Loading...
ITB 60-2013TC Sunset Harbour Pump Stations Pad INVITATION TO BID Sunset Harbour Pump Stations Retrofit and Drainage Improvements ITB No. 60-2013TC BID ISSUANCE DATE: MARCH 8, 2013 BID OPENING: APRIL 8, 2013 AT 3 P.M. Theo Carrasco, Ph.D., CPPO, CPPB, Senior Procurement Specialist PROCUREMENT DIVISION 1700 Convention Center Drive, Miami Beach, FL 33139 www.miamibeachfl.gov MIAWBEACH COMMISSION ITEM SUMMARY Condensed Title: Request for Approval to Award a Contract Pursuant to Invitation to Bid (ITB) No. 060-2013TC, for the Sunset Harbour Pump Stations Retrofit and Drainage Improvements; Authorizing the Mayor and City Clerk to Execute an Agreement with Lanzo Construction Co., Florida; in the Amount of $1,854,963.40 for the Construction of the Project, Plus Approve a Project Contingency of 10% for a Not-to-Exceed Grand Total of$2,040,459.74; Further Authorizing the Administration to Engage in Value Engineering to Further Reduce the Cost and Time for Completion of Said Protect. Key Intended Outcome Supported: Ensure well-maintained facilities Supporting Data (Surveys, Environmental Scan, etc.): The 2009 Customer Satisfaction Survey indicated that 79% of businesses rated recently completed capital improvement projects as "excellent" or"good." Issue: Shall the City Commission award the contract? Item Summa /Recommendation: This project will provide upgrades to three (3) existing storm water pump stations in the Sunset Harbour neighborhood to improve an inadequate existing storm water drainage system. The upgraded system will provide a greater level of stormwater service for the community and reduce the likelihood of future flooding events. The scope of services consists of replacing the existing pump station located at 20th Street and West Avenue with a new pump station, adding four (4) new injection drainage wells, constructing a new gravity storm sewer system, and connecting it to the existing drainage system. An alternate was also provided to replace the existing pumps and hardware for pump stations #1 and #2 located adjacent to Purdy Avenue. Invitation to Bid (ITB) 060-2013TC was issued on March 8, 2013, with an opening date of April 23, 2013. The pre-bid conference was held on March 20, 2013. The Public Group and Bidnet issued bid notices to 58 and 271 prospective bidders respectively of which a total of 29 accessed the advertised solicitation respectively. In addition, 77 vendors were notified via email, which resulted in the receipt of four(4)bids from: David Mancini & Sons; Lanzo Construction Co., Florida; Metro Equipment Service, Inc.; and, ManCon, Inc. After review of the bids received for responsiveness, staff determined, after consulting with the City Attorney's Office, that David Mancini & Sons, Inc., the lowest bidder at $1,535,481.03, was nonresponsive for failing to provide sufficient proof of project experience to meet the minimum requirements of the ITB. Accordingly, staff recommends that Lanzo Construction Co, Florida, the overall second-lowest bidder at$1,854,963.40, be considered for award. After considering the review and recommendation of City staff, the City Manager exercised his due diligence and carefully considered the specifics of this ITB process and recommends to the Mayor and City Commission to award the construction contract to Lanzo Construction Co., Florida and authorize the Administration to engage in value engineering to further reduce the cost and time for completion of said project. Advisory Board Recommendation: N/A Financial Information: Source of Amount Account Funds: 1 $1,974,840.00 427-2300-069357—Sunset Harbour Pump Station Upgrades 2 $6561974 431-2730-069357—Drainage Hots pots _ _.,.Total .$2,Q40,459.74,. Financial impact Summary: N/A City Clerk's Office Legislative Tracking: Jay Fink, ext. 6319 Sign-Offs: DepiWent Director As ' er J AD MT KGB JLM T:IAGENDA\2013\May BUM 060-2013TC—Sunset Harbour POMIrStations Impr ments—Summary.doc AGENDA ITEIN MIAMIBEACH DATE 311 MIAMI BEACH City of Miami Beach, 1700 Convention Center Drive,Miami Beach, Florida 33139,www.miamibeochfl.gov COMMISSION MEMORANDUM TO: Mayor Matti Herrera Bower and Me bers of a City Commission FROM: Jimmy L. Morales, City Manager DATE: May 8, 2013 SUBJECT: REQUEST FOR APPROVAL TO AWARD A CONTRACT, PURSUANT TO INVITATION TO BID NO. 060-2013TC, FOR THE SUNSET HARBOUR PUMP STATIONS RETROFIT AND DRAINAGE IMPROVEMENTS; AUTHORIZING THE MAYOR AND CITY CLERK TO EXECUTE AN AGREEMENT WITH LANZO CONSTRUCTION CO., FLORIDA; IN THE AMOUNT OF $1,854,963.40 FOR THE CONSTRUCTION OF THE PROJECT, PLUS APPROVE A PROJECT