Loading...
2012-28092 Reso RESOLUTION NO. 2012-28092 A RESOLUTION OF THE MAYOR AND THE CITY COMMISSION OF THE CITY OF MIAMI BEACH, FLORIDA, APPROVING, IN CONCEPT, THE GRANT OF AN EASEMENT TO COLLINS 3300, LLC AND 3420 COLLINS AVENUE, LLC (THE APPLICANT), OWNERS OF THE PROPERTIES LOCATED AT 3301 INDIAN CREEK DRIVE, 3400 COLLINS AVENUE AND 3420 COLLINS AVENUE, FOLLOWING A DULY NOTICED PUBLIC HEARING, FOR A PROPOSED SUBSURFACE PARKING GARAGE, THAT SPANS THE ENTIRE WIDTH OF THE 50-FOOT PUBLIC RIGHT-OF-WAY OF 34TH STREET FOR A LENGTH OF APPROXIMATELY 93 FEET; PROVIDED, HOWEVER, THAT THE AFORESTATED CONCEPTUAL APPROVAL BE SUBJECT TO AND CONTINGENT UPON COMPLETION OF CONTINUING NEGOTIATIONS OF THE EASEMENT AND AN AGREEMENT BETWEEN CITY AND THE APPLICANT, WHICH EASEMENT AND AGREEMENT, IF SUCCESSFULLY NEGOTIATED AND FINALIZED, SHALL BE SUBJECT TO FINAL APPROVAL BY THE CITY MANAGER AND CITY ATTORNEY; FURTHER AUTHORIZING THE MAYOR AND CITY CLERK TO EXECUTE THE FINAL EASEMENT AND AGREEMENT, IF AND WHEN FINALIZED; FURTHER ACCEPTING THE RECOMMENDATION OF THE CITY MANAGER. WHEREAS, Collins 3300, LLC And 3420 Collins Avenue, LLC, (Applicants) are owners of the properties located at 3301 Indian Creek Drive, 3400 Collins Avenue, and 3420 Collins Avenue (collectively, the Properties); and WHEREAS, the Applicants wish to connect the Properties and provide for required parking with a subsurface parking garage beneath 34th Street; and WHEREAS, the portion of the parking garage underneath the right-of-way is proposed to be 12 feet 10 inches below ground-level with a width of 50 feet and a length of approximately 93 feet; and WHEREAS, the Applicants have received approval from the City's Historic Preservation Board (pursuant to HPB Order No. 7299)to redevelop the Properties; and WHEREAS, at its June 13, 2012 meeting, the Land Use and Development Committee recommended that the City Commission set a public hearing to consider the granting of Applicants' request; and WHEREAS, at its July 18, 2012 meeting, the City Commission approved Resolution No. 2012- 27950, setting a public hearing to consider this request. NOW, THEREFORE, BE IT RESOLVED BY THE MAYOR AND CITY COMMISSION OF THE CITY OF MIAMI BEACH, FLORIDA, that the Mayor and City Commission hereby approve in concept, the grant of an easement to Collins 3300, LLC and 3420 Collins Avenue, LLC (the Applicant), owners of the properties located at 3301 Indian Creek Drive, 3400 Collins Avenue and 3420 Collins Avenue, following a duly noticed public hearing, for a proposed subsurface parking garage, that spans the entire width of the 50-foot public right-of-way of 34th Street for a length of approximately 93 feet; provided, however, that the aforestated conceptual approval be subject to and contingent upon completion of continuing negotiations of the easement and an agreement between the City and the Applicant, which easement and agreement, if successfully negotiated and finalized, shall be subject to final approval by the City Manager and City Attorney; further authorizing the Mayor and City Clerk to execute the final easement and agreement, if and when finalized; further accepting the recommendation of the City Manager. 2ot2-29o9Z PASSED AND ADOPTED this 12th day of December, 2012. ATTEST: M erre a Bower, Mayorr Rafae ranado, City CI rk APPROVED AS TO FORM, ' A L NGUAGE, AND FOR EXECUTION INCORP ORATED: 'Attorne Date �C ��'�� H 26 T:\AGENDA\2012\12-12-12\easements\3300 Collins Subterranean Easement-RESO by FB rev GH 12-7-12.docx COMMISSION ITEM SUMMARY Condensed Title: A Resolution Of The Mayor And The City Commission Of The City Of Miami Beach, Florida, Approving, In Concept, The Grant Of An Easement To Collins 3300, LLC And 3420 Collins Avenue, LLC (The Applicant), Owners Of The, Properties Located At 3301 Indian Creek Drive, 3400 Collins Avenue And 3420 Collins Avenue, Following A Duly Noticed Public Hearing, For A Proposed Subsurface Parking Garage, That Spans The Entire Width Of The 50-Foot Public Right-Of-Way Of 34th Street For A Length Of Approximately 93 Feet; Provided, However, That The Aforestated Conceptual Approval Be Subject To And Contingent Upon Continuing Negotiation Of The Agreement Between City And The Applicant, Which Agreement, If Successfully Negotiated And Finalized, Shall Be Subject To Final Approval By The City Manager And City Attorney; Further Authorizing The Mayor And City Clerk To Execute The Final Agreement, If And When Finalized; Further Accepting The Recommendation Of The City Manager. Key Intended Outcome Supported: Maintain Miami Beach public areas and Right-of-Ways Citywide Supporting Data (Surveys, Environmental Scan, etc.): N/A Item Summa /Recommendation: Collins 3300, LLC And 3420 Collins Avenue, LLC (Applicants)wish to construct a hotel with accessory assembly space, a parking garage, and retail and restaurant uses. They propose to connect the Properties and provide for required parking with a subsurface parking garage beneath 34th Street. The parking garage is proposed to be 12 feet 10 inches below ground-level with a width of 50 feet and a length of approximately 93 feet. At the Historic Preservation Board meeting, the Applicants received approval (pursuant to HPB Order No. 7299)to redevelop the Properties. At the June 28, 20122 FCWPC, it was recommended to use the fee simple methodology for valuation of this easement. The City appraiser valued the easement at $1,250,000. The applicant's appraiser valued it at$150,000. At the September 12, 2012 City Commission meeting, the Commission stated that it wanted a new appraisal that would result in the highest value and to bring it back to Commission for approval once negotiations have been finalized. A new.appraisal is being conducted; however, it won't be ready until mid January. The City has evaluated a proposal contained in the attached proposed terms and conditions agreement, where the Applicant would construct and demolish the existing board walk, and construct a new beachwalk from 32nd to 36th Streets, the Applicant would contribute up to $900,000 for hard costs and will pay for soft costs associated with design, permitting and construction management. In addition, the Applicant will be providing some intangible benefits such as the installation of new utilities in the sub-surface easement. The applicant also requested some consideration regarding on-street parking spaces. THE CITY ADMINISTRATION RECOMMENDS ACCEPTANCE OF THE APPLICANT'S PUBLIC BENEFIT PROPOSAL AND APPROVAL OF THE RESOLUTION SUBJECT TO A REVISED APPRAISAL. Advisory Board Recommendation: I .The Historic Preservation Board has approved the proposed design. Financial Information: Source of Amount Account Approved Funds: 1 2 OBPI Total Financial Impact Summary: City Clerk's Office Legislative Tracking: FHB/RWS, Public Works 6565 Sign-Offs: Department Director Assistant Cit Manager City Mana FHB JGG KGB T:\AGENDA\2012\12-12-12\easements\3300 Collins SubterraWj sement-SUMMARY.docx AGENDA ITEM 97 NAIAMIBEACH DATE 12-1 Z MIAMI BEACH City of Miami Beach, 1700 Convention Center Drive,Miami Beach, Florida 33139,www.miamibeachfl.gov COMMISSION MEMORANDUM TO: Mayor Matti Herrera Bower and Members of the City Commission PUBLIC HEARING FROM: Kathie G. Brooks, Interim City Manager DATE: December 12, 2012 SUBJECT: A RESOLUTION OF THE MAYOR AND THE CITY COMMISSION OF THE CITY OF MIAMI BEACH, FLORIDA, APPROVING, IN CONCEPT, THE GRANT OF AN EASEMENT TO COLLINS 3300, LLC AND 3420 COLLINS AVENUE, LLC (THE APPLICANT), OWNERS OF THE PROPERTIES LOCATED AT 3301 INDIAN CREEK DRIVE, 3400 COLLINS AVENUE AND 3420 COLLINS AVENUE, FOLLOWING A DULY NOTICED PUBLIC HEARING, FOR A PROPOSED SUBSURFACE PARKING GARAGE, THAT SPANS THE ENTIRE WIDTH OF THE 50-FOOT PUBLIC RIGHT-OF-WAY OF 34TH STREET FOR A LENGTH OF APPROXIMATELY 93 FEET; PROVIDED, HOWEVER, THAT THE AFORESTATED CONCEPTUAL APPROVAL BE SUBJECT TO AND CONTINGENT UPON CONTINUING NEGOTIATION OF THE AGREEMENT BETWEEN CITY AND THE APPLICANT, WHICH AGREEMENT, IF SUCCESSFULLY NEGOTIATED AND FINALIZED, SHALL BE SUBJECT TO FINAL APPROVAL BY THE CITY MANAGER AND CITY ATTORNEY; FURTHER AUTHORIZING THE MAYOR AND CITY CLERK TO EXECUTE THE FINAL AGREEMENT, IF AND WHEN FINALIZED; FURTHER ACCEPTING THE RECOMMENDATION OF THE CITY MANAGER. ADMINISTRATION RECOMMENDATION The Administration recommends that after the Public Hearing, the City Commission accept the applicant's public benefit proposal and approve the Resolution subject to receipt of the pending appraisal and finalization of the agreement if the appraisal is equal to or within 20% of the value of the public improvement as proffered by the applicant. If the appraisal is greater than 20% of the value of the proposed public benefit, the applicant shall have the option to pay the difference or cancel the agreement. BACKGROUND Collins 3300, LLC And 3420 Collins Avenue, LLC, (Applicants) are owners of the properties located at 3301 Indian Creek Drive, 3400 Collins Avenue and 3420 Collins Avenue (collectively, the Properties). The Properties are located in the Collins Waterfront Historic District and presently a vacant parcel, an existing 3-story hotel, and a vacant parcel, respectively. The Applicants wish to construct a 5-story hotel with an accessory assembly space on the vacant parcel at 3301 Indian Creek Drive, renovate the 3-story hotel at 3400 Collins Avenue, and construct a 6-story parking garage with accessory commercial uses on the vacant parcel at 3420 Collins Avenue. They propose to connect the Properties and provide for required parking with a subsurface parking facility beneath their property including portion of 34th Street. The portion of the subsurface parking facility underneath the ROW is proposed to be 12 feet 10 inches below ground-level with a width of 50 feet and a length of approximately 93 feet. At the City Commission Memorandum-3400 Collins Avenue Subterranean Easement December 12, 2012 Page 2 of 5 Historic Preservation Board meeting on February 14, 2012, the Applicants received approval (pursuant to HPB Order No. 7299)to redevelop the Properties. This proposed subsurface parking garage was then referred to the Land Use Committee and the Finance and Citywide Projects Committee for policy direction. At the June 13, 2012 Land Use Committee meeting, it was determined that: 1. An easement was the more appropriate instrument for allowing a subsurface parking facility across City right-of-way. 2. The value of the easement should be determined via an appraisal conducted for the City and paid for by the Applicants. 3. The Commission should set a public hearing to consider granting the easement. At the June 28, 2012 Finance and Citywide Projects Committee, it was recommended to use the fee simple methodology for valuation of this easement with flexibility to adjust the valuation when appropriate, based on recommendations from the City appraiser. An appraisal prepared by Waronker& Rosen, Inc. on June 27, 2012, estimates the fee simple value of the easement to be $1,250,000. The Applicant's appraiser valuated the subsurface easement at $150,000 using discounts to take into account the fact the easement property cannot be used for the highest and best value as the adjacent fee simple property. The rationale for applying discounts is that the sub-surface easement area cannot be used for habitable areas of the hotel and therefore should only be evaluated as a portion of an underground parking structure. This reduction does not take into account any value added to the project as it makes the underground parking facility feasible. At the July 18, 2012 City Commission meeting, pursuant to Resolution No. 2012-27948, the Commission set a public hearing for the September 12, 2012 Commission meeting. At the September 12, 2012 City Commission meeting, the Commission stated that it wanted the appraisal that would result in the highest value and to bring it back to Commission for approval once the negotiations have been finalized. As a result, the item has been opened and continued at each subsequent Commission meeting. As of the writing of this report, the revised appraisal has not been finalized. However, comparing both the City's fee simple valuation and the applicant's appraisal discounted for actual use would indicate that a revised highest value appraisal would not be dispositive on the actual value of the easement. Both the Land Use and Development Committee and the Finance and Citywide Projects Committee recognized that appraisals are more of a tool to evaluate the request for the easement and the public benefit created in consideration of granting the easement. Nonetheless, given the Commission's desire to have the results of the revised appraisal, then the Commission may choose to continue this item or the Commission may choose to approve the granting of the easement subject to receipt of the pending appraisal and finalization of the agreement if the appraisal is equal to or within 20% of the value of the public improvement as proffered by the applicant. If the appraisal is greater than 20% of the value of the proposed public benefit, the applicant shall have the option to pay the difference or cancel the agreement. The applicant has requested that the City move forward on this item as they do not believe that a revised appraisal would be definitive on the actual value of the easement and that the public benefit proposed by them far outweighs the actual request of the use of the subsurface easement. City Commission Memorandum-3400 Collins Avenue Subterranean Easement December 12, 2012 Page 3 of 5 ANALYSIS There is no section of the City Code that provides guidance on the appropriateness of granting an easement. Therefore, staff has reviewed the appropriateness of the facility pursuant to the criteria established under Section 82-38 of the City Code for the proposed sale or lease of City property as it has done for the proposed aerial easement across Ocean Court for the Tides Hotel. Those criteria are: 1. Whether or not the proposed use is in keeping with city goals and objectives and conforms to the city comprehensive plan. Satisfied - The property is located within the RM-2 Multifamily Residential Medium Intensity future land use category, and surrounded by this and the RM-3 Multifamily Residential High Intensity future land use category. The proposed use is underground parking garage use for the adjacent hotel facilities. The proposed use of the adjacent properties as hotel facilities is consistent with the future land use category description contained in the Comprehensive Plan. 2. The impact on adjacent property, including the potential positive or negative impacts such as diminution of open space, increased traffic, noise level or enhanced property values, improved development patterns and provision of necessary services. Based on the proposed use of the property, the city shall determine the potential impact of the project on city utilities and other infrastructure needs and the magnitude of costs associated with needed infrastructure improvements. Should it become apparent that further evaluation of traffic impact is needed; the proponent shall be responsible for obtaining a traffic impact analysis from a reputable traffic engineer. Satisfied - The property in question is surrounded on both the north and south by the proposed hotel development, and the property to the east, across Collins Avenue, is under the same ownership and approved for hotel and condominium use. There would be no diminution of open space as proposed. No additional utility or infrastructure is expected to be necessary. A traffic study was prepared as part of the development review approval process, which indicated that the proposal would not degrade the level of service of the surrounding roadway network below acceptable levels. 