Loading...
Agreement with Edward Lewis Architects, Inc. 0.0(c-01q0(ei AGREEMENT BETWEEN CITY OF MIAMI BEACH AND EDWARD LEWIS ARCHITECTS, INC. FOR PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" PURSUANT TO REQUEST FOR QUALIFICATIONS NO. 2014-346-YG DISCIPLINE: INTERIOR DESIGN AND SPACE PLANNING ARCHITECTURE RESOLUTION NO. 2015-29068 1 TABLE OF CONTENTS DESCRIPTION PAGE ARTICLE 1. DEFINITIONS 4 ARTICLE 2. BASIC SERVICES 9 ARTICLE 3. THE CITY'S RESPONSIBILITIES 14 ARTICLE 4. RESPONSIBILITY FOR CONSTRUCTION COST 16 ARTICLE 5. ADDITIONAL SERVICES 18 ARTICLE 6. REIMBURSABLE EXPENSES 19 ARTICLE 7. COMPENSATION FOR SERVICES 20 ARTICLE 8. CONSULTANT'S ACCOUNTING AND OTHER RECORDS 21 ARTICLE 9. OWNERSHIP OF PROJECT DOCUMENTS 21 ARTICLE 10. TERMINATION OF AGREEMENT 22 ARTICLE 11. INSURANCE 23 ARTICLE 12. INDEMNIFICATION AND HOLD HARMLESS 24 ARTICLE 13. ERRORS AND OMISSIONS 24 ARTICLE 14. LIMITATION OF LIABILITY 25 ARTICLE 15. NOTICE 25 ARTICLE 16. MISCELLANEOUS PROVISIONS 26 2 SCHEDULES: SCHEDULE A 29 SCHEDULE B 30 SCHEDULE C 32 ATTACHMENTS: ATTACHMENT A 33 ATTACHMENT B 34 ATTACHMENT C 35 3 AGREEMENT BETWEEN THE CITY OF MIAMI BEACH AND EDWARD LEWIS ARCHITECTS, INC. FOR PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" This Agreement made and entered into this 25 day of January , 2016 , (Effective Date), by and between the CITY OF MIAMI BEACH, a municipal corporation existing under the laws of the State of Florida, having its principal offices at 1700 Convention Center Drive, Miami Beach, Florida, 33139, (hereinafter referred to as City), and Edward Lewis Architects, Inc., a Florida corporation having its principal office at 2100 Ponce de Leon Boulevard, Suite 825, Coral Gables, FL 33134 (hereinafter referred to as Consultant). WITNESSETH: WHEREAS, on September 17, 2014, the Mayor and City Commission approved the issuance of Request for Qualifications No. 2014-346-YG for Professional Architectural and Engineering Services in Specialized Categories On An "As-Needed-Basis" (the RFQ); and WHEREAS, the RFQ was intended to provide access to architectural and engineering firms in accordance with the Florida Consultant's Competitive Negotiation Act; and WHEREAS, on July 8th, 2015, the City Commission approved Resolution No. 2015- i 29068, respectively, authorizing the City to enter into negotiations with Edward Lewis Architects, Inc. and, if successful, execute an agreement with the Consultant pursuant to the RFQ; and WHEREAS, City and the Consultant have negotiated the following agreement pursuant to the RFQ; and NOW THEREFORE, City and Consultant, in consideration of the mutual covenants and agreement herein contained, agree as follows: ARTICLE 1. DEFINITIONS 1.1 Definitions. The definitions included in this Section are not exhaustive of all definitions used in this Agreement. Additional terms may be defined in other Contract Documents. The following terms shall have the meanings specified herein unless otherwise stated herein: ADDITIONAL SERVICES: "Additional Services" shall mean those services, in addition to the Basic Services in this Agreement, as described in Article 5 and the Consultant Service Order, which the Consultant shall perform, at the City's option, and which must be duly authorized, in 4 writing, by the City Manager or his authorized designee, prior to commencement of same. APPLICABLE LAWS: "Applicable Laws" means all laws, statutes, codes (including, but not limited to, building codes), ordinances, rules, regulations, lawful orders and decrees of governmental authorities having jurisdiction over the Project, the Project Site or the Parties. BASE BID: "Base Bid" shall mean the elements contained in the Construction Documents recommended by the Consultant (and approved by the City) as being within the Construction Cost Budget. "Base Bid" shall not include additive alternates or deductive alternates. BASIC SERVICES: "Basic Services" shall include those services which Consultant shall perform in accordance with the terms of the Agreement, as described in Article 2 and the Consultant Service Order. Any Services not specifically enumerated as Additional Services (as defined herein) shall also be considered Basic Services. CITY (OR OWNER): The "City" shall mean the City of Miami Beach, a Florida municipal corporation having its principal offices at 1700 Convention Center Drive, Miami Beach, Florida, 33139. In all respects hereunder, City's obligations and performance is pursuant to City's position as the owner of the Project acting in its proprietary capacity. In the event City exercises its regulatory authority as a governmental body including, but not limited to, its regulatory authority for code inspections and issuance of Building Department permits, Public Works Department permits, or other applicable permits within its jurisdiction, the exercise of such regulatory authority and the enforcement of any Applicable Laws shall be deemed to have occurred pursuant to City's regulatory authority as a governmental body and shall not be attributable in any manner to City as a Party to this Agreement. CITY COMMISSION: "City Commission" shall mean the governing and