CONTINGENCY OF 10% FOR A NOT-TO-EXCEED GRAND TOTAL OF $2,040,459.74; FURTHER AUTHORIZING THE ADMINISTRATION TO ENGAGE IN VALUE ENGINEERING TO FURTHER REDUCE THE COST AND TIME FOR COMPLETION OF SAID PROJECT. ADMINISTRATION RECOMMENDATION Approve the award of contract. KEY INTENDED OUTCOME SUPPORTED Ensure well maintained facilities and ensure quality and timely delivery of capital projects. FUNDING $1,974,840.00 427-2300-069357 - Sunset Harbour Pump Station Upgrades $65,619.74 431-2730-069357- Drainage Hotspots $2,040,459.74 Total BACKGROUND This project will provide upgrades to three (3) existing storm water pump stations in the Sunset Harbour neighborhood to improve an inadequate existing storm water drainage system. The upgraded system will provide a greater level of stormwater service for the community and reduce the likelihood of future flooding events. SCOPE OF SERVICES The scope of services consists of replacing the existing pump station located at 20th Street and West Avenue with is new pump station; adding four '(4)- new injection -drainage wells, constructing a new gravity storm sewer system, and connecting it to the existing drainage system. An alternate was also provided to replace the existing pumps and hardware for pump stations#1 and #2 located adjacent to Purdy Avenue. ITB PROCESS Invitation to Bid (ITB) 060-2013TC was issued on March 8, 2013, with an opening date of April 312 Commission Memorandum—ITB 060-2013TC—Sunset Harbour Pump Stations Retrofit May 8, 2013 Page 2 23, 2013. The pre-bid conference was held on March 20, 2013. The Public Group and Bidnet issued bid notices to 58 and 271 prospective bidders respectively of which 24 and 5 accessed the advertised solicitation respectively. In addition, 77 vendors were notified via email. Bids were received from: • David Mancini & Sons, Inc. • Lanzo Construction Co. Florida • Man Con, Inc. • Metro Equipment Service, Inc. David Mancini & Sons, Inc., and ManCon, Inc., the lowest and highest bidders at $1,535,481.03 and $2,242,607 respectively, were deemed nonresponsive for failing to provide sufficient proof of project experience to meet the minimum requirements of the ITB. Also, Metro Equipment Service, Inc., the third-highest bidder at $1,963,000, was deemed nonresponsive for failing to submit omitted information that was requested by the Procurement Division. As a result, Lanzo Construction Co, Florida, the second-lowest bidder at $1,854,963.40, a responsive and responsible bidder, is recommended for award. CITY MANAGER'S DUE DILIGENCE After considering the review and recommendation of City staff, the City Manager exercised his due diligence and carefully considered the specifics of this ITB process and recommends to the Mayor and City Commission to award the construction contract to Lanzo Construction Co., Florida and authorize the Administration to engage in value engineering to further reduce the cost and time for completion of said project. CONCLUSION The Administration recommends the award of the contract to Lanzo Construction Co., Florida, pursuant to Invitation to Bid (ITB) 060-2013TC, for the Sunset Harbour pump stations retrofit and drainage improvements, in the amount of $1,854,963.40; plus approve a project contingency of 10% for a not-to-exceed grand total of $2,040,459.74; further authorizing the Administration to engage in value engineering to further reduce the cost and time for completion of said project. JLM/KGWO JAD 313 00600. CONTRACT: CONTRACT THIS IS A CONTRACT, by and between the City of Miami Beach, a political subdivision of the State of Florida, hereinafter referred to as City, and LANZO CONSTRUCTION CO., FLORIDA, hereinafter referred to as Contractor. W I T N E S S E T H, that Contractor and City, for the considerations hereinafter named, agree as follows: ARTICLE 1 SCOPE OF WORK Contractor hereby agrees to furnish all of the labor, materials, equipment services and incidentals necessary to perform all of the work described in the Contract Documents and related thereto for the Project. ARTICLE 2 CONTRACT TIME 2.1 Contractor shall be instructed to commence the Work by written instructions in the form of a Standing Order issued by the City's Procurement Director and a Notice to Proceed issued by the Contract Administrator. Two (2) Notices to Proceed will be issued for this Contract. Contractor shall commence scheduling activities, permit applications and other preconstruction work within five (5) calendar days after the Project Initiation Date, which shall be the same as the date of the first Notice to Proceed. The first Notice to Proceed and Purchase Order will not be issued until Contractor's submission to City of all required documents (including but limited to: Payment and Performance Bonds, and Insurance Certificate) and after execution of the Contract by both parties. 