3. A determination as to whether or not the proposed use is in keeping with a public purpose and community needs, such as expanding the city's revenue base, creating jobs, creating a significant revenue stream, and improving the community's overall quality of life. Satisfied - The proposal is associated with an important new hotel development of particular architectural distinction. This portion of the Collins Avenue corridor has not developed as rapidly as areas of the City further south, and the proposed new hotel developments in this corridor are generally seen as positive for the city's economic and tourism development. The proposed hotel development is expected to provide a significant number of jobs, and to provide additional property tax and resort tax revenues to the City. City Commission Memorandum-3400 Collins Avenue Subterranean Easement December 12,2012 Page 4 of 5 4. Determination as to whether or not the development is in keeping with the surrounding neighborhood, will block views or create environmental intrusions, and evaluation of the design and aesthetic considerations of the project. Satisfied - The proposed easement is entirely underground, and should not create any visual or environmental impacts on the surrounding neighborhood. 5. The impact on adjacent properties, whether or not there is adequate parking, street and infrastructure needs. Indeed, the granting of the easement will ensure that the project's required parking is created instead of paying a fee in lieu of providing parking. Furthermore, the operational parking needs of the existing historic hotels, which have no required parking, is also met by granting the easement. Satisfied - There should not be any adverse impacts to adjacent properties other than those owned by the Applicants. 6. Such other issues as the city manager or his authorized designee, who shall be the city's planning director, may deem appropriate in analysis of the proposed disposition. Not applicable - The Planning Department has no other issues it deems appropriate to analyze for this proposal. The Administration's analysis above shows that the above criteria established under Section 82- 38 of the City Code is satisfied. The City has evaluated a proposal contained in the attached proposed terms and conditions agreement, where the Applicant would construct and demolish the existing board walk, and construct a new beachwalk from 32nd to 36th Streets, excluding the Versailles property. It should be noted that the Administration has contacted the representatives of the Versailles property and they have agreed to consider making their contribution to the beachwalk project at the time that permits are obtained for same, even if it is prior to the issuance of the building permits for the Versailles project. Under the proposed public benefit proposal, the Applicant would contribute up to $900,000 for hard costs and will pay for soft costs associated with design, permitting and construction management. In addition, the Applicant will be providing some additional benefits such as the installation of new utilities in the sub-surface easement. While the City believes that the applicant's estimate for all of these costs may be too high, the City estimates the value of said costs to be approximately $240,000. This does not include the $700,000 refund in permit fees that the applicant has also proffered not to pursue. The applicant is also requesting that a payment required pursuant to City Code Section 106- 55(h), Removal of On-street Parking Spaces, be authorized by the City to be paid over a five year period. This would relieve some of the upfront costs associated with the issuance of the building permit and facilitates the applicant's proffer to fund the beachwalk. Seven on-street parking spaces will be removed to allow vehicular access to the property. The cost of such removal is set by the Code at $245,000. If paid over a five year period, the yearly payment would be $49,000 for five years. Five additional on-street parking spaces are also lost due to sidewalk pedestrian improvements. This typically happens in all of the City's streetscape improvement projects. The Code does not require for these spaces to be paid for by the private City Commission Memorandum-3400 Collins Avenue Subterranean Easement December 12, 2012 Page 5 of 5 property owners as these are viewed as pedestrian enhancements that the general public enjoys. The applicant has reiterated that there are no fees associated with the loss of parking in the terms and conditions agreement. One last consideration the applicant has requested is the use of seven spaces on the 32nd St. street end during the time that the sales center is operational for the Saxony project. There is no fee associated with creating passenger loading zones and the prevailing rate is $17/day, per space for valet ramps. As this cost appears to be minimal, the Administration has no issue with this request. If one discounts the value of the beachwalk behind the Saxony hotel, although a condition to fund the beachwalk was not included in the Historic Preservation Board's Final Order, this would represent approximately $400,000. Adding the remaining hard costs ($500,000) with the City's estimate of soft costs and utility replacement benefits ($240,000) would result in a value of the public benefit contribution of about 60% to the fee simple appraisal of the easement. If the beachwalk cost behind the Saxony is not deducted, then this public benefit proffer is close to the City's fee simple appraised value of the easement. As such, the Administration suggests to the Commission that this proposed public benefit is a just, fair and beneficial consideration for the subterranean easement requested by the applicant. Additionally, the Commission should also consider the benefits that the proposed development will bring to the area as a significant investment by the applicant will help stimulate interest and redevelopment opportunities in the area. Furthermore, the undergrounding of the parking facility creates a pedestrian friendly interface to the development and the public spaces and creates a project that is context sensitive to the surrounding historic district. However, given the Commission's directive to obtain a revised appraisal, the Commission may approve the request subject to receipt of the pending appraisal and finalization of the agreement if the appraisal is equal to or within 20% of the value of the public improvement as proffered by the applicant. If the appraisal is greater than 20% of the value of the proposed public benefit, the applicant shall have the option to pay the difference or cancel the agreement. Because the easement agreement language has not been finalized, and the developer has an urgency to have a conceptual approval of the granting of the subsurface easement, the City Administration recommends that the City Commission grant a conceptual approval, this approval be subject to and contingent upon continuing negotiation of the agreement between City and the Applicant, which agreement, if successfully negotiated and finalized, shall be subject to final approval by the City Manager and City Attorney; further authorizing the Mayor and City Clerk to execute the final agreement, if and when finalized; further accepting the recommendation of the City Manager. CONCLUSION The Administration recommends that after the Public Hearing, the City Commission accept the applicant's public benefit proposal and approve the Resolution Attachment: Terms And Conditions For Perpetual Subsurface Easement Agreement KGB/JGG/FHB/JJF/RWS/DEF T:\AGENDA\2012\12-12-12\easements\3300 Collins Subterranean Easement-Memo.docx 0/2 go h THIS INSTRUMENT PREPARED BY AND SHOULD BE RETURNED TO: Neisen O. Kasdin,Esq. Akerman Senterfitt 1 SE 3rd Avenue Miami,FL 33131 II ----------------------------------------------------[SPACE ABOVE THIS LINE FOR RECORDING DATA]---------------------------------------------------- SUBSURFACE EASEMENT AGREEMENT THIS SUBSURFACE EASEMENT AGREEMENT ("Agreement") is made and entered into this .11"/ day of 2013 ("Effective Date"), by and between CITY OF MIAMI BEACH, a political subdivision of the State of Florida, whose address is 1700 Convention Center Drive, Miami Beach, Florida 33139, as grantor, ("Owner" or "Citv"), and COLLINS 3300, LLC and 3420 COLLINS AVENUE, LLC, both are Foreign Limited Liability Corporations, whose address is 730 Fifth Avenue, 201h Floor, New York, NY 10019, as grantee, ("Developer" and together with the Owner, each, a "Party" and collectively, the "Parties"). RECITALS: A. Owner is the political subdivision of jurisdiction to all of the right-of-way known as 341h Street ("Right-of-Way") and that certain real property, situated, lying and being in Miami-Dade County, Florida, as legally described and depicted in the sketch in Exhibit "A" attached hereto and by this reference incorporated herein, consisting of a portion of the Right-of- Way (the"Easement Parcel"). B. Developer is the owner of fee simple title to that certain real property situated, lying and being in Miami-Dade County, Florida, as legally described and depicted in the sketch in Exhibit "B" attached hereto and by this reference incorporated herein (the "Developer Property"). C. As depicted on Exhibit "B," a portion of the Developer Property, consisting of the following folio number: 02-3226-001-1450; (the "North Parcel"), borders the northern boundary of the Easement Parcel. D. As depicted on Exhibit "B," another portion of the Developer Property, consisting of the following folio number: 02-3226-001-1430; (the "South Parcel"), borders the southern boundary of the Easement Parcel. E. Developer plans to install certain Improvements (hereinafter described) within the Easement Parcel, such as is depicted in Exhibit "C" attached hereto and by this reference incorporated herein. (26781517-111 Page l of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT I F. The Developer intends to develop the Developer Property for the Atlantic Hotels project (the "Project") generally consisting of a mixed-use project with two (2) hotels with accessory assembly space and accessory retail uses, together with off-street parking facilities; approved by the City Historic Preservation Board on February 14, 2012 (File No. 7299), the City Planning Board on February 28, 2012 (File No. 2049) and the City Board of Adjustment on March 2,2012 (File No. 3561) (the "Approved Plans"). G. As part of the Project, the Developer intends to construct certain Improvements (as hereinafter defined), and in connection therewith requires an Easement (as hereinafter defined) for the Project. H. The Owner agrees to grant to Developer the Easement pursuant to the terms set forth herein and as set forth in Resolution 2012-28092 of the City of Miami Beach (attached as Exhibit "D") and agrees that such Easement shall be a covenant running with the land. NOW, THEREFORE, in consideration of the mutual covenants, promises, terms and conditions set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby agree as follows: Section 1. Recitals. The above recitals are true and correct, and are incorporated herein by reference. Section 2. Easements. The easements described in Sections 2(a) through 2(c) below are hereinafter referred to as the "Easements" and the easement areas described in Sections 2(a) through 2(c) below are one and the same as the area of the Easement Parcel, legally described and sketched in Exhibit "A". This Agreement shall not become effective unless and until it is properly executed by the Parties and recorded by the Developer. Owner makes no representations or warranties whatsoever to developer with respect to the condition of the easement parcel. Developer is accepting the easement parcel on an "as is" "where is" basis and assumes all risk with respect to the condition thereof including, without limitation, thereunder or appurtenant thereto, whether known or unknown to owner. The developer shall take reasonable precautions within and around the easement parcel for,the safety of, and shall provide reasonable protection to prevent damage, injury or loss to, persons or property including, without limitation, employees, visitors to and residents of the surrounding site and those portions of the site and buildings adjacent to the easement parcel. The developer shall not encroach upon any other of owner's property beyond the boundaries of the easement parcel. The Developer may use the Easements and Easement Parcel solely for the following purposes: a. Temporary Construction Easement. Owner hereby grants and conveys to Developer, its employees, contractors, subcontractors and agents (i) a temporary and exclusive {26781517;1} Page 2 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT construction easement on, in, under, over, across and through the