legislative body of the City. CITY MANAGER: The "City Manager" shall mean the chief administrative officer of the City. The City Manager shall also be construed to include any duly authorized representatives designated by the City Manager in writing, including the Project Administrator, with respect to any specific matter(s) concerning the Services and/or this Agreement (exclusive of those authorizations reserved to the City Commission under this Agreement, or to regulatory or administrative bodies having jurisdiction over the Project). CONSTRUCTION COST BUDGET: The "Construction Cost Budget" shall mean the amount budgeted and established by the City to provide for the cost of construction of the Work for the Project ("Construction Cost"), as set forth in the Consultant Service Order. CONSTRUCTION DOCUMENTS: "Construction Documents" shall mean the final (100% completed) plans, technical specifications, drawings, schematics, documents, and diagrams prepared by the Consultant pursuant to this Agreement, setting forth in detail the requirements for the construction of the Project. The Construction Documents shall set forth in full all details necessary to complete the construction of the Project in accordance with the Contract Documents. Construction Documents shall not be part of the Contract Documents, until (a) the Consultant has submitted completed Construction Documents to the City and (b) they have been reviewed and approved by the City and any agencies having jurisdiction in accordance with the procedures as otherwise provided by the Contract Documents. However, approval by the City shall not in any way be construed, interpreted and/or deemed to constitute a waiver or excuse Consultant's obligations to ensure the Construction Documents are constructible, in 5 compliance with all Applicable Laws and in accordance with the Contract Documents. CONSULTANT: The named entity on page 1 of this Agreement, the "Consultant" shall mean the qualified and properly professionally licensed design professional in the State of Florida and as otherwise required by any entities, agencies, boards, governmental authorities and/or any other professional organizations with jurisdiction governing the professional practice area for which the design professional has been engaged by City and who will perform (or cause to be performed through Subconsultants acceptable to the City) all architectural, design and engineering services required under this Agreement and/or Consultant Service Order and will serve as the "architect of record" and/or "engineer of record" for the Project. When the term "Consultant" is used in this Agreement it shall also be deemed to include any officers, employees, or agents of Consultants, and any other person or entity acting under the supervision, direction, or control of Consultant to provide any architectural, design, engineering or similar professional services with respect to a Project ("Subconsultants"). The Consultant shall not be replaced by any other entity, except as otherwise permitted in this Agreement. Further, any Subconsultant that may perform services on behalf of the Consultant shall be a qualified and properly professionally licensed design professional in the State of Florida and as otherwise required by any entities, agencies, boards, governmental authorities and/or any other professional organizations with jurisdiction governing the professional practice area for which the Subconsultant has been engaged by Consultant to perform professional design services in connection with the Project. The Subconsultants in Schedule "C", attached hereto, are hereby approved by the City Manager for the Project. CONSULTANT SERVICE ORDER: Consultant Service Order shall mean the work order issued by the City to Consultant (in substantial form as in Schedule A attached hereto), that specifically describes and delineates the particular Services (Basic Services and/or Additional Services) which will be required of Consultant for the Project that is the subject of such Consultant Service Order, and which may include studies or study activity, and/or professional services as defined in Section 287.055 of the Florida Statutes. CONTRACT AMENDMENT: "Contract Amendment" shall mean a written modification to the Agreement approved by the City (as specified below) and executed between City and Consultant, covering changes, additions, or reductions in the terms of this Agreement including, without limitation, authorizing a change in the Project, or the method and manner of performance thereof, or an adjustment in the fee and/or completion dates. Contract Amendments shall be approved by the City Commission if they exceed fifty thousand dollars ($50,000.00). Even for Contract Amendments of fifty thousand dollars ($50,000.00) or less (or other such threshold contract amount as may be specified by the City of Miami Beach Procurement Ordinance), the City Manager reserves the right to seek and obtain concurrence of the City Commission for approval of any such Contract Amendment. CONTRACT DOCUMENTS: "Contract Documents" shall mean this Agreement (together with all exhibits, addenda, Consultant