NO. 29-95/96, "MIAMI BEACH BOARDWALK PROJECT"
Dear Mr, Octa:
You are hereby notified to proceed with performance of the above referenced contract.
Begin work with an adequate force and equipment within 1 calendar day from the date of this notice
to proceed and substantially complete all work awarded within not more than 172 calendar days
from date of this notice to proceed in accordance with the terms and conditions of the contract.
Sincerely,
,a&~, :{}
/ Al n#
Ass ~ Director of Procurement
L.
AL/al
NOTE: Beveling is hereby authorized, A change order increase shall be forthcoming,
*****************************************************************
START DATE: March 13. 1996
CONTRACT COMPLETION DATE: Au~ust 31. 1996
BY:
ACKNOWLEDGES
~7
s./c!Pt!7:
El'/~h,
PT OF TillS NOTICE TO
CONTRACTOR HEREBY
PROCEED
TITLE:
DATE:
" .
.
CONTRACT
(City Clerk)
TlliS AGREEMENT made this~ day of January 1996, A,D, between the CITY OF MIAMI
BEACH, a Florida municipal corporation, hereinafter called the City, which term shall include its
successors and assigns, party of the one part, and
Miami Hardwoods & Plywood Corp.
4238 N.W. 37th Avenue
Miami, FL 33142
(305) 633-6533
hereinafter called the Contractor, which term shall include its heirs, successors and assigns, party
of the other part,
WITNESSETH that the said Contractor for the consideration and compensation herein agreed to
be paid and the said City in consideration of the construction of improvements to be done by said
Contractor and designated "MIAMI BEACH BOARDWALK PROJECT" by said City, do
hereby mutually agree as follows:
I, This agreement shall extend to and be obligatory upon said City, its successors and assigns,
and upon said Contractor and it's heirs, successors and assigns, Neither this agreement nor
any part thereof nor any part of the Work herein contemplated, shall be assigned or sublet,
nor shall any sums of money provided to be paid to said Contractor be assigned by said
Contractor to anyone without the consent of the City Commission of said City evidenced by
its resolution,
2, The Contractor shall commence work on or before February 7.1996 and shall construct and
complete in a good and workmanlike manner the materials hereinbefore referred to, strictly
in accord herewith on or before AU!PL~t 31, 1996,
3, In such construction said Contractor shall furnish all implements, machinery, equipment,
transportation, tools, materials, supplies labor, and other things necessary to the execution
and completion of the Work, nothing being required of the City except that it may, at its
expense, supervise such construction and enter upon and inspect the same at all reasonable
times,
4, If any dispute arises between the City and said Contractor with reference to the meaning or
requirements of any part of this Contract and they cannot agree, the more stringent
requirements shall govern as determined by the City,
. 6, The Contractor shall file with the Purchasing Agent of said City of Miami Beach a Labor
Payment Bond, in the amount of 100 percent of labor portion of Contract Amount, in the
form as set forth herein or as otherwise approved by the City of Miami Beach City Attorney
and shall be executed by said Contractor and Surety Agent authorized to do business in the
State of Florida,
7, The Contractor shall file Insurance Certificates, as required, and they must be signed by a
Registered Insurance Agent licensed in the State of Florida and approved by the City of
Miami Beach Risk Manager,
8, All documents shall be executed satisfactorily to said City and until Bonds and Insurance
Certificates have been filed and approved, this Contract Agreement shall not be effective,
9, It is expressly agreed that Contractor shall not be responsible for delays imposed on the
completion of the Work caused solely by Acts of God, excluding rain at the job site, It is
further agreed than any delays caused by floods, fires, windstorms, and similar weather
circumstances and other Acts of God at the job site or the point of shipment of the Paulope
wood that prevent Contractor from performing and completing on a timely basis the Work
required by this Contract, that the date of completion shall be extended accordingly to the
same length of time that the Contractor is unable to perform the Work required by this
Contract due to those unfavorable weather conditions and other Acts of God,
10, It is expressly agreed that Contractor is authorized to barricade or otherwise cordon off a
work area measured as the width of the Boardwalk (estimated at twelve (12) feet by the
length of not more than one hundred and seventy-five (175) feet on any given work day,
Time is of the essence in this agreement.
IN WITNESS WHEREOF the said City. has caused this Agreement to be signed by the Mayor of
the City of Miami Beach, Florida and its corporate seal to be affixed, attested by the City Clerk of
the City of Miami Beach and the said Contractor has caused this Agreement to be signed it its name,
,4//,fP1/' /lard altm/.s ...