Easement Parcel for purposes of constructing, reconstructing, excavating, grading, sloping, installing, laying, inspecting, erecting, improving, removing, maintaining, operating, repairing, replacing and restoring the Improvements and the Project; (ii) the right to store materials and equipment on and in the Easement Parcel (but not above ground storage in the Right-of-Way unless expressly provided for by Right-of-Way permit), and (iii) a temporary access easement for ingress, egress and access in connection with the foregoing (collectively, the "Temporary Construction Easement"). Prior to the Commencement of Construction (as hereinafter defined) of the Improvements on, in, under, over, across or through the Easement Parcel, the Developer shall submit a right-of-way permit application to the City Public Works Department. The Temporary Construction Easement shall expire upon the completion of the construction of the Project, as evidenced by a final certificate of occupancy for the last phase or improvement'of the Project (the "Completion Date"), or if the building permit expires or is abandoned (as defined by Section 105.4.1.3 of the Florida Building Code, which states a permit is in active progress when the permit has received an approved inspection within 180 days; i.e. the building permit is expired or abandoned if an inspection is not approved within a 180-day period), as of a date confirmed by the City's Building Official. If construction on the Project is stopped for any reason, Developer agrees to restore the right-of-way to the condition existing prior to commencement of construction, or such other condition as the parties may agree. b. Subterranean Easement. Owner hereby grants and conveys to Developer, its employees, contractors and agents.an exclusive subterranean easement below, across and through the Easement Parcel for the purposes during construction, repair or reconstruction of the Project, of constructing, reconstructing, excavating, installing, laying, inspecting, erecting, improving, removing, maintaining, operating, repairing, replacing and restoring the Subterranean Improvements (as hereinafter defined) and the Project, including the right to store materials and equipment on the Easement Parcel related solely to the construction of the Easement Parcel and the Project, and grants and conveys to Developer, its tenants, employees, agents, customers and invitees, an easement for ingress, egress and access on, in, under, over and through the Subterranean Improvements. This easement also grants to the Developer the right to park under the Easement Parcel and the right of ingress and egress and passage of pedestrians and motor vehicles into, out of, on, over and across all driveways, entranceways, the Easement Parcel, common service lanes, and sidewalks, now existing or hereafter constructed on, under, over or about the Easement Parcel (the "Subterranean Easement"). C. Utility and Service Easements. Owner hereby grants and conveys to Developer, such utility easements on, in, under, over, across and through the Easement Parcel as deemed necessary by the Developer for the purposes of constructing, reconstructing, excavating, installing, laying, inspecting, erecting, improving, removing, maintaining, operating, repairing, replacing and restoring the Improvements and the Project, including, installing, connecting to, disconnecting from, repairing or relocating any utility facilities; piping; water, sanitary, storm, and sewer mains, lines and drains; utility lines, mechanical and electrical conduits, appurtenances and all other related utilities and equipment deemed necessary by the Developer for the Project (the "Utility Easement"). Developer, at its sole cost and expense, shall have the right to install or cause to be installed all necessary connections between the Improvements constructed or erected by it on, in, under, over, across and through the Easement Parcel, and the water, sanitary and storm mains, lines and drains and mechanical? {26781517;1} Pa-e 3 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT and electrical conduits and other, utilities, whether or not owned by the Owner. Owner shall cooperate with Developer pursuant to Section 5(d) hereof to the extent that the Developer needs the Owner to join in any agreements or documents for installation, connection to, disconnection from, repair or relocation of any utilities facilities; piping; water, sanitary, storm and sewer mains, lines and drains; utilities lines; mechanical and electrical conduits; connections or other utility facilities necessary for the Improvements or the Project or required by the Developer, including reasonable use of existing easements benefiting the Easement Parcel and adjoining rights of way to the Easement Parcel. The cost of all utilities relating to the Improvements, including, without limitation, gas, water, sewer and electric utilities and services shall be borne by and shall be the sole responsibility of the Developer. Nothing in this Agreement shall relieve the Developer from meeting minimum standards and obtaining all required permits, including but not limited to City Right-of-Way and Building Department permits, the issuance of which will not be unreasonably withheld. The Developer shall not cut, disconnect, or disturb any of the Owner's existing utility and/or service lines of any nature without the prior written consent of the Owner, which consent shall not be unreasonably withheld. Prior to the work being performed, the Developer shall identify the existing lines and notify the Owner, in writing, as to any required and/or anticipated relocation of utility and/or service lines to perform the project work. Developer shall be responsible for all costs associated with relocating any of Owner's utility and/or services lines of any nature. Developer shall notify each utility company owning utility lines within the Easement Parcel prior to the work being performed, to arrange for positive underground location, relocation or support of its utility, where that utility may be in conflict with or endangered by Developer's work and/or other activities. All costs of relocation of utility lines owned b utility p Y Y Y companies shall be the responsibility of the Developer. Section 3. Access Easements; Interference. The easements p rovided in the foregoing Section 2, shall not prohibit the Owner from entering upon the Easement Parcel, at such Owner's sole cost and expense, to maintain, repair and replace the Right-of-Way, or as otherwise necessary or appropriate within the scope of its governmental or proprietary authority, provided, that such access shall not adversely interfere with the Improvements and shall not prohibit a utility service provider who has the right to enter the Easement Parcel (a) pursuant to utility easement agreements recorded prior to the Effective Date in the Public Records of Miami- Dade County, Florida or (b) pursuant to all applicable laws and ordinances. The Owner agrees not to unreasonably obstruct or interfere in any way with the free flow of pedestrian and vehicular traffic over, under or above the Easement Parcel or with respect to the Project in any manner which would adversely interfere with the Improvements, the Project and Owner's use of the Easements and Easement Parcel except: (i) to the extent reasonably necessary for repair and maintenance and traffic regulation; or (ii) in the event of an emergency (which for purposes of this Section, means a situation or condition involving imminent injury to persons and /or imminent and material damage to property). Section 4. Legal Description. The legal descriptions of the Easement Areas are one and the same as the legal description for the Easement Parcel, described and sketched in Exhibit "A„ {26781517;1} Page 4 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT Section 5. Improvements. a. Improvements. The Developer intends to own, develop and operate, as part of the Project, those improvements as generally depicted in the Approved Plans, including, without limitation, (i) a subterranean parking structure, including intra-block access, parking spaces, ramps and related infrastructure, together with all appurtenant items and facilities within a parking garage, such as, but not limited to, drive aisles, ramps, stairs, elevators, mechanical or human-operated parking systems, etc.) under the Easement Parcel connecting the North Parcel and the South Parcel underground (the "Improvements"). The term, "Improvements" shall mean the aforedescribed Improvements, together with such utilities and facilities necessary to construct and operate the foregoing. b. Commencement of Construction. The Owner conceptually accepts the Developer's proposed development as depicted in the Approved Plans, which describes development of the Atlantic Hotels Project. However, given that the Improvements will be constructed on, in, under, across and through the Easement Parcel, the Parties agree that specific construction and development plans for the Improvements to be constructed on, above, under, across and through the Right-of-Way, in addition to permit review through the City of Miami Beach Building Department, shall be subject to the review and approval of the City of Miami Beach Public Works Department ("CMBPWD"), to ensure the public safety and convenience, and to limit any adverse impact to the Right-of-Way. Precedent to any construction, excavation, demolition, restoration, testing or staging on the Easement Parcel, the Developer shall submit to CMBPWD three (3) copies of certified engineering drawings Showing the relationship between the Improvements and the Easement Parcel and Right-of-Way. Notwithstanding anything herein, all construction on, over, under and through the Easement Parcel shall be in compliance with the City of Miami Beach Public Works Manual, the Florida Building ode and the Florida Fire Prevention Code and other applicable laws. For purposes g pP p rP of this agreement, "Commencement of Construction" when used in connection with construction of the Improvements shall mean the earlier of the filing of the notice of commencement under Florida Statutes Section 713.13 or the visible start of work on the Improvements, including on-site utility, excavation or soil stabilization work. In order to meet the definition of"Commencement of Construction" herein, such filing of notice or visible start of work must occur after the Developer has received a building permit and/or Right-of-Way permit for the particular Improvements or portion thereof on which construction is proposed to commence. C. Performance Bond. Prior to the Commencement of Construction of the Improvements, the Developer shall deliver, or cause its contractors to deliver, to Owner executed performance bonds, or their equivalent (including without limitation, the right to deliver alternative security pursuant to Section 713.23, Florida Statutes (2011)), to guarantee the construction of the portion of the Improvements then being constructed by such contractor on the Easement Parcel. The amount of such bond shall be equal to the proportionate share of the applicable hard costs of construction of the Improvements then being constructed on the Easement Parcel by such contractor. Each bond shall name the Owner as beneficiary thereof and shall be issued by a surety reasonably acceptable to Owner. Developer shall have the right from time to time to substitute or replace, or cause its contractors to substitute or replace, such bonds as deemed necessary by the Developer for any portion of the Improvements on the {26781517;1} Page 5 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT Easement Parcel then being done. Any such performance bonds, or the equivalent, and Developer's obligations thereunder, shall terminate upon approval of such work through inspection by CMBPWD inspectors and payment of such work as required under the Developer's construction contract. Notwithstanding anything in the foregoing, the Owner acknowledges that all of the Improvements are not being constructed on the Easement Parcel and the performance bond is not and shall not be based on the amount of the hard construction costs of the entire Improvements or Project or any portion of the Improvements that are not located on the Easement Parcel. d. Cooperation. It is intended that the Improvements will be developed pursuant to the Approved Plans. In connection with the construction of the Improvements and the Project, the Owner will join in or consent to such permits, licenses, approvals, or other administrative documents as provided in this Agreement, as may be necessary for the Developer to develop and use the Easement Parcel in accordance with the Approved Plans and in a manner otherwise permitted hereunder, provided that (i) such joinder or consent by the Owner shall be at no cost to the Owner other than its costs of review; (ii) the location, terms, and form of any such permits, licenses, approvals or other administrative documents shall be reasonably acceptable to the Owner; and (iii) the Owner agrees to use best efforts to review and approve (or disapprove with an explanation for such disapproval) any such requests within ten (10) business days of the submittal of a permit application by the Developer (except in the event that the approval of the City Commission is required under applicable laws and ordinances). The Parties agree to cooperate with each other to the full extent practicable pursuant to the terms and conditions of this Agreement. The Parties agree that time is of the essence in all aspects of their respective and mutual responsibilities pursuant to the Agreement. The Owner shall use reasonable efforts during the permitting and approval process in an effort to assist the Developer in obtaining its permits and achieving its development and construction milestones for the Project. e. Designation of the Owner's Representative. The Owner hereby designates the Public Works Director (the "Owner Representative"), who shall have the power, authority and right, on behalf of the Owner, in its capacity as Owner hereunder, and without any further resolution or action of the Commission or CMBPWD, to the extent allowed by applicable laws and ordinances, to: (i) review and approve (if