2.1.1. The receipt of all necessary permits by Contractor and acceptance of the full progress schedule in accordance with technical specifications section, submittal schedule and schedule of values is a condition precedent to the issuance of a second Notice to Proceed to mobilize on the Project site and commence with physical construction of the work. The Contractor shall submit all necessary documents required by this provision within twenty-one (21) calendar days of the issuance of the first Notice to Proceed. 2.2 Time is of the essence throughout this Contract. This project shall be substantially completed within one hundred and eighty (180) calendar days from the issuance of the second Notice to Proceed, and completed and ready for final payment in accordance with Article 5 within thirty (30) calendar days from the date certified by Consultant as the date of Substantial Completion. CITYOF MIAMI BEACH BID No: 60-2013TC 67 DATE:April 8, 2013 2.3 Upon failure of Contractor to substantially complete the Contract within the specified period of time, plus approved time extensions, Contractor shall pay to City the sum of one thousand four hundred dollars ($1,400.00) for each calendar day after the time specified in Section 2.2 above, plus any approved time extensions, for Substantial Completion. After Substantial Completion should Contractor fail to complete the remaining work within the time specified in Section 2.2 above, plus approved time extensions thereof, for completion and readiness for final payment, Contractor shall pay to City the sum of one thousand four hundred dollars ($1,400.00) for each calendar day after the time specified in Section 2.2 above, plus any approved extensions, for completion and readiness for final payment. These amounts are not penalties but are liquidated damages to City for its inability to obtain full beneficial occupancy and/or use of the Project. Liquidated damages are hereby fixed and agreed upon between the parties, recognizing the impossibility of precisely ascertaining the amount of damages that will be sustained by City as a consequence of such delay, and both parties desiring to obviate any question of dispute concerning the amount of said damages and the cost and effect of the failure of Contractor to complete the Contract on time. The above-stated liquidated damages shall apply separately to each portion of the Project for which a time for completion is given. 2.4 City is authorized to deduct liquidated damages from monies due to Contractor for the Work under this Contract or as much thereof as City may, in its sole discretion, deem just and reasonable. 2.5 Contractor shall be responsible for reimbursing City, in addition to liquidated damages, for all costs incurred by Consultant in administering the construction of the Project beyond the completion date specified above, plus approved time extensions. Consultant construction administration costs shall be pursuant to the contract between City and Consultant, a copy of which is available upon request of the Contract Administrator. All such costs shall be deducted from the monies due Contractor for performance of Work under this Contract by means of unilateral credit change orders issued by City as costs are incurred by Consultant and agreed to by City. ARTICLE 3 THE CONTRACT SUM [X] This is a Unit Price Contract:* 3.1 City shall pay to Contractor the amounts determined for the total number of each of the units of work completed at the unit price stated in the schedule of prices bid. The number of units contained in this schedule is an estimate only, and final payment shall be made for the actual number of units incorporated in or made necessary by the Work covered by the Contract Documents. 3.2 Payment shall be made at the unit prices applicable to each integral part of the Work. These prices shall be full compensation for all costs, including overhead and profit, associated with completion of all the Work in full conformity with the requirements as stated or shown, or both, in the Contract Documents. The cost of any item of work not covered by a definite Contract unit price shall be included in the Contract unit price or lump sum price to which the item is most applicable. CITYOF MIAMI BEACH BID No: 60-2013TC 68 DATE: April 8, 2013 [ ] This is a Lump Sum Contract:* 3.1 City shall pay to Contractor for the performance of the Work described in the Contract Documents, the total price stated as awarded. 