Horizon Contractor, Inc."~ ~ 00600. CONTRACT:
CONTRACT
THIS {S A CONTRACT, by and between the City of Miami Beach, a political
subdivision of the State of Florida, hereinafter referred to as CITY, and HORIZON
CONTRACTOR. INC., hereinafter referred to as CONTRACTOR.
W I T N E S S E T H, that CONTRACTOR and CITY, for the considerations
hereinafter named, agree as follows:
ARTICLE 1
SCOPE OF WORK
~^
CONTRACTOR hereby agrees to furnish all of the labor, materials, equipment
services and incidentals necessary to perform all of the work described in the Contract
Documents and related thereto for the Project.
ARTICLE 2
CONTRACT TIME
2.1 CONTRACTOR shall be instructed to commence the Work by written instructions
in the form of a Standing Order issued by the City's Procurement Director and a
Notice to Proceed issued by the Contract Administrator. Two (2) Notices to
Proceed will be issued for this Contract. CONTRACTOR shall commence
scheduling activities, permit applications and other preconstruction work within
five (5) calendar days after the Project Initiation Date, which shall be the same as
the date of the first Notice to Proceed. The first Notice to Proceed and Purchase
Order will not be issued until CONTRACTOR's submission to CITY of all required
documents (including but limited to: Payment and Performance Bonds, and
Insurance Certificate) and after execution of the Contract by both parties.
2.1.1. The receipt of all necessary permits by CONTRACTOR and acceptance
of the full progress schedule in accordance with technical spec cations
section, submittal schedule and schedule of values is a condition
precedent to the issuance of a second Notice to Proceed to mobilize on
the Project site and commence with physical construction of the work.
The CONTRACTOR shall submit all necessary documents required by
this provision within twenty-one (21) calendar days of the issuance of
the first Notice to Proceed.
~~,.'
substantially completed within five hundred and forty-seven (547) calendar days
from the issuance of the second Notice to Proceed, an mpleted and ready for
final payment in accordance with Article 5 within thirt~~30) calendar days from
the date certified by CONSULTANT as the date of Substantial Completion.
2.3 Upon failure of CONTRACTOR to substantially complete the Contract within the
specified period of time, plus approved time extensions, CONTRACTOR shall
pay to CITY the sum of Thirteen Hundred Dollars ($1,300.00) for each calendar
day after the time specified in Section 2.2 above, plus any approved time
extensions, for Substantial Completion. After Substantial Completion should
CONTRACTOR fail to complete the remaining work within the time specified in
Section 2.2 above, plus approved time extensions thereof, for completion and
readiness for final payment, CONTRACTOR shall pay to CITY the sum of six
hundred-fifty ($650.00) for each calendar day after the time specified in Section
2.2 above, plus any approved extensions, for completion and readiness for final
payment. These amounts are not penalties but are liquidated damages to CITY
for its inability to obtain full beneficial occupancy and/or use of the Project.
Liquidated damages are hereby fixed and agreed upon between the parties,
recognizing the impossibility of precisely ascertaining the amount of damages
that will be sustained by CITY as a consequence of such delay, and both parties
desiring to obviate any question of dispute concerning the amount of said
damages and the cost and effect of the failure of CONTRACTOR to complete the
Contract on time.
The above-stated liquidated damages shall apply separately to each portion of
the Project for which a time for completion is given.
2.4 CITY is authorized to deduct liquidated damages from monies due to
CONTRACTOR for the Work under this Contract or as much thereof as CITY
may, in its sole discretion, deem just and reasonable.
2.5 CONTRACTOR shall be responsible for reimbursing CITY, in addition to
liquidated damages, for all costs incurred by CONSULTANT in administering the
construction of the Project beyond the completion date specified above, plus
approved time extensions. CONSULTANT construction administration costs
shall be pursuant to the contract between CITY and CONSULTANT, a copy of
which is available upon request of the Contract Administrator. All such costs
shall be deducted from the monies due CONTRACTOR for performance of Work
under this Contract by means of unilateral credit change orders issued by CITY
as costs are incurred by CONSULTANT and agreed to by CITY.
~--.
BID No. 48-07/08 CITY OF MIAIMI BEACH Page 74 of 144
DATE: 09/30/08
2.2 Time is of the essence throughout this Contract. This project shall be
substantially completed within five hundred forty-seven (547) calendar days from
the issuance of the second Notice to Proceed, and completed and ready for final
payment in accordance with Article 5 within thirty (30) calendar days from the
date certified by CONSULTANT as the date of Substantial Completion.