required) documents, plans, applications, assignments and requests required or allowed by the Developer to be submitted to the Owner pursuant to Section 5(b) or otherwise under this Agreement; (ii) consent to actions, events, and undertakings by the Developer for which consent is required by the Owner; (iii) make appointments of individuals or entities required to be appointed or designated by the Owner in this Agreement; (iv) execute non-disturbance agreements and issue estoppel statements as provided elsewhere in this Agreement; (v) execute any and all documents on behalf of the Owner necessary or convenient to the foregoing approvals, consents, and appointments; (vi) execute on behalf of the Owner any and all consents, agreements, applications or other documents, needed to comply with applicable regulatory procedures and secure permits or other approvals needed to accomplish the construction of the Improvements, and (vii) to amend this Agreement to correct any typographical or non-material errors. The Owner's Representative shall have the rights as set forth in clauses (i)-(vii) above and will be the primary contact for the Developer in connection with this Agreement and any submissions, approvals, consents, {26781517;1} Page 6 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT I joinders or inquiries with respect to this Agreement, the Right-of-Way, the Easements, the Easement Parcel and the Improvements. f. Ownership of Improvements. The Improvements, as well as all material and equipment rovided b the Developer or on its behalf which is incorporated into the p Y P � Improvements shall be and remain the property of the Developer as long as the Agreement remains valid and in effect. Upon expiration or termination of this Easement, permanent improvements become the property of the Owner, temporary improvements can be removed as property of the Developer. g. Ownership of Excavated Material. Sand and other excavated material (the "Fill") in the easement area is the property of the Owner. Developer shall move the Fill from the easement area to a location of Owner's choosing within the City limits at Developer's cost and expense. Developer shall notify Owner at least thirty (30) calendar days in advance of the excavation of the Fill so Owner can plan to receive the Fill. Within five (5) business days of the 30-day notice, the Owner shall confirm to Developer its intention to receive the Fill and provide a specific location and delivery instructions for delivery of the Fill. If Owner cannot accommodate the Fill within the City limits, Owner agrees to release ownership of the Fill to Developer and Owner shall notify Developer as such within five (5) business days of the 30-day advance notice listed above. If Owner releases ownership of the Fill as described above, Developer shall use and/or relocate the Fill at its own cost and expense. g. Noise and other applicable restrictions provided by law. Developer acknowledges the applicability of City Code section 46-156, a copy of which is attached to this Agreement as Schedule B, and incorporated herein by reference, and agrees to comply with the requirements of such section. Execution of this Agreement does not provide Developer or its Contractors with any exemption from this section or other ordinances, rules, regulations or laws otherwise applicable to the Developer's work. Enforcement of this section, or other ordinances, rules, regulations or laws, by Owner/City shall be as permitted by law. Section 6. Maintenance of Improvements; Easements. a. Except as specifically set forth in this Agreement, the Developer shall be responsible to maintain, repair and replace the Improvements as deemed necessary in the reasonable discretion of the Developer and to maintain and keep in clean condition the Easement Parcel. The aforedescribed obligations shall terminate, automatically and without further action by the Parties, as to all or any portion of the Easements, at such time as, and to the extent that repair, maintenance and replacement of such Improvements (or portion thereof) or Easement Parcel (or portion thereof) is accepted by any utility service provider or governmental entity. Notwithstanding anything herein to the contrary, the Owner shall be responsible to maintain, repair and replace the Right-of-Way, it being expressly understood that the Developer shall have no obligation to maintain, repair or replace the Right-of-Way, except that should any aspect of the Improvements or Project result in or cause damage to the Right-of-Way, Developer shall be responsible for the repair or replacement of such Right-of-Way, to the design, specifications and satisfaction of Owner. Owner shall not be responsible for any damage caused to the Easement Parcel or Improvements as a result of its construction, reconstruction, maintenance or repair of {26781517;1} Page 7 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT the right-of-way and public utilities, except due to the negligence of Owner, Owner's agents, employees and contractors. b. At all times during the Term, the Developer, at its sole cost and expense, shall properly and adequately maintain the Easement Parcel in a safe, clean and neat condition, and shall make all repairs necessary to keep the Easement Parcel in such condition. The Developer, at its sole cost and expense, shall maintain the Easement Parcel in a neat and clean condition, free from any and all garbage, waste materials, or rubbish caused by operations of the Improvements. If all or any portion of the Easement Parcel is not kept in a condition reasonably acceptable to Owner, Owner and/or its Owner Representative shall notify the Developer, in writing, of any deficiency(ies), and Developer shall correct such deficiency(ies) within 48 hours of said notice. In the event Developer fails to timely comply with the foregoing obligation, Owner shall have the right (but not the duty), at Owner's sole option and discretion, to correct the deficiency(ies), in which event Developer shall promptly reimburse Owner for the reasonable costs incurred by Owner in connection therewith, but in no event later than thirty (30) days following receipt of an invoice thereof. c. Repairs. Developer will promptly repair (or cause to be repaired) any damages to the subsurface portion (or portions) of the Easement parcel, and/or to any and all portion(s) of the remainder of Owner's property outside of the Easement Parcel, caused by, through, under, arising out of and/or resulting from the work performed by Developer, Developer's General Contractor for the Improvements, or any of their respective employees, subcontractors, laborers, or material suppliers. Upon receipt of written notice from Owner, Developer shall perform such repairs within a reasonable timeframe, but commencing and completing such repairs not later than ten (10) business days after written notice thereof. However, in the event of an emergency, affecting the safety of persons or property, Developer shall immediately commence repairs to mitigate the damages caused therefrom at its sole cost and x n e pe se. If such repairs will require additional time beyond the 10 business days set forth herein, Developer shall provide prompt written notice to Owner and/or its Owner Representative of the additional time required for completing such repairs and the basis therefor. If Owner and/or its Owner Representative determine such time extension or delay in performing repairs beyond 10 business days is unreasonable and/or if Developer fails to perform any of its obligations under this Section 6, Owner shall have the right (but not the duty), to correct any condition and/or to make repairs, and the reasonable costs thereof shall promptly be reimbursed and/or paid by Developer after written notice of the same, but no later than thirty (30) days after receipt of written notice thereof. Notwithstanding the foregoing provisions of this Section 6, Developer shall not be responsible for repairing any damage to the subsurface portion (or portions) of the Easement Parcel and/or to the remainder of Owner's property, as to the Easement Parcel, to the extent it is caused by the gross negligence, recklessness or willful misconduct of Owner, and/or its officers, employees, or contractors; and, as to the remainder of Owner's property, to the extent it is caused by the gross negligence, recklessness or willful misconduct of Owner, its officers, employees, contractors, agents, licensees, invitees, and guests as a result of their (respective) use of the property. {26781517;1} Page 8 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT Section 7. Operations. a. Non-Interference. The Developer's development and construction of the Project and its use and operation of the Easement Parcel shall not materially and adversely interfere with the Owner's customary and reasonable operation of the Right-of-Way, unless, and to the extent permitted in, the Developer obtains a Right-of-Way permit. The Developer may request temporary interruption of the pedestrian and vehicular traffic of the Right-of-Way and in the Easement Parcel by the Owner for construction, maintenance or repairs to the Improvements and the Owner agrees to reasonably cooperate with such interruption in order to enable such construction, maintenance or repairs, and such interruption, if at the request of the Developer for purposes of construction, maintenance or repairs of the Improvements. Similarly, the Owner's use of the Right-of-Way shall not materially and adversely interfere with the Developer's development and construction of the Improvement and the Project (including, the development of the portions of the Project adjacent to the Right-of-Way and Easement Parcel) and its use and operation of the Easement Parcel and the Improvements, unless prior arrangements have been made in writing between the Parties or as provided in section 2, except in cases of emergency or to protect the public health, safety and welfare. Section 8. Consideration. a. The consideration and terms of this Easement Agreement are as set forth in Resolution 2012-28092 of the City of Miami Beach, attached as Exhibit "D". Section 9. Construction Liens. From and after the Commencement of Construction and until the expiration or earlier termination of this Agreement, each party will discharge any and all obligations incurred by such Party to third parties, it being understood and agreed that the Developer shall have the right to withhold any payment (or to transfer any such lien to a bond in accordance with applicable Florida law) so long as it is in good faith disputing liability therefor or the amount thereof. Section 10. Termination. The Easements are granted and this Agreement shall continue until such time as the Improvements encroaching onto the Right-of-Way or constructed in, on, under, across and through the Easement Parcel are demolished, removed or reach the end of their life. If after the Completion Date, the Easement Parcel permanently ceases to be used for the purposes set forth herein, the Easements (or such applicable portion thereof that has permanently ceased operation) shall terminate. No temporary vacancy during the term of this Agreement (meaning vacancies of substantially all of the Easement Parcel or Improvements for a period of more than three (3) years or non-occupancy during any construction of the Improvements shall be deemed a permanent cessation of use under this Section). Notwithstanding the foregoing, the Developer shall have the right to terminate this Agreement upon thirty (30) days prior written notice to the Owner. Notwithstanding the foregoing, Section 11 on Indemnification shall survive the termination of this Agreement. Section 11. Insurance; Indemnification. a. DEVELOPER, shall indemnify and hold harmless OWNER, its officers and employees, from any costs, liabilities, claims, losses, and damages (including, without limitation, reasonable attorneys' fees and disbursements at the trial level and all levels of appeal), whether suit is instituted or not, relating to death of or injury {26781517;1} Page 9 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT to persons, or loss of or damage to property, resulting from, arising out of, or incurred in connection with the existence and use of the EASEMENT and the EASEMENT AREA by DEVELOPER, and/or its officials, employees, contractors, and agents; and including, but not limited to, any violation by the DEVELOPER, and/or its officials, employees, contractors, and agents, of any laws, rules, regulations or ordinances regarding hazardous materials, hazardous wastes, hazardous substances, solid waste, or pollution, whether now existing or hereafter enacted or promulgated, as they may be amended from time to time ("Environmental Laws"); any presence, release, or threat of release of hazardous materials, hazardous wastes, hazardous substances, solid waste or pollution at, upon, under, from or within the EASEMENT AREA by DEVELOPER, and/or its officials, employees, contractors, and agents; the failure of DEVELOPER, and/or its officials, employees, contractors, and agents, to duly perform any obligations or actions required to be taken under any Environmental Laws (including, without limitation, the imposition by any governmental authority of any lien or so-called "super priority lien" upon the EASEMENT AREA); any clean-up costs; liability for personal injury or property damage or damage to the environment; and any fines, penalties, and punitive damages, or any fines or assessments incurred by or claimed against OWNER and arising out of the failure of DEVELOPER, and/or its officials, employees, contractors, and agents, to comply with Environmental Laws in connection with the use of the EASEMENT and the EASEMENT AREA by DEVELOPER, and/or its officials, employees, contractors, and agents. b. DEVELOPER shall also, as part of the indemnification provided to OWNER pursuant to this Section, defend any and all claims asserted against OWNER resulting from, arising out of, or incurred in connection with the existence and/or use of the EASEMENT and the EASEMENT AREA by DEVELOPER, and/or its officials, employees, contractors, and agents. DEVELOPER shall be entitled to select counsel of DEVELOPER'S choice to defend the claim; provided, however, that if the DEVELOPER elects to retain outside