3.2 Payment shall be at the lump sum price stated in the Contract. This price shall be full compensation for all costs, including overhead and profit, associated with completion of all the work in full conformity with the requirements as stated or shown, or both, in the Contract Documents. The cost of any item of work not covered by a definite Contract lump sum should be included in the lump sum price to which the item is most applicable. *Note: Some projects include both unit prices and lump sums in which case both sections shall apply to the Work identified for each type of Contract. ARTICLE 4 PROGRESS PAYMENTS 4.1 Contractor may make Application for Payment for work completed during the Project at intervals of not more than once a month. Contractor's application shall show a complete breakdown of the Project components, the quantities completed and the amount due, together with such supporting evidence as may be required by Consultant. Contractor shall include, but same shall be limited to, at Consultant's discretion, with each Application for Payment, an updated progress schedule acceptable to Consultant as required by the Contract Documents and a release of liens and consent of surety relative to the work which is the subject of the Application. Each Application for Payment shall be submitted in triplicate to Consultant for approval. City shall make payment to Contractor within thirty (30) days after approval by Consultant of Contractor's Application for Payment and submission of an acceptable updated progress schedule. 4.2 Ten percent (10%) of all monies earned by Contractor shall be retained by City until Final Completion and acceptance by City in accordance with Article 5 hereof, except that after ninety percent (90%) of the Work has been completed, the Contract Administrator may reduce the retainage to five percent (5%) of all monies previously earned and all monies earned thereafter. Any reduction in retainage shall be in the sole discretion of the Contract Administrator, shall be recommended by Consultant and Contractor shall have no entitlement to a reduction. Any interest earned on retainage shall accrue to the benefit of City. All requests for retainage reduction shall be in writing in a separate stand alone document. 4.3 City may withhold, in whole or in part, payment to such extent as may be necessary to protect itself from loss on account of: 4.3.1 Defective work not remedied. 4.3.2 Claims filed or reasonable evidence indicating probable filing of claims by other parties against Contractor or City because of Contractor's performance. 4.3.3 Failure of Contractor to make payments properly to Subcontractors or for material or labor. CITYOF MIAMI BEACH BID No: 60-2013TC 69 DATE:April 8, 2013 4.3.4 Damage to another contractor not remedied. 4.3.5 Liquidated damages and costs incurred by Consultant for extended construction administration. 4.3.6 Failure of Contractor to provide any and all documents required by the Contract Documents. When the above grounds are removed or resolved satisfactory to the Contract Administrator, payment shall be made in whole or in part. ARTICLE 5 ACCEPTANCE AND FINAL PAYMENT 5.1 Upon receipt of written notice from Contractor that the Work is ready for final inspection and acceptance, Consultant shall, within ten (10) calendar days, make an inspection thereof. If Consultant and Contract Administrator find the Work acceptable, the requisite documents have been submitted and the requirements of the Contract Documents fully satisfied, and all conditions of the permits and regulatory agencies have been met, a Final Certificate of Payment (Form 00926) shall be issued by Consultant, over its signature, stating that the requirements of the Contract Documents have been performed and the Work is ready for acceptance under the terms and conditions thereof. 5.2 Before issuance of the Final Certificate for Payment, Contractor shall deliver to Consultant a complete release of all liens arising out of this Contract, receipts in full in lieu thereof; an affidavit certifying that all suppliers and subcontractors have been paid in full and that all other indebtedness connected with the Work has been paid, and a consent of the surety to final payment; the final corrected as-built drawings; and the final bill of materials, if required, and invoice. 