~JroL: 67r,t?, (SEAL)
Contractor v
By
(Author'
e5JJfln f
Title
r
By
EST:
~\<owJ ~~
City Cler{(
FORM APPROVED
LEGAL D.EfT/.
By -1A:? If! J/At/Ilr-
Date s-<; -:')&
TERMS AND CONDITIONS OF CONTRACT
Inspection:
The Contractor shall furnish the Property Management Director with every reasonable facility for
ascertaining whether or not the work performed and materials used are in accordance with the
requirements and intent of the Contract. Failure to reject any defective work or material shall not
in any way prevent later rejection when such defect be discovered, or obligate the City to final
acceptance.
Failure to Remove and Renew Defective Materials and Work:
Should the Contractor fail or refuse to remove and renew any defective materials used or work
performed, or to make any necessary repairs in an acceptable manner and in accordance with the
requirements of the Contract Specifications within the time indicated in writing, the Property
Management Director shall have the authority to cause the unacceptable or defective materials or
work to be removed and renewed, or such repairs as may be necessary, to be made at the Contractor's
expense, Any expense incurred by the City in making these removals, renewals or repairs, which
the Contractor has failed or refused to make, shall be paid for out of any monies due or which may
become due the Contractor or may be charged against the "Contract Bond" deposited; and continued
failure or refusal on the part of the Contractor to make any or all necessary repairs promptly, fully,
and in an acceptable manner shall be sufficient cause for the City, at its option, to purchase materials,
tools, and equipment and employ labor or contract with any other individual, firm, or corporation
to perform the Work. All costs and expenses incurred thereby shall be charged against the defaulting
Contractor and the amount thereof deducted from any monies due or which may become due him,
or shall be charged against the "Contract Bond" deposited, Any work performed, as described in this
paragraph, shall not relieve the Contractor in any way from his responsibility for the work performed
by him,
Protection to Public:
The Contractor shall erect and maintain barricades and warning signs to protect the public during
the course of the Work,
Permits:
The permit for the Work shall be obtained by the Contractor from the City of Miami Beach and will
be issued without charge to the Contractor.
Failure to Complete tbe Work on Time:
The Work to be done under this Contract is to begin on or before the date set forth in the attached
document, and shall be prosecuted with proper dispatch towards completion to the satisfaction of
the City, and is to be fully completed within the time limit set forth in the attached document, It is
understood and agreed that the time limit for the completion of said Work is of the essence of the
Contract, and should the Contractor fail to complete the Work on or before the date specified it is
agreed that for each calendar day that any work shall remain uncompleted, after the time specified
in the attached document, with any extension of time which may be allowed by the Property
Management Director for the completion of the Work, the sum per day given in the following
schedule shall be deducted from the monies due to the Contractor, not as a penalty but as liquidated
damages, and added expense for supervision of Contract:
Amount of Liquidated Damages and Estimated Cost of Supervision Per Day - $300.00
Partial Payments:
If the Work progresses according to Contract, the Contractor will be paid monthly ninety (90%)
percent of the value of the work completed; ten (10%) percent of the amount due being reserved until
a fmal settlement after the completion of the Work,
Acceptance and Final P~ment:
Final payment shall be made whenever the improvement provided for under this Contract shall have
been completely performed on the part of the Contractor; all parts of the Work have been approved
by the Property Management Director according to the Contract; all trash, debris, and equipment
used in the construction removed from the site of the construction; and fmal releases of claims have
been submitted to the City,
PRODUCT SPECIFICATIONS:
ASTM-E84: SURFACE BURNING CHARACTERISTICS
TYPE TEST
PAULOPE
Flame Spread, 10 Minutes
Flame Spread, 30 Minutes
Smoke Develop Value, 10 Minutes
Fuel Contribution, 10 Minutes
o
5
2
o
CODE CLASS
PAULOPE
NEPA CLASS
A
UBC CLASS
1