2.3 Upon failure of CONTRACTOR to substantially complete the Contract within the
specified period of time, plus approved time extensions, CONTRACTOR shall
pay to CITY the sum of Thirteen Hundred Dollars ($1,300.00) for each calendar
day after the time specified in Section 2.2 above, plus any approved time
extensions, for Substantial Completion. After Substantial Completion should
CONTRACTOR fail to complete the remaining work within the time specified in
Section 2.2 above, plus approved time extensions thereof, for completion and
readiness for Onal payment, CONTRACTOR shall pay to CITY the sum of six
hundred-fifty ($650.00) for each calendar day after the time specified in Section
2.2 above, plus any approved extensions, for completion and readiness for final
payment. These amounts are not penalties but are liquidated damages to CITY
for its inability to obtain full beneficial occupancy and/or use of the Project.
Liquidated damages are hereby fixed and agreed upon between the parties,
recognizing the impossibility of precisely ascertaining the amount of damages
that will be sustained by CITY as a consequence of such delay, and both parties
desiring to obviate any question of dispute concerning the amount of said
damages and the cost and effect of the failure of CONTRACTOR to complete the
Contract on time.
The above-stated liquidated damages shall apply separately to each portion of
the Project for which a time for completion is given.
2.4 CITY is authorized to deduct liquidated damages from monies due to
CONTRACTOR for the Work under this Contract or as much thereof as CITY
may, in its sole discretion, deem just and reasonable.
2.5 CONTRACTOR shall be responsible for reimbursing CITY, in addition to
liquidated damages, for all costs incurred by CONSULTANT in administering the
construction of the Project beyond the completion date specified above, plus
approved time extensions. CONSULTANT construction administration costs
shall be pursuant to the contract between CITY and CONSULTANT, a copy of
which is available upon request of the Contract Administrator. All such costs
shall be deducted from the monies due CONTRACTOR for performance of Work
under this Contract by means of unilateral credit change orders issued by CITY
as costs are incurred by CONSULTANT and agreed to by CITY.
ARTICLE 3
THE CONTRACT SUM
[ ] This is a Unit Price Contract:*
3.1 CITY shall pay to CONTRACTOR the amounts determined for the total number
of each of the units of work completed at the unit price stated in the schedule of
prices bid. The number of units contained in this schedule is an estimate only,
and final payment shall be made for the actual number of units incorporated in or
made necessary by the Work covered by the Contract Documents.
3.2 Payment shall be made at the unit prices applicable to each integral part of the
Work. These prices shall be full compensation for atl costs, including overhead
and progt, associated with completion of all the Work in full conformity with the
requirements as stated or shown, or both, in the Contract Documents. The cost
of any item of work not covered by a del=tnite Contract unit price shall be included
in the Contract unit price or lump sum price to which the item is most applicable.
[ X ] This is a Lump Sum Contract:*
3.1 CITY shall. pay to CONTRACTOR for the performance of the Work described in
the Contract Documents, the total price stated as awarded.
3.2 Payment shall be at the lump sum price stated in the Contract. This price shall
be full compensation for all costs, including overhead and profit, associated with
completion of all the work in full conformity with the requirements as stated or
shown, or both, in the Contract Documents. The cost of any item of work not
covered by a definite Contract lump sum should be included in the lump sum
price to which the item is most applicable.
*Note: Some Projects include both unit prices and lump sums in which case both
sections shall apply to the Work identified for each type of Contract.
ARTICLE 4
PROGRESS PAYMENTS
4.1 CONTRACTOR may make Application for Payment for work completed during
the Project at intervals of not more than once a month. CONTRACTOR's
application shall show a complete breakdown of the Project components, the
quantities completed and the amount due, together with such supporting
evidence as may be required by CONSULTANT. CONTRACTOR shall include,
but same shall be limited to, at Consultant's discretion, with each Application for
Payment, an updated progress schedule acceptable to CONSULTANT as
`"^" required by the Contract Documents and a release of liens and consent of surety
relative to the work which is the subject of the Application. Each Application for
Payment shall be submitted in triplicate to CONSULTANT for approval. CITY
shall make payment to CONTRACTOR within thirty (30) days after approval by
CONSULTANT of CONTRACTOR's Application for Payment and submission of
an acceptable updated progress schedule.
4.2 Ten percent (10%) of all monies earned by CONTRACTOR shall be retained by
CITY until Final Completion and acceptance by CITY in accordance with Article 5
hereof, except that after ninety percent (90%) of the Work has been completed,
the Contract Administrator may reduce the retainage to five percent (5%) of all
monies previously earned and all monies earned thereafter. Any reduction in
retainage shall be in the sole discretion of the ~ Contract Administrator, shall be
recommended by CONSULTANT and CONTRACTOR shall have no entitlement
to a reduction. Any interest earned on retainage shall accrue to the benefit of
CITY. All requests for retainage reduction shall be in writing in a separate stand
alone document.