5.3 If, after the Work has been substantially completed, full completion thereof is materially delayed through no fault of Contractor , and Consultant so certifies, City shall, upon certificate of Consultant, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims. 5.4 Final payment shall be made only after the City Manager or his designee has reviewed a written evaluation of the performance of Contractor prepared by the Contract Administrator, and approved the final payment. The acceptance of final payment shall constitute a waiver of all claims by Contractor, except those previously made in strict accordance with the provisions of the General Conditions and identified by Contractor as unsettled at the time of the application for final payment. CITYOF MIAMI BEACH BID No:60-2013TC 70 DATE:April 8, 2013 ARTICLE 6 MISCELLANEOUS 6.1 This Contract is part of, and incorporated in, the Contract Documents as defined herein. Accordingly, all of the documents incorporated by the Contract Documents shall govern this Project. 6.2 Where there is a conflict between any provision set forth within the Contract Documents and a more stringent state or federal provision which is applicable to this Project, the more stringent state or federal provision shall prevail. 6.3 Public Entity Crimes In accordance with the Public Crimes Act, Section 287.133, Florida Statutes, a person or affiliate who is a contractor, consultant or other provider, who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to the City, may not submit a bid on a contract with the City for the construction or repair of a public building or public work, may not submit bids on leases of real property to the City, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with the City, and may not transact any business with the City in excess of the threshold amount provided in Section 287.017, Florida Statutes, for category two purchases for a period of 36 months from the date of being placed on the convicted vendor list. Violation of this section by Contractor shall result in cancellation of the City purchase and may result in Contractor debarment. 6.4 Independent Contractor Contractor is an independent contractor under this Contract. Services provided by Contractor pursuant to this Contract shall be subject to the supervision of Contractor. In providing such services, neither Contractor nor its agents shall act as officers, employees, or agents of the City. This Contract shall not constitute or make the parties a partnership or joint venture. 6.5 Third Party Beneficiaries Neither Contractor nor City intends to directly or substantially benefit a third party by this Contract. Therefore, the parties agree that there are no third party beneficiaries to this Contract and that no third party shall be entitled to assert a claim against either of them based upon this Contract. The parties expressly acknowledge that it is not their intent to create any rights or obligations in any third person or entity under this Contract. CITYOF MIAMI BEACH BID No: 60-2013TC 71 DATE:April 8, 2013 6.6 Notices Whenever either party desires to give notice to the other, such notice must be in writing, sent by certified United States Mail, postage prepaid, return receipt requested, or by hand-delivery with a request for a written receipt of acknowledgment of delivery, addressed to the party for whom it is intended at the place last specified. The place for giving notice shall remain the same as set forth herein until changed in writing in the manner provided in this section. For the present, the parties designate the following: Procurement Division 1700 Convention Center Drive Miami Beach, Florida 33139 Attn: Alex Denis, Procurement Director With copies to: City Attorney City of Miami Beach 1700 Convention Center Drive Miami Beach, Florida 33139 For Contractor: Lanzo Construction Co. Florida 15—ST E_. 5 Court Deerfield Beach, Florida 33441 Attn: Michael Bone, Vice President Phone: 954-973-9700 Fax: 954-974-3894 E-mail: michaelbAllanzo.org 6.7 Assignment and Performance Neither this Contract nor any interest herein shall be assigned, transferred, or encumbered by either party. In addition, Contractor shall not subcontract any portion of the work required by this Contract except as authorized by Section 27 of the General Conditions. Contractor represents that all persons delivering the services required by this Contract have the knowledge and skills, either by training, experience, education, or a combination thereof, to adequately and competently perform the duties, obligations, and services set forth in the Scope of Work and to provide and perform such services to City's satisfaction