ASTM D-143: PHYSICAL PROPERTIES CHARACTERISTICS
Bending Strength
Compression Parallel to grain
Shear parallel to grain
Modulus of elasticity
22,950 psi
13,840 psi
11,434 psi
2,890 psi
1. GRADE DEFINED:
1.1 First Export Quality (FEQ): Suitable for the highest quality work where high strength with
good appearance is required,
This grade is suitable for export to discriminating markets,
2, GRADE REOUlREMENTS:
2,1 Durability: Paulope is specified as "Highly durable" according to F.P ,R.L. criteria for
durable woods. This is the highest rating given. Woods in this category are suitable for
structures without preservative treatment,
2.2 Moisture Content: Sawn lumber under this rules will normally be graded and supplied
green,
2,3 Sawing Tolerance: A11lumber shall be well and truly sawn to specified nominal
dimensions and with square trimmed ends,
1
continued - PRODUCT SPECIFICATION~
The following tolerances for nominal sizes at time of sawing shall apply:
Thickness and Width: (sawn lumber) up to 3" Nominal + 1/4
-0
above 3" Nominal + 3/8
-1/8
Lengths shall increase in intervals of one foot and shall be square trimmed 0" to 4" longer than
nominal length,
DRESSED SIZE MATCHED LUMBER:
Where lumber of close dimensional tolerance is produced by machine planning, after sawing, the
following reductions in size of nominal dimensions of width and thickness shall be permitted. 1/2"
in thickness and widths,
2.4 DEFECT5
Sawn lumber meeting these specifications shall not contain defects beyond the limits given in the
following table:
FIRST EXPORT QUALITY (FEQ)
P.L. Ol-FEQ
DEFECTS:
ALLOWANCE:
Knots: Loose decayed or hollow
End Splits
Not Permitted,
Not to exceed the width of the face
in length,
Not Permitted,
Not Permitted, except for trace on
one face.
1 in 8 maximum slope.
2" in 12'
Standard: 1" in 12'
Variable based on board width.
Slight,
Not Permitted.
Not permitted.
Not permitted,
Superficial-Not affecting the
structural integrity of the piece,
Surface Scaling
Sapwood, sound not preservately
treated,
Sloping Grain
Bow
Spring
Twist
Bark and Gum Pockets
Compression Failure
Brittleheart and Unsound Heart
Seasoning Checks
2
continued - PRODUCT SPECIFICATIONS
DECKING:
Paulope hardwood 5/8" x 5" x 6' - 16' S4S,E4E, Pre-Drilled & end routed with slight angle,
Quantity: 130,000 sq, ft, (+\-)plus or minus,
FASTENERS'
Stainless steel deck screws #10 x 2 1/2"
Quality: 390,000 PCS (+\-) plus or minus,
LABOR AND INSTALLATION:
Labor & Installation ofthe above products by an authorized contractor as specified by Miami
Hardwoods,
DELIVERY:
Delivery of the Paulope hardwood will be made in partial shipments to the City of Miami Beach
for storage, The installer will pick up quantities needed on a daily basis.
EXISTING DECK BOARDS:
This proposal is submitted on the basis that the City of Miami Beach is responsible for replacing
any and all of the existing deck boards that due to their unfit conditions would prevent the
installers from obtaining an even surface after installing the Paulope deck boards,
STREET SIGNS:
The installation would include a routed street sign at every block needed,
LABOR & INSTAl ,LATION DETAILS'
1. All the boards to be equally spaced,
2. All the boards will be staggered approximately 18" - 20",
3, All the ends of the boards will be slightly routed,
4. A depth collar will be used for the pre-drilling to insure uniform depth of the screws,
5. Chalk lines will be used to drill holes for screws in order to maintain the straightest lines
possible,
6. End routering of all the material will be done at the Miami Beach storage facility or at the
job site,
7, Existing benches to be removed by the City,
8, Two (2) new 10' benches will be installed at no cost to the City at each pavillion,
9, Screw spacing will be 18" on center, approximately. All board ends will receive two screws,
3
PRICE BREAKDOWN:
Price: @$4.40 per sq, ft,
130,000 SF @ $4.40 = $571,000,00
Paulope hardwood:
$377,000
Fastenen
$ 65,000 ~(I{J.
S119,OOO A4""
110'1: ()(X)D
,
Labor & Installation:
TERMS OF PAYMENT:
PAULOPE HARDWOOD:
The Paulope hardwood is payable upon delivery to Miami Hardwoods or City of Miami Beach
storage facility and after verification of quantity, A release oflien will be required from Miami
Hardwoods and Greenheart Durawoods, Inc. at time of payment,
FASTENERS:
The stainless steel screws would be payable in 10 days after delivery,
LABOR:
The labor portion of the job would be paid in monthly draws payable to Miami Hardwoods and
Plywood, Corp.