4.3 CITY may withhold, in whole or in part, payment to such extent as may be
necessary to protect itself from loss on account of:
4.3.1 Defective work not remedied.
4.3.2 Claims filed or reasonable evidence indicating probable filing of claims
by other parties against CONTRACTOR or CITY because of
CONTRACTOR's performance.
4.3.3 Failure of CONTRACTOR to make payments properly to Subcontractors
or for material or labor.
4.3.4 Damage to another contractor not remedied.
4.3.5 Liquidated damages and costs incurred by CONSULTANT for extended
construction administration.
4.3.6 Failure of CONTRACTOR to provide any and all documents required by
the Contract Documents.
When the above grounds are removed or resolved satisfactory to the Contract
Administrator, payment shall be made in whole or in part.
ARTICLE 5
ACCEPTANCE AND FINAL PAYMENT
5.1 Upon receipt of written notice from CONTRACTOR that the Work is ready for
final inspection and acceptance, CONSULTANT shall, within ten (10) calendar
days, make an inspection thereof. If CONSULTANT and Contract Administrator
find the Work acceptable, the requisite documents have been submitted and the
requirements of the Contract Documents fully satisfied, and all conditions of the
permits and regulatory agencies have been met, a Final Certificate of Payment
(Form 00926) shall be issued by CONSULTANT, over its signature, stating that
the requirements of the Contract Documents have been performed and the Work
is ready for acceptance under the terms and conditions thereof.
5.2 Before issuance of the Final Certificate for Payment, CONTRACTOR shall
deliver to CONSULTANT a complete release of all liens arising out of this
Contract, receipts in full in lieu thereof; an affidavit certifying that all suppliers and
subcontractors have been paid in full and that all other indebtedness connected
with the Work has been paid, and a consent of the surety to final payment; the
final corrected as-built drawings; and the final bill of materials, if required, and
invoice.
5.3 If, after the Work has been substantially completed, full completion thereof is
materially delayed through no fault of CONTRACTOR, and CONSULTANT so
certifies, CITY .shall, upon certificate of CONSULTANT, and without terminating
the Contract, make payment of the balance due for that portion of the Work fully
completed and accepted. Such payment shall be made under the terms and
conditions governing final payment, except that it shall not constitute a waiver of
claims.
5.4 Final payment shall be made only after the City Manager or his designee has
reviewed a written evaluation of the performance of CONTRACTOR prepared by
the Contract Administrator, and approved the final payment. The acceptance of
final payment shall constitute a waiver of all claims by CONTRACTOR, except
those previously made in strict accordance with the provisions of the General
Conditions and identified by CONTRACTOR as unsettled at the time of the
application for final payment.
ARTICLE 6
MISCELLANEOUS
6.1 This Contract is part of, and incorporated in, the Contract Documents as defined
,~ herein. Accordingly, all of the documents incorporated by the Contract
Documents shall govern this Project.
6.2 Where there is a conflict between any provision set forth within the Contract
Documents and a more stringent state or federal provision which is applicable to
this Project, the more stringent state or federal provision shall prevail.
6.3 Public Entity Crimes
In accordance with the Public Crimes Act, Section 287.133, Florida Statutes, a
person or affiliate who is a contractor, consultant or other provider, who has been
placed on the convicted vendor list following a conviction for a public entity crime
may not submit a bid on a contract to provide any goods or services to the CITY,
may not submit a bid on a contract with the CITY for the construction or repair of
a public building or public work, may not submit bids on leases of real property to
the CITY, may not be awarded or perForm work as a contractor, supplier,
subcontractor, or consultant under a contract with the CITY, and may not
transact any business with the CITY in excess of the threshold amount provided
in Section 287.017, Florida Statutes, for category two purchases for a period of
36 months from the date of being placed on the convicted vendor list. Violation
of this section by Contractor shall result in cancellation of the CITY purchase and
may result in Contractor debarment.
6.4 Independent Contractor
CONTRACTOR is an independent contractor under this Contract. Services
provided by CONTRACTOR pursuant to this Contract shall be subject to the
supervision of CONTRACTOR. In providing such services, neither
CONTRACTOR nor its agents shall act as ofhcers, employees, or agents of the
CITY. This Contract shall not constitute or make the parties a partnership or joint
venture.
6.5 Third Party Beneficiaries
Neither CONTRACTOR nor CITY intend to directly or substantially benefit a third
party by this Contract. Therefore, the parties agree that there are no third party
beneficiaries to this Contract and that no third party shall be entitled to assert a
claim against either of them based upon this Contract. The parties expressly
acknowledge that it is not their intent to create any rights or obligations in any
third person or entity under this Contract.