counsel, then such counsel shall first be approved by OWNER'S City Attorney, which approval shall not be unreasonably conditioned, withheld, or delayed; and, provided further, that the OWNER shall be permitted, at its cost and expense, to retain independent counsel to monitor the claim proceeding. The duty to defend set forth in this subsection shall be severable and independent from the indemnity obligations otherwise set forth in this Section, to the extent that if any other provisions and/or subsections of this Section are deemed invalid and/or unenforceable, this duty to defend provision shall remain in full force and effect. c. The indemnity and defense obligations set forth in this Section shall survive the expiration of the Term or any termination of this EASEMENT regarding any and all costs, liabilities, claims, losses, and damages (including, without limitation, reasonable attorneys' fees and disbursements at the trial level and all levels of appeal), whether suit is instituted or not, relating to death of or injury to persons, or loss of or damage to property, resulting from, arising out of, or incurred in connection with the existence and use of the EASEMENT and the EASEMENT AREA by DEVELOPER and/or its officials, employees, contractors, and/or agents, prior to the expiration of the Term or other termination of the EASEMENT, whether or not such costs, liabilities, claims, losses, and/or damages were known or unknown, accrued or unaccrued, as of the date of expiration of the Term or other termination of the EASEMENT. For purposes of example only and without limiting the generality of the foregoing, costs, liabilities, claims, losses, and/or damages which are unknown or unaccrued as of the date of expiration of the Term {26781517;1 Page 10 of 24;PERPETUAL SUBSURFACE EASEMENT AGREEMENT or other Termination of the EASEMENT could include, but not be limited to, latent construction defects and/or environmental remediation claims. Developer shall also indemnify and hold harmless the Owner and its officers, employees, agents and instrumentalities from any and all liability, losses or damages, including attorneys' fees and costs of defense, which the Owner or its officers, employees, agents or instrumentalities may incur as a result of claims, demands, suits, causes of actions or proceedings of any kind or nature arising out of, relating to or resulting from the performance of this Agreement by the Developer or its employees, agents, servants, partners principals or subcontractors. The Developer shall pay all claims and losses in connection therewith and shall investigate and defend all claims, suits or actions of any kind or nature in the name of the Owner, where applicable, including appellate proceedings, and shall pay all costs, judgments, and attorney's fees which may issue thereon. The Developer expressly understands and agrees that any insurance protection required by this Agreement or otherwise provided by the Developer shall in no way limit the responsibility to indemnify, keep and save harmless and defend the Owner or its officers, employees, agents and instrumentalities as herein provided. d. Insurance. See Schedule A attached to this Agreement and incorporated by reference as if fully set forth herein. Section 12. Condemnation. Should all or part of the Easement Area be taken by governmental action, the rights of the affected parties shall be determined by applicable Florida law. Section 13. Developer's Right to Transfer. During the term of this Agreement, the Developer shall have the right and privilege from time to time to sell, assign or otherwise transfer all or any p ortion of its rights under this Agreement, subject to a pp roval by Owner, which shall not be unreasonably withheld, to such other persons, firms, corporations, general or limited partnerships, unincorporated associations, joint ventures, estates, trusts, any Federal, State, County or Municipal government bureau, department or agency thereof, or any other entities as the Developer shall select; and subject further, however, to the following: a. In the event of a proposed transfer of all of the Developer's rights hereunder, the Developer shall deliver written notice to the Owner of such transfer, together with a copy of the transfer agreement (if applicable) and the address for the transferee thereunder, after which Owner shall have fourteen days to approve or deny such transfer, with written notice of its decision to Developer. If no action is taken by Owner within fourteen days the proposed transfer is automatically deemed to be approved by the Owner; b. Upon the transfer by the Developer, the Developer shall be released and discharged from all of its duties and obligations hereunder which pertain to this Agreement for the then unexpired term of this Agreement; C. Any sale, assignment or transfer of all or any part of the Developer's interest in this Agreement and the Property shall be made expressly subject to the terms, covenants and conditions of this Agreement, and such assignee or transferee shall expressly assume all of the obligations of the Developer under this Agreement applicable to that portion le 126781517;1} Page 1 l of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT of the Agreement being sold, assigned or transferred, and agree to be subject to all conditions and restrictions to which the Developer is subject, but only for matters accruing while such assignee or transferee holds, and only related to, the sold, assigned, or transferred interest. However, nothing in this subsection or elsewhere in this Agreement shall abrogate the Developer's obligation and/or right to payment of any sums due to the Owner which accrued prior to the effective date of such transfer, and the Owner shall always have the right to enforce collection of such sums due in accordance with the terms and provisions of this Agreement; and d. The Developer shall not have the right to assign this Agreement or its rights and obligations under this Agreement to a party that is on the Miami-Dade County Delinquent Vendor List or Disbarment List, or its then equivalent, or any third party, without the prior consent of the Owner. Section 14. Owner's Right to Transfer. During the term of this Agreement, the Owner's right to transfer the Right-of-Way and the Easement Parcel or any portion thereof and to assign any of its rights and obligations under this Agreement shall be subject to the following: a. Owner shall deliver written notice to Developer of such transfer, together with a copy of the transfer agreement (if applicable) and the address for the transferee thereunder; b. Upon the transfer by Owner pursuant to the terms of this Agreement, Owner shall be released and discharged from all of its duties and obligations hereunder from and after the effective date of such transfer and only those which pertain to the portion of the Right-of-Way or Easement Parcel transferred; C. Any sale, assignment or transfer of all or any part of Owner's interest in the Agreement and/or to the Right-of-Way or Easement Parcel, or any portion thereof shall be made expressly subject to the terms, covenants and conditions of this Agreement, and such assignee or transferee shall expressly assume all of the obligations of Owner under this Agreement applicable to such portion being sold, assigned or transferred, and agree to be subject to all conditions and restrictions and obligations to which Owner is subject, but only for matters accruing while such assignee or transferee holds, and only related to, the sold, assigned, or transferred interest; and d. Any successor, assignee or transferee of Owner shall be prohibited from using the Right-of-Way, the Easement Parcel or the Improvements or any portion hereof for any of the prohibited uses as described in Section 12(h) above or in a manner that will adversely impact Developer, the Easement Parcel, the Improvements or the Project. Section 15. Owner's Representations and Warranties. Owner represents and warrants to Developer as follows: a. Owner is the owner of the Right-of-Way and the Easement Parcel, and has the full right, title (free and clear of any liens), power and authority to enter into this Agreement and to encumber the Right-of-Way and the Easement Parcel as described herein without the need for joinder or consent of any third party; {26781517;1} Page 12 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT b. Owner will make available the Right-of-Way (subject to the terms herein) and the Easement Parcel to the Developer as contemplated in this Agreement; C. Owner has full power and authority to enter into this Agreement and perform in accordance with its terms and provisions and that the parties signing this Agreement on behalf of the Owner have the authority to bind the Owner and to enter into this transaction and the Owner has taken all requisite action and steps to legally authorize it to execute, deliver and perform pursuant to this Agreement; and d. Neither this Agreement, nor the easements, covenants, restrictions, obligations or other provisions set forth herein, are prohibited by, in contradiction of, or will result in a breach or default under, any agreements, covenants, restrictions or easements applicable to Owner or the Right-of-Way or the Easement Parcel. The Developer acknowledges that in accordance with Florida Statutes Section 125.411(3) (1990), the Owner does not warrant the title or represent any state of facts concerning the title to the Right-of-Way and the Easement Parcel, except as specifically stated in this Agreement. Section 16. Developer's Representations and Warranties. Developer hereby represents and warrants to the Owner that it has full power and authority to enter into this Agreement and perform in accordance with its terms and provisions and that the parties signing this Agreement on behalf of the Developer have the authority to bind the Developer and to enter into this transaction and the Developer has taken all requisite action and steps to legally authorize it to execute, deliver and perform pursuant to this Agreement. Section 17. Not a Public Dedication. Except as may be specifically and explicitly set forth herein, nothing herein contained shall be deemed to be a gift or dedication of any portion of the Right-of-Way or Easement Parcel to the general public or for the general public or for any g Y g p g P public purposes whatsoever, it being the intention of the Parties that this Agreement shall be strictly limited to and for the purposes herein expressed. Notwithstanding anything to the contrary contained herein, Developer shall have the right to prohibit or limit any solicitation, petition signing, distribution of literature, collection of money, giving of speeches, leafletting, picketing, carrying of signs, canvassing, demonstrations, or similar activities within the confines of the Improvements lying within the Easement Parcel. . Section 18. Breach Shall Not Permit Termination. No breach of this Agreement shall entitle the Owner or Developer to cancel, rescind or otherwise terminate this Agreement, but such limitation shall not affect in any manner any other rights or remedies which Owner or Developer may have hereunder by reason of any breach of this Agreement. Section 19. Defaults; Remedies; Liability. a. Defaults and Remedies. This Agreement may be enforced by either Party by any action available at law or in equity, including, but not limited to injunctive relief and specific performance. In the event that either Party defaults in the performance of any of its obligations pursuant to this Agreement, the non-defaulting Party shall be entitled to cure such default. Any and all expenses incurred by the Party in curing such default, together with interest thereon calculated at the lesser of(i) a rate of interest equal to fifteen percent (15%) per. {26781517;1} iOw�' Pale 13 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT annum, or (ii) the highest rate permitted by Florida law, shall be payable by the defaulting Party within thirty (30) days of written demand therefor by the Party curing the default to the defaulting Party. Interest shall accrue from and after the defaulting Party's receipt of the demand for payment by the Party curing the default. The failure to enforce any of the terms or provisions of this Agreement, however long continued, shall in no event be deemed a waiver of the right to enforce the same thereafter as to the same breach or violation, or as to any other breach or violation occurring prior to or subsequent thereto. The Parties acknowledge and agree that the pursuit by a Party of any one remedy shall not operate as an election of remedies prohibiting the pursuit of other remedies established by this Agreement. The prevailing party to any action or suit pertaining to or arising out of this Agreement shall be entitled to recover, in addition to costs and disbursements, allowed by law, such sum as the Court may adjudge to be reasonable for the serves of his attorney. Notwithstanding anything in the foregoing to the contrary, a "Default" by any party with respect to any of its obligations hereunder shall be deemed to exist only in the event that the non-defaulting party notifies the defaulting party in writing specifically describing the nature of the alleged failure by the defaulting party under this Agreement, and only in the event that the defaulting party has not cured such failure within thirty (30) days of the defaulting party's receipt of such written notice from the non-defaulting party setting forth with specificity the nature of such breach (or if such default cannot reasonably be cured within thirty (30) days, then only if the defaulting party shall fail to commence action within said thirty (30) day period intended to result in cure of such failure, and thereafter diligently pursue same to completion). b. Limitation of Liability of the Owner. Owner shall not be liable to the Developer for any incidental or consequential loss or damage whatsoever arising from the rights of the Owner hereunder. C. Limitation of Liability of the Developer. Developer shall not be liable to the Owner for any incidental or consequential loss or damage whatsoever arising from rights of the Developer hereunder. Excluding damage to the Right-of-Way or the Easement Area caused by the Developer, any liability of the Developer hereunder is limited to the fair market value of the Improvements made by the Developer on the Easement Parcel. Section 20. 