4
10 YEAR LIMITED WARRANTY
PAULOPE HARDWOOD
Miami Hardwoods & Plywood, Corp, herein after called MHP, extends this limited warranty to
the City of Miami Beach herein after called consumer, for Paulope hardwood used for resurfacing
the boardwalk on the beach,
THIS WARRANTY COVERS:
Paulope hardwood as per spec, #P,L.OI-FEQ
Paulope hardwood, is warranted for 10 years from the date of purchase, against damage by fungal
decay or termite infestation that makes the Paulope structurally unfit for the application for which
it was used,
MHP, within 60-days of written notice of claim under this warranty, will arrange to exchange the
damaged Paulope for new Paulope, Consumer must present to MHP the original invoice showing
date and specified amount of Paul ope purchased, along with a detailed list of the Paulope claimed
to be damaged, MHP reserves the right to have a representative inspect all the Paulope which is
claimed to be damaged,
THIS WARRANTY DOES NOT COVER AND MHP SHALL NOT BE LIABLE FOR:
1. Damages caused by natural change in physical properties of Paul ope beyond the control of
the product,
2. Damages to the Paulope resulting from moving or twisting associated with an unstable
sub-structure,
The obligation oHIMP under this warranty is limited to replacement and installation of Paul ope in
accordance with the terms of this warranty, There are no warranties offered by MHP other than
those described herein, Nothing in this warranty shall affect customary duration, or create implied
warranties,
Some state laws vary with regard to duration of implied warranties and limitations of incidental or
consequential damages contained in such implied warranties, In any event, MHP will comply with
the laws of the state in which a limited warranty is validated,
5
'.. ,
'..:
BOND # KO 47 47 06 9
LABOR PAYMENT BOND
(SECTION 255.05, FLA. STAT.)
PREMIUM FUllY
EARNED
MIAMI HARDWOODS &
BY THIS BOND, We,pI.YWOOD CORPORATION, as Principal, and
INSURANCE COMPANY OF
NORTII AMERICA as corporation, as Surety, are bound to the City of Miami Beach,
Florida, as obligee, herein called City, in the sum of$ 129.000.00 for the
payment of which we bind ourselves, our heirs, personal representatives, successors and assigns,
jointly and severally.
THE CONDITION OF THIS BOND is that if Principal:
Promptly makes payments to all claimants, as defined in Section 255.05 (I), Fla. Stat.,
supplying Principal with labor used directly or indirectly by Principal in the prosecution of
the work provided for in the contract; and
Pays City all losses, damages, expenses, costs, and attorney's fees, including appellate
proceedings, that the City sustains in enforcement of this bond.
Perfonns the guarantee of all labor furnished under the contract for the time specified in the
contract, then this bond is void, otherwise it remains in full force.
Any changes in or under the contract documents and compliance or noncompliance with any
fO!1llalities connected with the contract or the changes does not affect Surety's obligation
under this bond,
, The provisions of Section 255.05, Fla. Stat., are specifically adopted by reference and made
a part hereof for the purposes specified therein, .
The contract dated Janwuy 8.1996 between the City and Principal is made a part of this
Bond by reference, .
Claimants are advised that Section 255.05, Fla. Stat., contains notice and time limitation
provisions which must be strictly complied with,
.
'.'
lN WITNESS WHEREOF, the above bounded parties have caused this Bond to be executed by
their appropriate officials of the 27TII day of FEBRUARY
19 96 .
WITNESS:
PRINCIPAL:
(If sole Proprietor or partnership)
(Firm Name)
BY
Title: (Sole Proprietor or Partner)
PRINCIPAL (If Corporation)
(P (lent)
v:.t...~~
(Secretary)
(CORPORATE SEAL)
COUNTERSIGNED BY
, RESIDENT FLORIDA
AGENT OF SURETY:
.
SURETY:
d.D~
INSURANCE COMPANY OF
NORTII AMERICA
By: g;jt~L~.)
./ Attorney-in-fact ROBERT PONIICVAR
opy of Agent's current
License as issued by State
of Florida Insurance
Commissioner
(Power of Attorney must be attached)
CERTIFICATES AS TO CORPORATE PRINCIPAL
,I, ~(is~ Oria.