6.6 Notices
Whenever either party desires to give notice to the other, such notice must be in
writing, sent by certified United States Mail, postage prepaid, return receipt
requested, or by hand-delivery with a request for a written receipt of
acknowledgment of delivery, addressed to the party for whom it is intended at the
place last specified.
The place for giving notice shall remain the same as set forth herein until
changed in writing in the manner provided in this section. For the present, the
parties designate the following:
For CITY:
Fred H. Beckmann. Interim CIP Director
Capital Improvement Projects (CIP) Office
777 17 Street, 2" Floor
Miami Beach. Florida 33139
With copies to:
City Attorney
City of Miami Beach
1700 Convention Center Drive
Miami Beach. Florida 33139
For Contractor:
Jose M. Sanchez. P.E.
Horizon Contractors Inc
"""~` 8175 West 32" Avenue #1
Hialeah. Florida 33018
6.7 Assignment and Performance
Neither this Contract nor any interest herein shall be assigned, transferred, or
encumbered by either party. In addition, CONTRACTOR shall not subcontract
any portion of the work required by this Contract except as authorized by Section
27 of the General Conditions. CONTRACTOR represents that all persons
delivering the services required by this Contract have the knowledge and skills,
either by training, experience, education, or a combination thereof, to adequately
and competently perform the duties, obligations, and services set forth in the
Scope of Work and to provide and perform such services to CITY's satisfaction
for the agreed compensation.
CONTRACTOR shall perform its duties, obligations, and services under this
Contract in a skillful and respectable manner. The quality of CONTRACTOR's
performance and all interim and final product(s) provided to or on behalf of CITY
shall be comparable to the best local and national standards.
6.8 Materiality and Waiver of Breach
CITY and CONTRACTOR agree that each requirement, duty, and obligation set
°"""" forth in these Contract Documents is substantial and important to the formation of
this Contract and, therefore, is a material term hereof.
CITY's failure to enforce any provision of this Contract shall not be deemed a
waiver of such provision or modification of this Contract. A waiver of any breach
of a provision of this Contract shall not be deemed a waiver of any subsequent
breach and shall not be construed to be a modification of the terms of this
Contract.
6.9 Severance
In the event a portion of this Contract is found by a court of competent jurisdiction
to be invalid, the remaining provisions shall continue to be effective unless CITY
or CONTRACTOR elects to terminate this Contract. An election to terminate this
Contract based upon this provision shall be made within seven (7) days after the
finding by the court becomes final.
6.10 Applicable Law and Venue
This Contract shall be enforceable in Miami-Dade County, Florida, and if legal
action is necessary by either party with respect to the enforcement of any or all of
the terms or conditions herein exclusive venue for the enforcement of same shall
lie in Miami-Dade County, Florida. By entering into this Contract,
CONTRACTOR and CITY hereby expressly waive any rights either party
may have to a trial by jury of any civil litigation related to, or arising out of
the Project. CONTRACTOR shall specifically bind all subcontractors to the
provisions of this Contract.
6.11 Amendments
No modification, amendment, or alteration in the terms or conditions contained
herein shall be effective unless contained in a written document prepared with
the same or similar formality as this Contract and executed by the Board and
CONTRACTOR.
6.12 Prior Agreements
This document incorporates and includes all prior negotiations, correspondence,
conversations, agreements, and understandings applicable to the matters
contained herein and the parties agree that there are no commitments,
agreements or understandings concerning the subject matter of this Contract that
are not contained in this document. Accordingly, the parties agree that no
deviation from the terms hereof shall be predicated upon any prior
representations or agreements, whether oral or written. It is further agreed that
no modification, amendment or alteration in the terms or conditions contained
herein shall be effective unless set forth in writing in accordance with Section
6.11 above.
IN WITNESS WHEREOF, the parties have set their hands and seals the day and
year first above written.
EST: THE CITY OF MIAMI BE H
ity Clerk a r
CONTRACTOR MUST EXECUTE THIS CONTRACT AS INDICATED BELOW. USE
CORPORATION OR NONCORPORATION FORMAT, AS APPLICABLE.
[If incorporated sign below.]
CONTRACTOR
ATTEST:
(Secretary)
(Corporate Seal)
day of , 20
[If not incorporated sign below.]
WfTNESSES:
(Nam of C poration)
.,
By:
S nature)
~~ ~ ~ ~ Z
(Print Name and Title)
CONTRACTOR
(Name of Firm)
13y:
(Signature)
(Print Name and Title)
day of , 20_
CfTY REQUIRES FOUR (4) FULLY-EXECUTED CONTRACTS, FOR DISTRIBUTION.
APPROVED AS TO
FORM S~ANGUAGI
t c c~~ ~z~nv