'Perm/Amendment. The Easements set forth in this Agreement shall be 99 years in duration unless otherwise specifically provided (such as the Temporary Construction Easement, which is intended to have the limited duration expressed in paragraph 2.a). The restrictions, covenants and conditions set forth in this Agreement shall be binding upon and enforceable against the Developer and the Owner for a period of twenty (20) years from the date this Agreement is filed in the Public Records of Miami-Dade County, Florida, after which time, such restrictions, covenants, and conditions shall be automatically extended for successive periods of twenty (20) years each, until the maximum easement term of 99 years is reached. In the event any law prohibits any such restrictions, covenants, and/or conditions from being enforceable for a period in excess of twenty (20) years, or beyond any other stated period, the Developer is granted a limited and specific power of attorney, coupled with an interest, for the sole purpose to re-record this Agreement at any time and from time to time for the purpose of extending the enforceability of same as contemplated by this Section, as long as the total easement term of 99 years is not exceeded without further written agreement of the parties. (26781517;1) Page 14 of 24;PERPETUAL SUBSURFACE EASEMENT AGREEMENT Section 21. Estoppel. Each Party shall, at the request of the other Party, execute and deliver an acknowledgment in such reasonable form as may be requested stating that the Easements and covenants set forth in this Agreement are in full force and effect (if such is the case and if not, the specific areas of relinquishment of same), that said Party knows of no violation of this Agreement (if such is the case and if not, what violations exist), that the requesting Party is in compliance with this Agreement (if such is the case and if not, the specific areas of non-compliance), and such other reasonable information as requested by the other Party. Section 22. Entire Agreement. This Agreement constitutes the entire agreement between the Parties hereto with respect to the Easements and it supersedes all understandings or agreements between the Parties existing prior to the Effective Date, except as provided in Section 8. Any modification to this Agreement shall be required to be in writing and executed by the Parties. Section 23. Binding Effect/Rights of Occupants. All terms and provisions of this Agreement are binding upon the Parties hereto and their respective successors and assigns. Further, all terms and provisions of this Agreement and all rights, privileges, benefits and burdens created hereunder are covenants running with the lands described herein, binding upon and inuring to the benefit of the Parties hereto, their respective heirs, successors, successors-in- title, legal representatives and assigns. With respect to the Easements created by this Agreement, Developer shall be entitled to designate from time to time which, if any, of its Occupants (as hereinafter defined) shall be entitled to utilize and enjoy such Easements and to create such rules and regulations as deemed necessary or appropriate by Developer, including the right to regulate the hours and days for access to the Easement Parcel. No independent rights shall be created by this Agreement as to any Occupant, except with the consent or approval of the Developer. For purposes of this Agreement, the term "Occupant" shall mean the Developer or any of its tenants, subtenants, assignees, concessionaires, licensees, invitees, contractors, agents or licensees who, from time to time, are entitled to use or occupy all or any portion of the Easement Parcel under an agreement, lease, sublease, assignment, concession, license, or other similar agreement with the Developer. Section 24. Construction. Each Party hereto hereby acknowledges that all Parties hereto participated equally in the drafting of this Agreement and that, accordingly, no court construing this Agreement shall construe it more stringently against one party than the other. Section 25. Execution and Counterparts. This Agreement may be executed in as many counterparts as may be required and it shall not be necessary that the signature of, or on behalf of, each party, or that the signatures of all persons required to bind any party, appear on each counterpart; it shall be sufficient that the signature of, or on behalf of, each party, or that the signatures of the persons required to bind any party, appear on one or more of such counterparts. All counterparts shall collectively constitute a single agreement. Section 26. Governing LawNenue. This Agreement shall be governed by and construed under the laws of the State of Florida. Venue for any action arising out of this Agreement shall be Miami, Florida [or Miami-Dade County, Florida]. {26781517;1} Page 15 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT Section 27. Notices. Any notices which may be permitted or required hereunder shall be in writing and shall be deemed to have been duly given as of the date and time the same are received at the addressee's address set forth below, whether same are personally delivered, mailed by United States Postal Service, postage prepaid by registered or certified mail, return receipt requested, delivered by Federal Express or other overnight delivery service from which a receipt may be obtained, and addressed as follows: To Owner: City Attorney 1700 Convention Center Drive Miami Beach, Florida 33139 With a copy to: Director of Public Works 1700 Convention Center Drive Miami Beach, Florida 33139 City Manager 1700 Convention Center Drive Miami Beach, Florida 33139 To Developer: The Faena Group 3201 Collins Avenue Miami Beach, FL 33139 Attention: Sergio Jalife With a copy to: Akerman Senterfitt One SE Third Avenue, 25th Floor Miami, Florida 33131 Attention: Neisen Kasdin, Esq. or to such other address as either party hereto shall from time to time designate to the other party by notice in writing as herein provided. Section 28. Time. Time is of the essence of this Agreement. Notwithstanding anything in the foregoing to the contrary, in the event that the time for performance of any event or obligation under this Agreement ends on a Saturday, Sunday, or legal holiday, then the date for performance of such event or obligation shall automatically extend to the next day that is not a Saturday, Sunday or legal holiday. Section 29. Waiver. No delay in exercising any right or remedy shall constitute a waiver thereof, and no waiver of the breach of any provision of this Agreement shall be construed as a waiver of any preceding or succeeding breach of the same or any other provision of this Agreement. Section 30. Section Headings. The paragraph and sub-paragraph headings as herein used are for convenience or reference only and shall not be deemed to vary the content of this Agreement or the covenants, agreements, representations and warranties herein set forth or limit the provisions or scope of any section herein. {2678117;1} Pa-e 16 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT Section 31. Severability. This Agreement is intended to be performed in accordance with, and only to the extent permitted by, all applicable laws, ordinances, rules and regulations. If any provision of this Agreement or the application thereof to any person or circumstance shall, for any reason and to any extent, be invalid or unenforceable, the remainder of this Agreement and the application of such provision to other persons or circumstances shall not be affected thereby but rather shall be enforced to the greatest extent permitted by law. Section 32. Successors and Assigns. This Agreement runs with the land and shall be binding upon and shall inure to the benefit of the parties hereto, and their respective successors and assigns, subject to the rights of the Parties to approve successors and assigns. Section 33. Relationship of the Parties. This Agreement does not create the relationship of principal and agent or of mortgagee and mortgagor or of partnership or of joint venture or of any association between the Parties, the sole relationship between the Parties being that of the Owner and the Developer. Section 34. Recording. This Agreement shall be recorded among the Public Records of Miami-Dade County, Florida, at the sole cost of the Developer. Section 35. Consents. Whenever in this Agreement the consent or approval of the Owner or the Developer is required, such consent or approval, with respect to the City as the Owner shall be made by the City Manager or Owner's Representative or their designees on behalf of the Owner and: (a) shall not be unreasonably or arbitrarily withheld, conditioned, or delayed unless specifically provided to the contrary, and shall not require a fee from the party requesting same; (b) shall not be effective unless it is in writing; and (c) shall apply only to the specific act or transaction so approved or consented to and shall not relieve the Developer or the Owner, as applicable, of the obligation of obtaining the other's prior written consent or approval to any future similar act or transaction. Section 36. Brokers. The Parties hereby represent and agree that no real estate broker or other person is entitled to claim a commission as a result of the execution and delivery of this Agreement. Section 37. Protest Payments. If at any time a dispute shall arise as to any amount or sum of money to be paid by the Developer to Owner, if any, under the provisions of this Agreement, in addition to the rights set forth in Section 19 above, the Developer shall have the right to make payment "under protest" and such payment shall not be regarded as a voluntary payment, and there shall survive the right on the part of the Developer to seek the recovery of such sum, and if it should be adjudged that there was no legal obligation on the Developer to pay such sum or any part thereof, the Developer shall be entitled to recover such sum or so much thereof as it was not legally required to pay under the provisions of this Agreement; and if at any time a dispute shall arise between the parties hereto as to any work to be performed by either of them under the provisions of this Agreement, the party against whom the obligation to perform the work is asserted may perform such work and pay the cost thereof "under protest" and the performance of such work shall in no event be regarded as a voluntary performance and there shall survive the right upon the part of said Developer and/or the Owner to seek the recovery of the cost of such work, and if it shall be adjudged that there was no legal obligation on the part of {26781517;1} Page 17 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT said Developer and/or the Owner to perform the same or any part thereof, said Developer and/or the Owner shall be entitled to recover the cost of such work or the cost of so much thereof as the Developer or the Owner was not legally required to perform under the provisions of this Agreement. [Remainder of Page Intentionally Blank] i {26781517;1} Page 18 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT IN WITNESS WHEREOF, the Owner has caused this Agreement to be executed in its name by the City Mayor; as authorized by the City Commission, and the Developer has caused this Agreement to be executed by its duly authorized representative all as of the Effective Date. OWNER(Grantor): CITY OF MIAMI BEACH By: May *iryT.rf iami each Attest: CV Clerk C' each Approved as to form and IaZ.. d for ex cu ion ko ey Da d STATE OF FLORIDA CH COUNTY OF MIAMI-DADE The foregoing instrument was knowledged before me this day of , 2013, by oa)ff—, who is personally known to me or s produced as identification. ary Public in and or t Coun State mentioned above ,�,������- wAM R.HATRED = '= MY O,0MMISS10N#EE 844865 1 g 8,2017 (AFFIX NOTARY SEAL) M Commission Expire exPlaES:February a M�Ttuu Notary Public Undermders y Po w'o p •�' THE REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK (26781 17,1) Page 19 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT Signed in the presence of: DEVELOPER(Grantee) COLLINS 3300, LLC, a Foreign Limited Liability Corporation By: Name: Sergio Jalife Print Name: Title: Manager, Collins 3300, LLC Print Name: STATE OF FLORIDA COUNTY OF MIAMI-DADE The foregoing instrument was acknowledged before me this day of , 2013, by Sergio Jalife, who is personally known to me or has produced as identification. Notary Public in and for the County and State mentioned above (AFFIX NOTARY SEAL) My Commission Expires THE REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK 126781517;1} Page 20 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT Signed in.the presence of: DEVELOPER(Grantee) 3420 COLLINS AVENUE, LLC, a Foreign Limited Liability Corporation By: Name: Sergio Jalife Print Name: Title: Manager, 3420 COLLINS AVENUE, LLC Print Name: STATE OF FLORIDA COUNTY OF MIAMI-DADE The foregoing instrument was acknowledged before me this day of , 20135 by Sergio Jalife, who is personally known to me or has produced as identification. Notary Public in and for the County and State mentioned above (AFFIX NOTARY SEAL) My Commission Expires THE REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK (26781517;1) Page 21 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT SCHEDULE A- INSURANCE - CONSTRUCTION The Developer and Contractor shall furnish to Risk Management Division, Department of Human Resources, City of Miami Beach, 1700 Convention Center Drive, 3rd Floor, Miami Beach, Florida 33139, Certificate(s) of Insurance, prior to the commencement of construction, which indicate that insurance coverage has been obtained that meets the requirements as outlined below: A. Commercial General Liability on a comprehensive basis, including Contractual Liability, Products/Completed Operations, XCU, and Pollution Liability in an amount not less than $1,0003000 combined single limit per occurrence for bodily injury and property damage. City of Miami Beach must be shown as an additional insured with respect to this coverage. B. Excess/Umbrella