for the agreed compensation. Contractor shall perform its duties, obligations, and services under this Contract in a skillful and respectable manner. The quality of Contractor's performance and all interim and final product(s) provided to or on behalf of City shall be comparable to the best local and national standards. CITYOF MIAMI BEACH BID No: 60-2013TC 72 DATE:April 8, 2013 6.8 Materiality and Waiver of Breach City and Contractor agree that each requirement, duty, and obligation set forth in these Contract Documents is substantial and important to the formation of this Contract and, therefore, is a material term hereof. City's failure to enforce any provision of this Contract shall not be deemed a waiver of such provision or modification of this Contract. A waiver of any breach of a provision of this Contract shall not be deemed a waiver of any subsequent breach and shall not be construed to be a modification of the terms of this Contract. 6.9 Severance In the event a portion of this Contract is found by a court of competent jurisdiction to be invalid, the remaining provisions shall continue to be effective unless City or Contractor elects to terminate this Contract. An election to terminate this Contract based upon this provision shall be made within seven (7) days after the finding by the court becomes final. 6.10 Applicable Law and Venue This Contract shall be enforceable in Miami-Dade County, Florida, and if legal action is necessary by either party with respect to the enforcement of any or all of the terms or conditions herein exclusive venue for the enforcement of same shall lie in Miami-Dade County, Florida. By entering into this Contract, Contractor and City hereby expressly waive any rights either party may have to a trial by jury of any civil litigation related to, or arising out of the Project. Contractor shall specifically bind all subcontractors to the provisions of this Contract. 6.11 Amendments No modification, amendment, or alteration in the terms or conditions contained herein shall be effective unless contained in a written document prepared with the same or similar formality as this Contract and executed by the Board and Contractor. 6.12 Prior Agreements This document incorporates and includes all prior negotiations, correspondence, conversations, agreements, and understandings applicable to the matters contained herein and the parties agree that there are no commitments, agreements or understandings concerning the subject matter of this Contract that are not contained in this document. Accordingly, the parties agree that no deviation from the terms hereof shall be predicated upon any prior representations or agreements, whether oral or written. It is further agreed that no modification, amendment or alteration in the terms or conditions contained herein shall be effective unless set forth in writing in accordance with Section 6.11 above. CITYOF MIAMI BEACH BID No:60-2013TC 73 DATE: April 8, 2013 IN WITNESS WHERE rties have set their hands and seals the day and year first above written. r`1 B� ATTEST: CITY OF MIA BEACH &Wed Ci y Clerk INCORP ORATE : a r Contractor MUST UTE IS..` RACT AS INDICATED BELOW. USE CORPORATION OR N RMAT, AS APPLICABLE. [If incorporated sign below.] Contractor ATTEST: pZD GNSI✓u C, 04 CD.� (Name of Corporation) By: /Y (Secretary) (Signature) c lit a l 416?0✓J e1 y� (Corporate Seal) (Print Name and Title) fit day of t `/ 20 1 3 [If not incorporated sign below.] Contractor WITNESSES: (Name of Firm) By: (Signature) (Print Name and Title) day of , 20 CITY REQUIRES FOUR (4) FULLY-EXECUTED CONTRA WWN ION. & FOR EX UTION City a ate CITYOF MIAMI BEACH BID No: 60-2013TC 74 DATE:April 8, 2013 00708. FORM CERTIFICATE OF INSURANCE A certificate of insurance form will be attached here. BID No: 60-2013TC CITYOF MIAMI BEACH DATE:April 8,2013 75 '4c® CERTIFICATE OF LIABILITY INSURANCE DATE(MMIDD/YWY) 6/3/2013 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: Donna Griffiths Guy Hurley Blaster and Heuer, LLC PHONE (298)519-1439 AIC No: (248)519-1401 1080 Kirts Blvd. , Suite 500 E-MAIL d riffiths@ hb.com ADDRESS: g g INSURERS AFFORDING COVERAGE NAIC 4 Troy MI 48084 INSURER AAmerisure Insurance Company 19488 INSURED INSURER B Amerisure Mutual Ins. Co. 23396 Lanzo Construction Co. , Florida INSURER C: 1 Stainless Plaza INSURER D: 125 S.E. 5th Court INSURER E Deerfield Beach FL 33441 INSURER F: COVERAGES CERTIFICATE NUMBER:12-13 Master REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR I TYPE OF INSURANCE A S BR POLICY EFF POLICY EXP LTR IN SR WVD POLICY NUMBER MM/OD/YYYY