__, cCliify that 1 am the Secrctary of (he Corporation named as'
Pnrieipal in the aforegoing bond; that 00..11'" +0 O('t~ who signed the said bond on behalf of
~rQ'S ~ ~Q')'\-t
of said Corporation; that I know his signature, and
the Principal, was then
his signature hereto is genuine; and that said bond was duly signed, sealed, and attested for and in
behalf of said Corporation by authority of its governing body,
&#
Corporate
Seal
STATE OF FLORIDA)
ss
COUNTY OF )
Before me, a Notary Public, duly commissioned, qualified and acting, personally appeared
ROBERT PONIKVAR
to me well known, who being by me first duly sworn upon oath, says
that he is the Attorney in Fact for the INSURANCE COMPANY and that he has been
, OF NORTH AMERICA
INSURANCE COMPANY
~uthorized by OF NORTH 1\MERICl'. to execute the foregoing bond on behalf of the
Contractor named therein in favor of the City of Miami Beach, Florida,
Subscribed and swombefore me this 27TH day of FEBRUARY ,1996 A,O,
(AttachP~werof Attorney) ,~~j)r~
Notary Public
r-- State of Iil!lIJdJt;&'XKfr.X~
'. KATH~O~WH~ I ARIZONA AT LARGE
\ NlllIIY':~ My commission Expires:$~r6? /9?f1
" ""Caml,flQlhsIllrtll12,1~
. ~<, '-.:;'::/1;0 '-/fJi'. '" ^ 'S;S.., ~ <'if' ~~'~'S!/~'V: ~ ~:, "',v~" v /"'~"~/"..~/"': ~~~ "'''~' 'l~" : "./ -"'Z?,! ,'//' ,
, ,::;}; ,Y,,~ ',,,, ~/r'\~'/%':;' ;..~'~~.... /":-."" ' ~~UJ
;,- Y -.'" '-' ^0; / ^" ^' /" /' ./..: ,/, ~ , ,', ~ "~ ^ '/ "Y ,,'
\' -""''';' -, :""~ '/'''':::: .(.:'( ",~",,:: v'~/~.r ,..; .. /A.~///'->.:'/' -' , ~ 'v I'; J.~ ',I '" "/,"/, ,~
~' ' .~,' /.' " ,J~." ~::./' .'0; :/. \, " ~/ '." '
. . t!1~~...;." ,.-,.'.. ^'-' /' /~,...",f/ ." '/~"'//'::;:\".//I ;:-";:.%-,,,//:' ,If>. '- ," '"
/,_",., '..,-- ",:/- /" ',/,Y~,-' 'I"\V" -- ^, ,f
'\ ,.;~,,1.:0./~; ;'\'\','_"';;""',/~,/,;::"~/,i.',?,, '\;'.1; " '/, '" f'
, """ V ~ I:: '^' U ~ ~ ." /" /2:: 'J'/. // ,/" " . ? /j" 4"!~A.:- ...
,,,,, :.,/^, _'';I'" r\;- /" f" - '--;: .,II'.., -~ "., ,;',",,',//,"': / \,~ f 'J ,:::;. /' f r "'~.l~~
'" ","~,.' :/:.' ",'-/',"';i:" /,#r-,..,// //'Jfr~'~", .." '/' /f,,', ,// "f','
~; ~;'tiH~~i~t ~~~r.~,~;~~,t~~~~~(~0 ;',W ~~~1l~:'/'~'~~;i~e~dt ofPQQI}Sylvania.
baV~ ba~ijlaIj\f:lille'in 1ba:.Cityj;t, ~~~~. '~~U1g Ji.eso_",~~y tbeJloatd 01 &ireclOrs of !he said Compan
on Deecm~ 5\ 1-983. to wit '~~"': '/;'-:;v ,:-~'"/J;:\: vr/;;, ,,~;,' -/" , /' / 'C.' ;" /1" , -
, ::' , ,', ~ ',< ~-;I ;,~. -0~v:.:.r ~;1,'~ //::.., I~', ~ ,//. 'C.:" r"" 'C. J ,f ~ ,'C. ? ~ 7 '" ' "f , .