Service Orders and written amendments issued thereto), and all Design Documents and Construction Documents. The Contract Documents shall also include, without limitation (together with all exhibits, addenda, and written amendments issued thereto), the Invitation to Bid (ITB), instructions to bidders, bid form, bid bond, Design Criteria Package (if any), the Contract for Construction, surety payment and performance bonds, Conditions of the Contract for Construction (General, Supplementary, and other Conditions), Divisions 0-17 specifications, an approved Change Order(s), approved Construction Change Directive(s), and/or approved written order(s) for a minor change in the Work. 6 CONTRACT FOR CONSTRUCTION: "Contract for Construction" shall mean the legally binding agreement between City and Contractor for performance of the Work covered in the Contract Documents, including, without limitation, a general contractor, construction manager, design- builder or any other duly licensed construction contractor selected pursuant to any other procurement methodology available under Florida law. CONTRACTOR: "Contractor" shall mean the individual or individuals, firm, company, corporation, joint venture, or other entity contracting with City for performance of the Work covered in the Contract Documents. DESIGN CRITERIA PACKAGE or DCP: "Design Criteria Package" means concise, performance-oriented drawings or specifications of a design-build Project, prepared for the purpose of furnishing sufficient information to permit design-build firms to prepare a bid or a response to a City request for proposal, or to permit the City to enter into a negotiated design- build contract. The Design Criteria Package must specify performance-based criteria for the design-build Project, including the legal description of the site, survey information concerning the site, interior space requirements, material quality standards, schematic layouts and conceptual design criteria of the project, cost or budget estimates, design and construction schedules, site development requirements, provisions for utilities, stormwater retention and disposal, and parking requirements applicable to the project. DESIGN DOCUMENTS: "Design Documents" means all plans, drawings specifications, schematics and all other documents which set forth in full the design of the Project and fix and describe in detail the size, configuration and character of the Project concerning all items of the Project necessary for the final preparation of the 100% completed, permitted Construction Documents in accordance with the requirements of the Contract Documents including, without limitation, all architectural and engineering elements as may be appropriate. Design Documents shall not be part of the Contract Documents, until (a) the Consultant has submitted completed Design Documents to the City and (b) they have been reviewed and approved by the City and agencies having jurisdiction in accordance with the procedures as provided by the Contract Documents. However, approval by the City shall not in any way be construed, interpreted and/or deemed to constitute a waiver or excuse Consultant's obligations to ensure the Design Documents are constructible, in compliance with all Applicable Laws and in accordance with the Contract Documents. FORCE MAJEURE: "Force Majeure" shall mean any delay occasioned by superior or irresistible force occasioned by violence in nature without the interference of human agency such as a hurricane, tornado, flood, loss caused by fire and other similar unavoidable casualties; or other causes beyond the City's or Consultant's control that are not due to any act, omission or negligence of either City or Consultant and, which have, or may be reasonably expected to have, a material adverse effect on the Project, or on the rights and obligations of City or Consultant under this Agreement and which, by the exercise of due diligence, such parties shall not have been able to avoid; provided, however, that inclement weather (except as noted above), the acts or omissions of Subconsultants, the Contractor and its sub-contractors, market conditions, labor conditions, construction industry price trends, and similar matters which normally impact on the construction process shall not be considered a Force Majeure. If the Consultant is delayed in performing any obligation under this Agreement due to a Force Majeure, the Consultant shall request a time extension from the Project Administrator within five (5) business days of said Force Majeure. Any time extension shall be subject to mutual 7 agreement and shall not be cause for any claim by the Consultant for extra compensation, unless Additional Services are required and approved pursuant to Article 5 hereof. PROJECT: The "Project" shall mean that certain City capital project described in the Consultant Service Order. Project Cost: The "Project Cost", shall mean the estimated total cost of the Project, as prepared and established by the City, including the estimated Construction Cost and Soft Costs. The Project Cost may, from time to time, be revised or adjusted by the City, in its