Liability, in amount not less than $5,000,000 combined single limit, per occurrence for bodily injury and property damage. All deductibles for insurance required in this Agreement are the responsibility of the Developer and Contractor. The insurance coverage required shall include those classifications, as listed in standard liability insurance manuals, which most nearly reflect the operations of the vendor. All insurance policies required above shall be issued by companies authorized to do business under the laws of the State of Florida, with the following qualifications: The company must be rated no less than "B" as to management, and no less than "Class V" as to financial strength, by the latest edition of Best's Insurance Guide, published by A.M. Best Company, Oldwick, New Jersey, or its equivalent, subject to the approval of the City Risk Management Division. or The company must hold a valid Florida Certificate of Authority as shown in the latest "List of All Insurance Companies Authorized or Approved to Do Business in Florida" issued by the State of Florida Department of Insurance and are members of the Florida Guaranty Fund. Certificates will indicate no modification or change in insurance shall be made without thirty (30) days in advance notice to the certificate holder. CERTIFICATE HOLDER MUST READ: CITY OF MIAMI BEACH 1700 CONVENTION CENTER DRIVE 3rd FLOOR MIAMI BEACH, FL 33139 Compliance with the foregoing requirements shall not relieve the Developer and Contractor of their liability and obligation under this section or under any other section of this Agreement. {26781517;1} Page 22 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT Schedule B—City Code Section 46-156 (relevant portions) Requirements and procedures. The city manager is authorized to issue a temporary permit to allow noise when produced by a temporary use or activity as provided in this section. The city manager may prescribe any reasonable conditions necessary to minimize any adverse effect upon the community. A permit granted under this article shall contain all conditions upon which the permit has been granted, including the period of time for which the permit has been granted. Such relief may be granted in the following situations: (1) Code compliance in progress. When an applicant is utilizing best efforts to comply with the noise restrictions in this article, but additional time is required for the applicant to modify his activity to comply and no reasonable alternative is available to the applicant, such permits may be granted for a period of time not to exceed ten consecutive days. .(2) Construction. When construction activities pursuant to a valid building permit cannot be carried out in a manner which would comply with section 46-152, notwithstanding that all equipment is operated in accordance with manufacturer's specifications, is in good repair and utilizes all noise baffling methods as specified by the manufacturer, such activities shall occur only as follows: b. Between the hours of 8:00 a.m. and 6:00 p.m. on weekdays and 10:00 a.m. and 4:00 p.m. on Saturdays in areas zoned as RM-1, RM-2, RM-3, RM-PRD, RPS-1, RPS-2, RPS-3, RPS-4, RMPS-1, RS-1, RS-2, RS-3, RS-4, RO, TH and in any exclusively residential zoning district not otherwise specified in this subsection and within 300 feet of any of these zoning districts. On Sundays and national holidays, construction shall not be permitted before 10:00 a.m. or after 4:00 p.m. and construction noise that violates section 46-152 shall not be permitted between 10:00 a.m. and 4:00 p.m. in the zoning districts set forth in this subsection or within 300 feet thereof, except that in buildings with occupied apartment units, as defined in section 114-1 of this Code, no construction shall be allowed on Sundays or national holidays. However, the city manager may authorize any necessary construction activities to occur earlier and/or later than as otherwise provided in this subsection based upon a finding that: 1. There are no reasonable alternatives; 2. There are no prior code violation adjudications or fines and no pending construction noise violation cases against the property owner, contractor, or construction site; and 3. There is a significant community need, public purpose or benefit. The work authorized by the city manager may be conditioned upon reasonable notice to surrounding property owners and tenants. Permits issued pursuant to such authorization shall not exceed three consecutive days. c. The issuance of a temporary permit is a privilege and does not constitute a right or expectation that said permit will remain in effect. Any permits issued pursuant to subsections (2)a. and b., shall not constitute or be deemed precedent for the granting of any future permits. (26781517-,1) Page 23 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT i d. Notwithstanding the provisions of subsections (2)a. and b., temporary permits shall be subject to authorization by the building official under emergency circumstances or when the building official determines that for reasons of technical necessity work earlier or later than the time frames specified in subsections (2)a., b. or on any day (including Sundays or national holidays) is required. The work authorized by the building official pursuant to this subsection shall be conditioned upon reasonable notice to surrounding property owners and tenants. (b) Violation of temporary permit. Failure to comply with any condition of a temporary permit issued pursuant to this section shall constitute a violation and shall result in enforcement procedures and penalties as set forth in sections 46-159 and 46-160 (c) Revocation of temporary permits. Any temporary permit may be immediately revoked pursuant to the procedures set forth in sections 102-383 and 102-385 if the city manager finds that an emergency condition exists involving serious danger to the public health, safety, or welfare; if the permit holder failed to disclose or misrepresented material information in the permit application or in the permit application process; or that there was a failure to comply with any condition of a particular temporary permit. (26781517;1) Page 24 of 24,PERPETUAL SUBSURFACE EASEMENT AGREEMENT Exhibit A STONER &ASSOCIATES, INC. SURVEYORS-MAPPERS 4341 S.W. 62nd Avenue Florida Licensed Survey Tel. (954) 585-0997 Davie, Florida 33314 and Mapping Business No.6633 Fax (954) 585-3927 RECORDING AREA LEGAL. DESCRIPTION OF: A SUBTERRANEAN EASEMENT LYING IN SECTION 26, TOWNSHIP 53 SOUTH, RANGE 42 EAST CITY OF MIAMI BEACH, MIAMI-DADE COUNTY, FLORIDA A SUBTERRANEAN EASEMENT BEING A PORTION OF SECTION 26, TOWNSHIP 53 SOUTH, RANGE 42 EAST, LYING WITHIN THE CITY OF MIAMI BEACH, MIAMI—DADE COUNTY, FLORIDA; ALSO, BEING UNDER 34th STREET, A PUBLIC DEDICATED RIGHT OF WAY WITHIN SAID CITY OF MIAMI BEACH; SAID EASEMENT BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS: COMMENCE AT THE NORTHEAST CORNER OF LOT 7, BLOCK 20 OF THE AMENDED MAP OF THE OCEAN FRONT PROPERTY OF THE MIAMI BEACH IMPROVEMENT COMPANY, ACCORDING TO THE PLAT THEREOF, AS RECORDED IN PLAT BOOK 5, PAGES 7 AND 8, OF THE PUBLIC RECORDS OF MIAMI—DADE COUNTY, FLORIDA. THENCE NORTH 82'28'02" WEST, ALONG THE NORTH LINE OF LOT 7 AND ALSO ALONG THE SOUTH RIGHT OF WAY LINE FOR SAID 34th STREET, A DISTANCE OF 15.79 FEET TO THE POINT OF BEGINNING; THENCE CONTINUE NORTH 8228'020 WEST, ALONG THE NORTH LINE OF LOTS 7 AND 10 OF SAID BLOCK 20 AND ALSO ALONG SAID SOUTH RIGHT OF WAY LINE, A DISTANCE OF 93.92 FEET; THENCE NORTH 07 31'57° EAST, A DISTANCE OF 6.42 FEET; THENCE NORTH 14'5734° EAST, A DISTANCE OF 27.45 FEET; THENCE NORTH 07'31'57" EAST, A DISTANCE OF 16.22 FEET TO A POINT ON THE SOUTH LINE OF LOT 17, BLOCK 22, OF SAID PLAT OF AMENDED MAP OF THE OCEAN FRONT PROPERTY OF THE MIAMI BEACH IMPROVEMENT COMPANY AND ALSO TO A POINT ON THE NORTH RIGHT OF WAY LINE FOR SAID 34th STREET; THENCE SOUTH 82 35'19° EAST, ALONG THE SOUTH LINE OF LOTS 17 AND 10 OF SAID BLOCK 22 AND ALONG SAID NORTH RIGHT OF WAY LINE, A DISTANCE OF 89.77 FEET; THENCE SOUTH 0731'57" WEST, A DISTANCE OF 50.04 FEET TO THE POINT OF BEGINNING. THE TOP OF THE EASEMENT HAVING AN ELEVATION OF +0 FEET 4 INCHES (+0'4" = +0.33) AND THE BOTTOM OF THE EASEMENT HAVING AN ELEVATION OF —12 FEET 8 INCHES (-12'8" = —12.66) SAID ELEVATIONS ARE RELATIVE TO THE NATIONAL GEODETIC VERTICAL DATUM OF 1929 (NGV029). SAID EASEMENT SITUATE, LYING AND BEING IN THE CITY OF MIAMI BEACH, MIAMI—DADE COUNTY, FLORIDA, CONTAINING 59,215 CUBIC FEET, MORE OR LESS. NOTES: 1. THE PROPERTY SHOWN HEREON WAS NOT ABSTRACTED FOR OWNERSHIP, RIGHTS—OF—WAY, EASEMENTS OR OTHER MATTERS OF RECORD BY STONER & ASSOCIATES, INC.. 2. THIS SKETCH DOES NOT REPRESENT A FIELD SURVEY. (THIS IS NOT A SURVEY). 3. THIS SKETCH OF DESCRIPTION WAS PREPARED BY THIS FIRM WITHOUT THE BENEFIT OF A TITLE SEARCH. AND WAS BASED ON: A. AMENDED MAP OF THE OCEAN FRONT PROPERTY OF THE MIAMI BEACH IMPROVEMENT COMPANY, ACCORDING TO THE PLAT THEREOF, RECORDED IN PLAT BOOK 5, PAGES 7 & 8, MIAMI—DADE COUNTY, FLORIDA. B. STONER & ASSOCIATES, INC. PROJECTS NUMBER 04-6545, 08-7228, 11-7613, 11-7729 C. SKETCH PROVIDED BY CLIENT. 4. THE BEARINGS SHOWN HEREON ARE BASED ON N.29°57'53"E., ALONG THE BASELINE OF STATE ROAD AIA (INDIAN CREEK DRIVE), AS SHOWN ON FLORIDA DEPARTMENT OF TRANSPORTATION PROJECT NETWORK CONTROL SHEET, FINANCIAL PROJECT ID. 414641-1-52-01, BETWEEN BASELINE STATIONS 51+40.33 AND 53+57.73. 5. TOP AND BOTTOM ELEVATIONS PROVIDED BY CLIENT. CERTIFICATE: THIS IS TO CERTIFY THAT THE SKETCH AND LEGAL DESCRIPTION SHOWN HEREON IS ACCURATE AND CORRECT TO THE BEST OF MY KNOWLEDGE AND BELIEF. 1 FURTHER CERTIFY THAT THIS SKETCH AND LEGAL DESCRIPTION MEETS THE MINIMUM 'TECHNICAL STANDARDS SET FORTH BY THE FLORIDA BOARD OF PROFESSIONAL SURVEYORS AND MAPPERS IN CHAPTER 5J-17, FLORIDA ADMINISTRATIVE CODE, SEAL w t C PURSUANT TO SECTION 472.07, FLORIDA STATUTES. REVISIONS DATE BY ��) ,,t ( �1 •!��' NOT VALID UNLESS 1 REVISE EASEMENT PER CLIENT 03/07/12 WDLR WALTER DE L4 ROCHA SEALED HERE WITH � AN EMBOSSED o re) 2 IREVISE EASEMENT WITH ELEV, 04 28 13 WDLR PROFESSIONAL SURVEYOR AND MAPPER NO. 6081 — STATE OF FLORIDA SURVEYOR'S SEAL Z THE MATERIAL SHOWN HEREON IS THE PROPERTY OF STONER & x ASSOCIATES, INC. AND SHALL NOT BE REPRODUCED IN WHOLE OR DATE OF SKETCH: DRAWN BY CHECKED BY FIELD BOOK U IN PART COPYRIGHT OF STONER & ASSOCIATES, INC. 02/22/12 WIDLR JDS N/A SHEET 1 OF 2 Y I DATE: May 09, 2013 - 7:37om EST FILE: F:\Draw\MISC\11-7729 Saxony Hotel - Claro\dwq\11-7735 UGE.dwq Exhibit A STONER &ASSOCIATES, INC. SURVEYORS-MAPPERS Tel. 954 585-0997 4341 S.W. 62nd AVE. Florida Licensed Survey ( ) Davie, Florida 33314 and Mapping Business No.6633 Fax (954) 585-3927 RECORDING AREA SKETCH OF DESCRIPTION OF: A A SUBTERRANEAN EASEMENT LYING IN SECTION 26, TOWNSHIP 53 SOUTH, RANGE 42 EAST CITY OF MIAMI BEACH, MIAMI-DADE COUNTY, FLORIDA ARTHUR G DF EY RD. LEGEND: .. . PLAT BOOK i PG.. ............ PAGE 5th St.4� M-D.C.R......... .MIAMI-DADE COUNTY RECORDS N 1a 1a ! P.0.C... ......... POINT OF COMMENCEMENT , i6 12 THIS P.O.B.. .... ...... POINT OF BEGINNING °» SKETCH (P) . ......... PER PLAT 34th St. (R) . ......... . PER RECORDS L-14 R/W... .........RIGHT-OF-WAY O BLOCK 20 ' 2 ' a 2 E EL. ............. .ELEVA T ON V� 33rd St Q 6 1 BLOCK 1.9 p NGVD29 . ....... .NATIONAL GEODETIC VERTICAL V DATUM OF 1929 O e a SCALE: 1" = 40' a 32n V a 2 BLOC 17 o'Si 1 Q o 10 so 40 so GRAPHIC SCAI F - SOUTH RIGHT NORTH RIGHT VICINITY MAP OF WAY LINE OF WA Y LINE (NOT TO SCALE) TOP OF 34th STREET EASEMENT NOTE: EL.= +0'4" _ _ _ _ NGVD29 SEE SHEET 1 FOR THE LEGAL DESCRIPTION OF I— EL.= 0'0" THE SKETCH GRAPHICALLY SHOWN HEREON. BOTTOM OF ►-i EASEMENT BLOPK 22 EL.= -12'8" CROSS SECTION VIEW AM ENDED P OF NOT TO SCALE THE OA FRONT M/A M/ OF THE PROPER T Y LOT 17 EACH /MP s PC T CO G. MP souTH 8, M_ ANY O S LINE D.C.R. LOT 10 J� LOT 17 _ I 100' (p� SOUTy LINE SOF CORNER Q o NOR Ty LOT 1 p RIGH T OF LOT 10 BLOCK 22 J m Q OF WA Y L/NE• S 8 100' (P) 22 O �c N 071,31'S7" 2 3519 E 3 m �V N 14.5734 E 34th STREE �. . J Q Q o°Uw RIGHT N 27.45' 10th STR T �- Z �O AY LINE 076 31,7„ E. 50' RIGHT OF WAY (�R I 100 (P 8 P. p N, Q N 2 28 D2ry 93 B. NOR (P)LINE �/ � LOT 10 .32 U) w r\ BLOC NORTH LINE (P roN ^� Q O coo LOT 10 K 20 of LOT � p. AMENDED_MqP O•C THE OCEAN FR N T OF LOT N.E. COST ER OF OF 7, MIAMI SE A CH IMP HE PROPERTY BLOCK 20 Q I P"3' 5, P ROVEMEN T CO 7'8. M-D.0 MPANY Z v� R. 100.00 P) I � W� 3 Li O SKETCH NO. DATE: May 09, 2013 - 7:39am EST FILE: F:\Draw\MISC\11-7729 Saxony Hotel - Claro\dwg\11-7735 UGE.dwg [SHEET 2 OF 2111-7735 UGE EXHIBIT B Legal Description of Grantee Property Lots 10, 11, 12 and Lot 13, Block 22, all of the amended map of the ocean front property of the Miami Beach Improvement Company, as recorded in Plat Book 5, at Pages 7 & 8 of the public records of Miami-Dade County, Florida; together with; All of Block 20 and all that land lying west of Indian Creek Drive and between the north line of Lot 10 in Block 20 and the south line of Lot 10 in Block 20 both produced westerly to the waters of Indian Creek, all of Amended Map of the Ocean Front Property of the Miami Beach Improvement Company, according to the amended plat thereof, as recorded in Plat Book 5, at Pages 7 & 8 of the public records of Miami-Dade County, Florida; also described more particularly,_as; A parcel of land being a portion of Section 26, Township 53 South, Range 42 East, lying within the City of Miami Beach, Miami-Dade County, Florida. Said parcel of land being more particularly described as follows: Begin at the Southeast corner of Lot 9, Block 20, of the Amended Map of the Ocean Front Property of the Miami Beach Improvement Company, according to the amended plat thereof, as recorded in Plat Book 5, at Pages 7 & 8 of the public records of Miami-Dade County, Florida. Thence North 07 degrees 35'14" East, along the East line of Lots 9, 8 and 7 of said Block 20, and the West right of way line of State Road A I A (Collins Avenue), a distance of 131.00 feet to the Northeast corner of said Lot 7, Block 20; thence North 82 degrees 28'02" West, along the North line of Lots 7 and 10, of said Block 20 and the South right of way line of 34th Street, a distance of 200.48 feet to the Northwest corner of said Lot 10, said point being reference Point "A"; thence South 07 degrees 25'37" West, along the West line of said Lot 10, and the East right of way line of Indian Creek Drive, a distance of 87.01 feet to the Southwest corner of said Lot 10; thence South 70 degrees 04'28" East, along the South line of said Lots 10 and 9, and the North right of way line of 33rd Street, a distance of 204.97 feet to the Point of Beginning; TOGETHER WITH: Commence at the aforementioned reference Point "A"; thence North 82 degrees 28'02" West, along the Western projection of the North line of said Lot 10, a distance of 50.00 feet to the Point of Beginning; thence continue North 82 degrees 28'02" West, a distance of 7.94 feet; thence South I1 degrees 30'22" West, a distance of 73.30 feet; thence South 70 degrees 04'28" East, along the Western projection of the South line of said Lot 10, a distance of 13.47 feet; thence North 07 degrees 25'37" East, along the West right of way line of said Indian Creek Drive, a distance of 76.02 feet to the Point of Beginning. Said lands situate within the City of Miami Beach, Miami-Dade County, Florida. (23796058;1} Page I of 2 of EXHIBIT B EXHIBIT B Sketch of Grantee Property not to scale ill W r Vb w tR,rd'� i tiwt OB-,j; x{:1t •-'�"-,-A•�-`_'_"° 437;:f3'jy"� -1°�:• 1 .:..,� °'�, ��h � _ ;-• c^--^_,_°� g LOT;�t arAl; r Ip 6�II<`a i yp !