'l~).V!lll,too,~)o~);~.#,~..~"'...;.p;.~I..,l<WoJ;ol~,="",f".~yo''''''',~""'''''>j~~.,,J_W<"'''''~''""'"
',iW~,:~.~:. ;~~,j-.;~;,g'~~~' '%.(,"\'<t<p..~, ',!i.1~,"~~"''''''';;..r-"",,,,:,;,,,,,,~'''' ,...a.(~~;.,;;,;;,;.;..l,_, .-,_"""'"
~_~.:w '" ~~'iIti' ',!II: ,,' ,', '~:y,*~~-w.~~2f_a~ASI~C~ ", ./t6dllW(e;tlOftha~1lff'nedtl\crctO:aI144b&tIbePmsident
~~~If,'~f'~r~~~~~ ,;~~,~:~~0~-~.~~*,~~:~~11~r~.~1~:~_-,/:",_~'~~~'~:N#'!O~:b.ecute~~~lOtbeextcuf
. .,;,;",~".~fu~"""ibar.~~~.p.,,4\>~"'~~Ai:~~~"'~oi;t~.~..."'''"~~'
~~-t~~~~~1~.~~~.~~$~=~~~~r*'t~~r.=~':.r~~==:~.:m'
~~.~~~~:'~^~~-jfta!I:~,llllifl9rlty~oi:!U~'~'~ir,-~~;~'fte.~,~~Y~d~~Y. andau;,~Vil1YieQmJ.Ofrre~~,tD
~Qt~It.~.-, '':'''' ",::.::.:..:::.::.-":":::::::::.>'::<<':::',:::':"<:::<::h,"" ,::.:..:":,.:.:::_:y,'.":":,':,,,--:_'..<'__<{:::::,.')::'7::::::.::,:"__:::'::;, ,",:" ,7',,','" :::::::::_':':::':":::-':,.,:."..' - .' ...,;
(5) Tbiipasl.c>C~.."~~~::~.:~~:~~.~W~:~;k~~:OC~:>>.~~l~:J?J;.~~.:~~~~9.1m.;Jar23. ~5:~:~23,.~917." . .
"_ "..:. ... .' .,:::,'..::::..:::'..:..:;:---:,:.....-"-...'_:":::---..::::<::.:.::,<",':'::/::,:-:../J, ..:'.'.',:::---.:,....</...:....:'.",',':"-:':.-",..::--:;::::"::<::: " , ..--.:::<.::::..:,,:..::..:.,:, . ..'
.'.doe. hereby ~;'consti"~~IIl!ll!lP9iJtr, ',:R.ol:j~~l$,:YAR,~'flIR:YN'D.~rfll, .9oth' ()f~P\tY~;:Piibtttix.
Slllte<lfAl!.1~~A;;"'S-::"'<;,, ";.;" '../.'
'/"::
: .. _ .... :..;> .:,'.> < , ,',', /','
On this 2nd' jlaY of Novembal, A'D. 1995.beforem.; "'Nowy\>llblicof~e';IIUnO~fh.oi~~ in alIIIforlhe
of Philadelphia came" WilliamJ~! . Vic.-Pie'W,bl,.;{tlie' ,~~4N!~~<laTH~C~,.",;mepersonall
known 10 ba the individual and officer whoexeculea!he precedini ~lnlll~kand~aiknb\V~gedthafba~llle """..and that~..a1 al'flXed
the JlI!'ceding inslI11ment is the corporate ..a1 of said c-Pany; tI1at !hesail!eprpoGlte sealan<i h.is signllflJrc,~.",' d\llyatfued hy~authtll:ity
direction of the said corporation, and that ~solution, adopted by flu: Boanl'ot D~of said cOri>P~~"~ toP,' ll>Op~ ~1snow .
force. ____ ~ ",' ;-' >;:~/
IN ~ffi)h WHeREOF. I bave bareunto set my band' and affiXed my '<,fficial 'seal' '"1lle-CilY:'or~eiPhia ~.d1IY ~..,.lirst abOv
Wri~\\~~e~111lQ; , - -,.-.;~._,' ,~~/_
....... _I "". ~ ~ ',. . '
~~" .... ..# ~i ,'. ' -, '/
is.. ...'A'~':~ '~/ "/ ~ /: '/
~- ..- ~...-..;Jf't\ ~ ,'~ ---.;: --' : _ f .'
'*{J~~ ~i'~~l;; ,'.r;,',., ~ "'. ,.~~....;~i~~'..,;!;-.