MMIOD/YYYY LIMITS - GENERAL-LIABILITY- - -— -- - --- - - EACH OCCURRENCE $ 1,0 0,000 -- DAMAGE TO RENTED X COMMERCIAL GENERAL LIABILITY PREMISES Ea occurrence $ 100,000 A CLAIMS-MADE Fx] OCCUR X CPP2079089 9/30/2012 9/30/2013 MED EXP(Any one person) $ 5,000 X XCU Coverage Incl PERSONAL 8 ADV INJURY S 1,000,000 GENERAL AGGREGATE $ 2,000,000 GENT AGGREGATE LIMIT APPLIES PER PRODUCTS-COMP/OP AGG $ 2,000,000 JFCI X POLICY X PRO LOC $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT Ea accident $ 1,000,000 A X ANY AUTO BODILY INJURY(Per person) $ X ALL OWNED EX SCHEDULED A2079088 9/30/2012 9/30/2013 BODILY INJURY(Per accident) $ AUTOS AUTOS X HIRED AUTOS NON-OWNED PROPERTY DAMAGE $ AUTOS Per accident Underinsured motorist S X UMBRELLA LIAR OCCUR EACH OCCURRENCE $ 5,000,000 B EXCESS LIAB HCLAIMS-MADE AGGREGATE $ 5,000,000 DED X RETENTIONS 0 CU2079090 9/30/2012 9/30/2013 $ WORKERS COMPENSATION I WC STATU- ITH- AND EMPLOYERS'LIABILITY YIN I I I ER ANY PROPRIETORIPARTNER/EXECUTIVE❑ OFFICER/MEMBER EXCLUDED? NIA E.L.EACH ACCIDENT $ (Mandatory in NH) E.L.DISEASE-EA EMPLOYE $ If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ A Inland Marine CPP2079089 9/30/2012 9/30/2013 Leased/Rented Equipment $250,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (Attach ACORD 101,Additional Remarks Schedule,if more space is required) Project: P011, Invitation to Bid (ITB) No. 2013-060-TC, Sunset Harbour Pump Stations Retrofit and Drainage Improvements. The City of Miami Beach is an Additional Insured for General Liability when required by written contract. Installation Coverage, $3,000,000. Blanket Limit, Policy #CPP2079089, Effective 09/30/2012-09/30/13. CERTIFICATE HOLDER CANCELLATION (786) 3 94-4010 kpatterson @miamibeachfl.go SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of Miami Beach ACCORDANCE WITH THE POLICY PROVISIONS. Risk Management 1700 Convention Center Drive AUTHORIZED REPRESENTATIVE Miami Beach, FL 33139 Paul Hurley/CSMITH ACORD 25(2010/05) ©1988-2010 ACORD CORPORATION. All rights reserved. INS025omnnstni Tho Ar r)pn nnmc anti Innn nrn rcnicfnrnrl mnrlrc of annDn �-� LANZO-1 OP ID: DC ,d►corzn° CERTIFICATE OF LIABILITY INSURANCE DATE(MMIDDIYYYY) `16* � 1 06/03/2013 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). CONTACT PRODUCER Phone: 561-392-3300 NAME: Greg Carignan Workers Compensation Group PHONE FAx P O Box 410 Fax: 561-361-1132 CAC.No xt E :561-392-3300 A/c No: 561-361-1132 Boca Raton, FL 33429-0410 E-MAIL William F.Comiskey ADDRESS,certs@workerscompgroup.com INSURER(S)AFFORDING COVERAGE NAIC p INSURER A:Bridgefield Employers Ins 110701 INSURED Lanzo Construction Co. FL INSURER B 125 S.E. 5th Court Deerfield Beach, FL 33441 INSURER C INSURER D INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR I DOL BR POLICY EFF POLICY EXP LIMITS LTR TYPE OF INSURANCE POLICY NUMBER MMIDDIYYYY MMIDD/YYYY GENERAL LIABILITY -- - - — - - - - --- - - - _ -EACH OCCURRENCE - $ - -- AMA COMMERCIAL GENERAL LIABILITY PREMISES Ea occurrence $ CLAIMS-MADE El OCCUR MED EXP(Any one person) $ PERSONAL 8 ADV INJURY $ GENERAL AGGREGATE $ GENT AGGREGATE LIMIT APPLIES PER PRODUCTS-COMP/OP AGG $ n POLICY n PRO- LOC $JECT A COMBINED SINGLE LIMIT AUTOMOBILE LIABILITY Ea accident $ ANY AUTO BODILY INJURY(Per person) $ ALL OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS AUTOS NON-OWNED PROPERTY DAMAGE $ HIRED AUTOS AUTOS Per accident $ I UMBRELLA LIAB I EACH OCCURRENCE $ EXCESS LIAR AGGREGATE $ DED I I RETENTION$ $ WORKERS COMPENSATION X WC STATU- OTH- AND EMPLOYERS'LIABILITY TORY LIMITS ER A ANY PROPRIETOR/PARTNERIEXECUTIVEY/N 830-24200 01/01/2013 01/01/2014 E.L.EACH ACCIDENT $ 1,000,000 OFFICERIMEMBER EXCLUDED? NIA (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ 1,000,00 If yes.describe under DESCRIPTION OF OPERATIONS below DISEASE-POLICY LIMIT $ 1,000,000 I DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (Attach ACORD 101,Additional Remarks Schedule,If more space is required) Lanzo Job P011, Invitation to Bid (ITB) No.2013-060-TC, Sunset Harbour Pump Stations Retrofit and Drainage Improvements. � �n **30 Days notice of cancellation, 10 days for Non-Payment of premium CERTIFICATE HOLDER CANCELLATION MIAMIBE SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE City of Miami Beach THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Y ACCORDANCE WITH THE POLICY PROVISIONS. Attn: Risk Management 1700 Convention Center Dr. Miami Beach, FL 33139 AUTHORIZED REPRESENTATIVE I ©1988-2010 ACORD CORPORATION. All rights reserved. ACORD 25(2010/05) The ACORD name and logo are registered marks of ACORD