• 'i R ,�lWr•o t ���v � � ' '�.. � � is N4',vy ! t-I• '`IJi.N�",j�N.a�y� JS�� _ �! �i- ..� z 7.`k .% ,.- ••�d.� :Iq'41AyK A't��Y fffL?yr ,k_' � � s c t ;,y t �'kF'" r +�q��4'-� ^ ^c�5• _nay F''';rw ��¢���vt~� $; /"3 k��s E i r 1 JJ F I "' (•` R� _.'•rte �7w -(:r�`�' i x(, c ! �Ya1 Q; v yI i 77 At i!• AJi A�.'s�t?[.i(JI y,41 r�.Z• ...III 1r'/,f ; ! i f!8! ~ � tGf7. C tN cc..xs a wr -4 LO �p°"t°Ryd\\qi aLy�m�.v'� a�.-_._�•i.4-l�ce`" A T IWO Bt=22 ! AueYMW U)P!V JiL 7C'AN rrr%r i A DIEM'C�Wly! a s I ! q A�n,rrP.,xclr 40', MT"LEE T r.O.© m' ;sir v/a 1 jL A AA°t`.Y PAW RjYF'ra}(ej tc,7.se:oc+r x_. Z278%2! K K L'.^.%EN >�A! 2'4y�j_ `!�/�'°.�—� 3'MVD 3 RS IMP AW tm u xe •c4r?vt r+ACwe sv)tES b 7.56'(C) . � .t r! ..,mM.. ..,',_. _'',�.. _ 140 .-u.s..._z.a.';cl i ai ILI . 4s. 0 s�xlc{z PAR 8 4 C _'QY M Y pj (aY C r33G' M: �I r F f4LSNJ!'u y;P G.rrc W:rm 9.". I LY'�C 1 aackn;r❑ ^i rt.°AU'tl"lGtl � Y - 'ti::.. 0.. /: e'S• �" .0!L Purrs r -Etter n N'.ti S fir:j-4.v.-u:v) �A14 ?M E:ac r r 3 F )°((S'Ac CY G537 a,.0 tJLr cow.a2Anu ! r ' �(:�r 8D:::.dAleq.y 7$RV• •,wt f r rx.1'.ps I,T..tS C` � as ' :.. ass,a 1 a acacx.�c pr4id s7a C4728 1E Vic/ °3? {C} t�1tiyw lcn, F.'*•'. 1 L0I.9 E.wbr LBT!• a r.�no.� ~� TMw`--szto r rtt" d 32t. C-r+tom' ��_^'�`I' r �'•`n� ��;•'°U` p. OF S 123796058-111 Page 2 of 2 of EXHIBIT B • • • M M•••�1 ® I Z 1 O I C ® cu D 6 t ( \ MD t! C I 2 c ® E I w N 'I co I 3 I LOT i I LOT 16 r I \ '/ j °s-ia i � - BUI TORY 9LOCK 22 9'= 1 I 'A TLAfJ TIC _. ii PONTJED,NAP y THE OCEAN J I ' CIE IV `4MEN EPL7EEP i1'OF THE MIA.NI --- 1 PEACH MPPOVEMENT COMPAH-1 C u LOT 10 / P.9 5,P% 7-0.M-C Ck. C(D E -—\ I I E LOT 17 N _Ii w V) / .'_ I lvcs?dcc3 /fir IALL C — y CC'rr RrWP��DP?�n 86 iF rr n CJFnCR or[0*,�\� [�^E_ �tC 5➢KES _s000'I � �® _ tovc.rr s0n.u• ° r�-- � a"E'1 - \�.wR I ¢W>B r- P) �a[t0,r 1/ �in`��- o U I - cn Qua, 11 �� I I 111 1 I r W1�1 LOT 7 - - T G c C-1 vi L 0 T 3 7 3 page 1 of 1 EXHIBIT C Exhibit D RESOLUTION NO. 2012-28092 A RESOLUTION OF THE MAYOR AND THE CITY COMMISSION OF THE CITY OF MIAMI BEACH, FLORIDA, APPROVING, IN CONCEPT, THE GRANT OF AN EASEMENT TO COLLINS 3300, LLC AND 3420 COLLINS AVENUE, LLC (THE APPLICANT), OWNERS OF THE PROPERTIES LOCATED AT 3301 INDIAN CREEK DRIVE, 3400 COLLINS AVENUE AND 3420 COLLINS AVENUE, FOLLOWING A DULY NOTICED PUBLIC HEARING, FOR A PROPOSED SUBSURFACE PARKING GARAGE, THAT SPANS THE ENTIRE WIDTH OF THE 50-FOOT PUBLIC RIGHT-OF-WAY OF 34TH STREET FOR A LENGTH OF APPROXIMATELY 93 FEET; PROVIDED, HOWEVER, THAT THE AFORESTATED CONCEPTUAL APPROVAL BE SUBJECT TO AND CONTINGENT UPON COMPLETION OF CONTINUING NEGOTIATIONS OF THE EASEMENT AND AN AGREEMENT BETWEEN CITY AND THE APPLICANT, WHICH EASEMENT AND AGREEMENT, IF SUCCESSFULLY NEGOTIATED AND FINALIZED, SHALL BE SUBJECT TO FINAL APPROVAL BY THE CITY MANAGER AND CITY ATTORNEY; FURTHER AUTHORIZING THE MAYOR AND CITY CLERK TO EXECUTE THE FINAL EASEMENT AND AGREEMENT, IF AND WHEN FINALIZED; FURTHER ACCEPTING THE RECOMMENDATION OF THE CITY MANAGER. WHEREAS, Collins 3300, LLC And 3420 Collins Avenue, LLC, (Applicants) are owners of the properties located at 3301 Indian Creek Drive, 3400 Collins Avenue, and 3420 Collins Avenue (collectively, the Properties); and WHEREAS, the Applicants wish to connect the Properties and provide for required parking with a subsurface parking garage beneath 34th Street; and WHEREAS, the portion of the parking garage underneath the right-of-way is proposed to be 12 feet 10 inches below ground-level with a width of 50 feet and a length of approximately 93 feet; and WHEREAS, the Applicants have received approval from the City's Historic Preservation Board (pursuant to HPB Order No. 7299)to redevelop the Properties; and WHEREAS, at its June 13, 2012 meeting, the Land Use and Development Committee recommended that the City Commission set a public hearing to consider the granting of Applicants' request; and WHEREAS, at its July 18, 2012 meeting, the City Commission approved Resolution No. 2012- 27950, setting a public hearing to consider this request. NOW, THEREFORE, BE IT RESOLVED BY THE MAYOR AND CITY COMMISSION OF THE CITY OF MIAMI BEACH, FLORIDA, that the Mayor and City Commission hereby approve in concept, the grant of an easement to-Collins 3300, LLC and 3420 Collins Avenue, LLC (the Applicant), owners of the properties located at 3301 Indian Creek Drive, 3400 Collins Avenue and 3420 Collins Avenue, following a duly noticed public hearing, for a proposed subsurface parking garage, that spans the entire width of the 50-foot public right-of-way of 34t" Street for a length of approximately 93 feet; provided, however, that the aforestated conceptual approval be subject to and contingent upon completion of continuing negotiations of the easement and an agreement between the City and the Applicant, which easement and agreement, if successfully negotiated and finalized, shall be subject to final approval by the City Manager and City Attorney; further authorizing the Mayor and City Clerk to execute the final easement and agreement, if and when finalized; further accepting the recommendation of the City Manager. �oo2-Z8o9Z Exhibit D PASSED AND ADOPTED this 12"day of December, 2012. ATTEST: l M erre a Bower, May Rafae ranado, City CI rk ,6� APPROVED AS TO FORM, A L NGUAGE, AND FOR EXECUTION ? INCORP ORATED: 1 Z-7-I.Z 'Attorne Date TAAGENDA\2012 112-12-12\easements\3300 Collins Subterranean Easement-RESO by FB rev GH 12-7-12.docx f Exhibit D TERMS AND CONDITI®NS FOR PERPETUAL SUBSURFACE EASEMENT AGREEMENT These terms and conditions for a perpetual subsurface easement agreement ("Term Sheet") are dated this day of , 20 ("Effective Date"). The parties to the Term Sheet are the CITY OF MIAMI BEACH a political subdivision of the State of Florida, whose address is 1700 Convention Center Drive, Miami Beach,Florida 33139 ("City"), and COLLINS 3300, LLC and 3420 COLLINS AVENUE, LLC, both of whom are Foreign Limited Liability Corporations, whose address is 730 Fifth Avenue, 20`h Floor, New York, NY 10019 ("Developer"). RECITALS: A. City is the political subdivision of jurisdiction to all of the right-of-way known as 34`' Street ("Right-of-Way") and that certain real property, situated, lying and being in Miami-Dade County, Florida, as legally described and depicted in the Perpetual Subsurface Easement Agreement ("Easement Agreement"), consisting of a portion of the Right-of-Way(the"Easement Parcel"), as depicted in Exhibit A. B. Developer is the owner of fee simple title to that certain real property situated, lying and being in Miami-Dade County, Florida, as legally described and depicted in the Easement Agreement and generally lying on the opposite sides of the Easement Parcel (the "Developer Property'), as depicted in Exhibit B. C. Developer plans to install certain improvements within the Easement Parcel, such as underground parking and driveway facilities (the "Improvements"), further depicted in the Easement Agreement. D. The Improvements will facilitate the provision of needed off-street parking in the City. E. The City agrees to grant to Developer the Easement Agreement pursuant to the terms set forth herein and agrees that such Easement shall run with the land. TERMS AND CONDITI®NS: A. Grant of Easement. In consideration of the items proffered below by the Developer, the City agrees to grant the Easement Agreement to the Developer. B. Beachwalk. In consideration of the Easement Agreement, the Developer agrees to contribute certain funding, as provided herein, for the improvement of a new public beach walk between 32nd Street and 36th Street, excluding behind the Versailles property(the "Beachwalk"). 1. Hard Costs. The Developer will pay up to $1,100 per linear foot for the entire length of the Beachwalk between 32nd Street and 36th Street, excluding behind the Versailles Property ("Hard Costs"); however, in no event will the Developer pay more than $900,000 (the "Developer's Maximum Contribution") for Hard Costs. The City will fund the difference between the Developer's Maximum {25404946;31 Exhibit D Contribution and the overall cost of the Beachwalk. The Beachwalk shall be an at-grade Beachwalk, similar to the at-grade Beachwalk south of 22nd Street. 2. Soft Costs. The Developer will pay for soft costs (estimated to be valued at approximately $400,000), including permitting, and fees for architects, engineers, construction management and other professional labor, associated with portions of the Beachwalk located between 32nd Street to 34th Street, and 35th Street to 36th Street. Soft Costs shall not be considered in the calculation of the Developer's Maximum Contribution. C. Infrastructure. The Developer will implement appropriate modifications to utility infrastructure within and outside of to the Easement Area, such as new water, sewer and stormwater lines, reinforced concrete slabs above utilities with less than 36" cover and other agreed-upon modifications requested by the Public Works Department. The Developer will also re-route all utilities such as water, sewer, FPL, AT&T and Atlantic Broadband in the Easement Area at its own expense. The estimated value of the hard and soft costs associated with the utility relocation work is approximately$1,725,000. D. Permit Fee Credit. The Developer will not cancel its existing hotel master permit for the Project, and therefore will not seek a credit for fees associated with a new master hotel permit. The estimated value of this credit is approximately$700,000. E. Removal of On-Street Parking Spaces Adjacent to Developer Property. In order to provide vehicular access to the Developer Property and its associated off-street parking facilities and to improve pedestrian safety and convenience, the Developer must remove seven (7) on-street, metered parking spaces that are adjacent to the Developer Property. These seven (7) spaces are shown in red on Exhibit C. The Developer agrees to pay for the removal of these seven(7) on-street spaces as follows: the Developer will pay$7,000 per space per year for five (5) years so that a total of$35,000 per space is paid in total. The first payment is due prior to the issuance of a building permit for the Atlantic Hotels project on the Developer Property. The City, at its own cost and expense, will remove five (5) on-street spaces adjacent to the Developer Property, shown in blue on Exhibit C. Because these five spaces improve the pedestrian environment pursuant to policies of the Comprehensive Plan, the City will not charge the Developer for the removal of these five(5) spaces. F. Temporary Use of 32nd Street. The Developer will receive the use of seven (7) on-street parking spaces on 32nd Street, east of Collins Avenue, during the period when the sales center for the Saxony Condominium project is operational. The use of these seven spaces shall be at no cost to the Developer. (25404946;3) Exhibit D EXHIBIT A STOMER&ASSOCIATES,IMC. SURVEYORS-MAPPERS 4341 S.W. 62nd AVE, r Tel. (954) 565-0997 Fbrfdm Lcenscx!Surrsy Uavia, Florida 33314 and A ng 8;s rn=h 6693 Faa (954) 5.85-3927 • r � SKETCH OF DIESCAIFTIOM OF: A PARCEL OF LAND LYING IN SECTION 26, TOWNSHIP 53 SOUTH,RANGE 42 EAST C17Y OF MIAMI BEACH, MIAMI-DADE COUNTY, FLORIDA aATNUR C D £Y RV. 5- TMS SKETCH .I1(th St 4 Q f V �d St, y SCALE t" = 40' ° Q a J"nd a to ao 40 e9 GRAPHIC SCALE LEGEND: VICINITY MAP P.8_............ PLAT&O(Jx p:of ro=Fj PG. ............ .NACr' u—D.C.R........ .miAMi—OAOc COUNTY RECORDS P.ac.-......... .PamT 019'COMUENCcv3uT Nar_: P.O 8........_....Fawr OF a—EMMYG SEE SHEET 1 FOR THE LEGAL D:SCRiPTION OF (P ........... .PER PLAT THE SI(Mi GRAROCALLY SH-VN HEREON. (►Ri .......PER R=CVS R/W............ RnHT-Cr-WAY ...............CEIJTE►tuv� B;_OK 22 A�4 7F,f &-4& MAP OF OZAN rgaV7 oc P...=Rrr kIA.V.i BEA 7'y� COI' 17 Chi'Up Z P S PC 1 p8MN 0> � O.CR. LOT 10 C.) �P sovr,i u, Ccwv- a ! r"P;cxr or or for�o m p or WAY uv£ too°P�o et ocx 2 2 j Y N 07'.31'S7° S 82.35 19 E 2 4 o�J ` '�� 16 22' £ 89.77 3 'r 'Ca Al 1'P57 3�q�'-F.� -14 gh S T ^- w Q scuwet R%cNr N 07 45• b �0rh R£f�' -._ '�o (Qyr '.31'57 so' .>T �+°i �- C o 6.42 E WAY�ANaI �o`�Q Q OF 82�8 02 w 8� O n, C Z ;.oT TO ,aa t'v '3.32 8L4GiC 20 NOCW7pI uyL J ev" Q LOT 70 AArZrJDf-p'ra tar Y P.0.C. z U TxF oc�n, rR r 0, coR)vD? C� r RROP�Rrr LOT 7 OF Lor 2 I :I/AAf! 3F'ACn!A Pr?Q�r ENT 44 w i OCk?0 � p'B 5. PG. 7 d M_ Cou?ANY > cn tog s4 S+cEIt;FI N0. SHEET 2 CF 2 I-7735 UGE r nr n � - • ';t+m ;trro �rtr�nv' -i.am Ran - .. t on Li��� {25404946;3} `o Sx :.•_ .s,"'�j.' 'as ,;;s'`.,kaaa a"'Es-a_W PIK Wy vq � s .-•"'�a�� .�x��. i s �r��� �' �� �€2 �y. �� sus "'S'Gy �� q wro7 �aypp Xf'O_ >i... .. "Ewa um :tre y t c j v ..% :m..'I rah. 'e 4�`,3�;�•"1Y��• �. ,� fib: I� I Exhibit D EXHIBIT C } I x F� 1 N I f FEE t, a ' 1 ✓' V, 11 y 1 i s � / . � �•4 .fie ^ 'T' c jv s` y; pper'. '!� �i, g •; `` ✓ -1.^`'r,t' .Y,i". ; �`{•( �, �..�.L.:..r. Y' -t- s e r �.77 77 r t ;� ` r . r.-x� -�� s..a:.a ♦ 1w.t,.,a� s �c3� s �" h 1 (� t 3. 1 � i-, -. li re n.�.e i,... ro< � ... �6(„/rry wi':4,y � °'_ ♦ _ (- [r ? ,. a Ltf s r r '��� •; p..,,.. '. av-r i' ."`J w ..:�.ss, {25404946;3}