.'i, . ~..o,:"::.,::::.,'.:..<:: .~: ::.::,~.:,::__:::::~ftY~~q~NQt~~ltc"::::::::::::::::; ., _~ ":~<>::.-~; w ,',',;J"::J;'" '>"
, \~P~~R~$~~~~.~~~~7~~,"".'2 :~/ :'/~/~H~O~~Oli
1, the unde~"llN.lMl!.~\~~iJIl~tE~ANY O'F~?~W(~~9~:dp ~,iba "~~ P!;)\'I};R~ ~\\
whicb the ,foruoing is a substantianY. aue atid. colied:' ~y.' is btfuU force and eft~~::<:v:,.:>:.:--,': . " . " <, ;':-; ';t2> .:;~~,,:;}::;>' ~':~',~~ "/'~: ;>>>'":-- i,:,:< ,.:",.,:
In witnes.\ whereof, 1 have hereunlosubscrihed my naole as S.cretllry. and affixed !he coiponw; ieOI'tlf;:ilIt~\t.,/iIlri-z~~""dayO
_fl" _' FEBRUARY ,,1',96., " . ",' I, ,\\;"1,',..'. ", .."'.:,?,:a..'..".,'-.../:,'~,/0.."."".ic;',.,::,;\'~,"',/_':'/":";,,~;,,,0';.(,':',".,","','."
, - . //.Y~*,d-: ';''''"o;'J!2'</'i"
.. " '.:'<,';/,,">~~~, r::>:.;,:-;'_,~.>;2:';:-;~,-_::'/:-':;'~",
. . ,Debra:..lI~f~':::'-' / .' /'\'-- _,:'--..-,'/.', "'/.-'-,,'" ~
nus POWER OF ATrORNEY MAYl'lONlE USED'ro EXECUTEANYB0Ni>~_A.Nl!iii~~i_~~~~~~~~'~
,', . ,. . ',,-.;:::-',-'., .'';--/ :--::__,/">\",,:v '#.. ::.:%.......'......1/. ",;
BS-333t!3c PtO; inU;S.A. , " _ . <~~'/-;:;":( ',:<~~~j/~'<:f1'C.,::;;/'-,0 "<J~"~Y.::f
(I)
(3)
(4)
..::
l
-8
J!
,j::f ;
~!
~g
...-;
~ >
.!!ca
..g
g '!;j
..... e
. ...
~",~
'"
........
~tl
~e
o ~
e ,;:!
.s~
...
:g~
~ ~
~,~
65o{i~&
--.'.'.'
</' ///.."..,',:,-" ,..,~,,:--/(,
7,: . . : <'>'::-:::<:":; ::,'}:::":':'.,.:)/ '.' ;>,>~;,:,::<:<:-' :"' ,,' ."'.' '\.' .': :,-:,':','.-:.'.."",-::".-,.;"",:::' ". ,>, ,:." ""..', f
.....a individ~~lt:'th~ bl: ~~~ ~;Jfs ~~i&wt\i1irU<irjl6l';m.~jl,6,.)ok~,>~~~.~ ijlj\l/~v'e.: .;;~ itSbellalf, atid.as ils act
deed any an4a11.>.:bOnda,' UlId.,~.l'OOPgl)i;!anoo~;"",irtr.!cJ!i ana: .wntingsm ,the [IIlture~f in penaltie. 110' exceed'
O..Mi11ionDot~~{~I'()()l)~~~'~lr, ,ii<> ,:8ndth<<'~~~ ot'~~h.\futiDgs!n i#t#i~e. of th~pre~ shall be
oinding upon said C6lll1'!l'!r\~~fl'Uy~;jIIlPl~~~l(jjley had Oe?'lll1o/t~~ltlI~~know~il:by !he tegullU!lr~I~;'~ officers of the c;ompany atj
principal offfCe. . ,,," " . . ,..,.... ' , . ..'... ~
. ,"', "" 0
IN WITNESSWllllREOF, the SJid W'J!lia!nfungreis , Vice-Presiden~ ~ bereUnlo Sl/o.crilJid lii$ illlme atid affltea 0
C<)rporare seal of the said INSURAN'CE COMPANY OF NORm AJIlERICA!his 2nd day of Novelllbe, 1995 ~
,. ",.' z
1JIlSURANcE, COMPANY QF NOR'QI ~CA. ~
-
'\VIlH~ rUllg~is
COMMONWEALTH OfJ',ENNSYLVANIA
CouNTY OF PHILADE~IA
...
CERTIFICATE OF INSURANCE: MIAMHAR
PRODUCER,
Robbins Insurance Inc,
P.O. Box 3375
Tampa FL 33601-3375
813-251-1099
CSR MN 02/28/96
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND
CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE
DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE
POLICIES BELOII.
COMPANIES AFFORDING COVERAGE
COMPANY
A Maryland Casualty Insurance Co
INSURED
COMPANY
B FCCI
~iami Ha+dwoods & Plywood
CorporatJ.on
~f3B N. W, 37th Avenue
,..iami FL 33142
COMPANY
C
COMPANY
o
> COVERAGES <================================================================================================~==================
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOI/ HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY
PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO
WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO
ALL THE TERMS, EXCLUSIONS, AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
co
LTR
TYPE OF INSURANCE
POLICY NUMBER
POLICY EFF POLICY EXP
DATE (MM/DD/YY) DATE(MM/DD/YY)
LIMITS
GENERAL LIABILITY
A Q{ I COMMERCIAL GEN LIABILITY
[ I CLAIMS MADE [XI OCC,
I OWNERS'S & CONTRACTOR'S
PROTECTIVE
I
I
EPA 22214986
01/22/96 01/22/97
GENERAL AGGREGATE
PROD-COMP/OP AGG.
PERS. & ADV. INJURY
EACH OCCURRENCE
F IRE DAMAGE
(ANY ONE FIRE)
MED, EXPENSE
(ANY ONE PERSON)
1,000,000
1,000,000
1,000,000
1,000,000
50,000
5,000
AUTOMOBILE LIABILITY
A Q{ I ANY AUTO
[ I ALL OWNED AUTOS
[ I SCHEDULED AUTOS
Q{ I NIRED AUTOS
Q{] NON-OWNED AUTOS
[ I
[ I
ECA 22214721
01/22/96 01/22/97
COMB, SINGLE LIMIT
BODILY INJURY
(PER PERSON)
1,000,000
BODILY INJURY
(PER ACCIDENT)
PROPERTY DAMAGE
GARAGE LIABILITY
[ I ANY AUTO
[ I
[ I
AUTO ONLY (EA ACC)
OTHER / AUTO ONLY:
EACH ACCIDENT
AGGREGATE
-----.--.-------------.----.--- ~-------------------------- --------------- ------------_. --------.-----.---- -----.--------
EXCESS LIABILITY
[ I UMBRELLA FORM
[ I OTHER THAN UMBRELLA FORM
EACH OCCURRENCE
AGGREGATE
---------------------------.--- ------._--------------_._-- --------------- -.----------_. ---._---------._--- ----------_.--
WORKERS COMPo AND EMP. LIAS.
THE PROPRIETOR/PARTNERS/
B EXECUTIVE OFFICERS ARE: 27559
[ I INCL. [ I EXCL.
ISTATUYORY LIMITS
EACH ACCIDENT
01/01/96 01/01/97 DISEASE-POL. LIMIT
DISEASE-EACH EMP,
500,000
500,000
500,000
-----._------------------------ ~---------------------~-_.- _.--_._---~---- ---_.-~_.----~ ----------------------------------
OTHER
A Automobile
Physical Damage
ECA 22214721
01/22/96 01/22/97 Compo
ColI.
$500
$500
-DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES/SPECIAL ITEMS---------------------------,---------------------,--------------------
~~oject: Miami Beach Boardwalk Project
~ddJ.tional Insured: City of Miami Beach
Hold Harmless Agreement is added to the policy per the attached.
City of Miami Beach
City Hall
~?OO Convention Center
",iami Beach FL 33139
> CERTIFICATE HOLDER <====================================> CANCELLATION <=======================================================
CITYMIA SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO MAIL
30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE
LEFT, BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR
LIABILITY OF ANY KIND UPON THE COMPANY,ITS AGENTS OR REPRESENTATIVES,
Drive
----------------------------------------------------------------------
AUTHORIZED REPRESENTATIVE
rR~jI. )~~
_ACORD 25-S (3/93)
Robert Hoffman
Miami Hardwoods & Plywood Corporation
"The contractor hereby agrees to indemnify and hold harmless the City of Miami Beach, a
municipal Corporation, its officers, agents and employees from all claims of bodily injuries
to the public in and up to the amount of $1,000,000 for each occurrence and for all
damages to the propeny of others in and up to the amount of $1,000,000 for each
occurrence per the insurance requirement under the specifications including costs of
investigation, all expenses of litigation, including reasonable attorney fees and the cost of
appeals arising out of any such claims or suits because of any and all acts of omission or
commission of any by the contractor, his agents, servants, or employees, or through the
mere existence of the project under contract, "MIAMI BEACH BOARDWALK
PROJECT"