sole discretion, to accommodate approved modifications or changes to the Project or scope of work. Project Scope: The "Project Scope" shall mean the description of the Project, as described in the Consultant Service Order. PROJECT ADMINISTRATOR: The "Project Administrator" shall mean the individual designated by the City Manager who shall be the City's authorized representative to issue directives and notices on behalf of the City with respect to all matters concerning the Services of this Agreement (exclusive of those authorizations reserved to the City Manager or City Commission under this Agreement, or to regulatory or administrative bodies having jurisdiction over the Project). PROPOSAL DOCUMENTS: "Proposal Documents" shall mean the RFQ, together with all amendments or addenda thereto (if any), which is incorporated by reference to this Agreement and made a part hereof; provided, however, that in the event of an express conflict between the Proposal Documents and this Agreement, the Agreement shall prevail. Consultant's proposal in response to the RFQ is included for reference purposes only and shall not be incorporated as part of this Agreement, except with respect to Consultant's representations regarding the qualifications and experience of Consultant and its key personnel, its commitment to provide the key personnel listed therein, and its capability to perform and deliver the Services in accordance with this Agreement and consistent with the all representations made therein. SCHEDULES: "Schedules" shall mean the various schedules attached to this Agreement and referred to as follows: Schedule A — Consultant Service Order Schedule B—Consultant Compensation and Hourly Billing Rate Schedule. Schedule C —Approved Subconsultants. SCOPE OF SERVICES: "Scope of Services" shall include the Project Scope, Basic Services, and any Additional Services (as approved by the City), all as described in Schedule "A" hereto. SERVICES: "Services" shall mean all services, work, and actions by the Consultant performed pursuant to or undertaken under this Agreement. SOFT COSTS: "Soft Costs" shall mean costs related to the Project other than Construction Cost including, without limitation, Consultant's Basic Services, Additional Services, surveys, testing, general consultant, financing, permitting fees and other similar costs, as determined by the City, that are not considered as direct costs for the construction of the Project. STATEMENT OF PROBABLE CONSTRUCTION COST: The "Statement of Probable 8 Construction Cost" shall mean the detailed estimate prepared by Consultant in Construction Standard Index (CSI) format or other format approved by the Project Administrator, which includes the Consultant's estimated total construction cost to the City of the Work for the Project (as established in the Contract Documents, as they may be amended from time to time). The Statement of Probable Construction Cost shall be in sufficient detail to identify the costs of each element of the Project and include a breakdown of the fees, general conditions and construction contingency for the Project. Costs shall be adjusted to the projected bid date to take into account anticipated price escalation. WORK: "Work" shall mean all labor, materials, equipment, supplies, tools, machinery, utilities, fabrication, transportation, insurance, bonds, permits and conditions thereof, building code changes and government approvals, licenses, tests, quality assurance and/or quality control inspections and related certifications, surveys, studies, and other items, work and services that are necessary or appropriate for the total construction, installation, and functioning of the Project, together with all additional, collateral and incidental items, and work and services required for delivery of a completed, fully functional and functioning Project as set forth in the Contract Documents. ARTICLE 2. BASIC SERVICES 2.1 The Consultant shall provide Basic Services for the Project, specifically described in the Consultant Service Order. 2.2 The Services will be commenced by the Consultant upon receipt of a written Consultant Service Order signed by the City Manager or the Project Administrator. Consultant shall countersign the Consultant Service Order upon receipt and return the signed copy to the City. 2.3 As it relates to the Services and the Project, Consultant warrants and represents to the City that it is knowledgeable of and shall comply with all Applicable Laws. The Consultant agrees to comply with all Applicable Laws, whether now in effect or as may be amended or adopted from time to time, and shall further take into account all known pending changes to the foregoing of which it should reasonably be aware. 2.4 The Consultant warrants and represents to the City that all of the Services required under this Agreement shall be performed in accordance with the standard of care normally exercised in the design of comparable projects in South Florida. Consultant warrants and represents to the City that it is experienced, fully qualified, and properly licensed (pursuant to Applicable Laws) to perform the Services. Consultant warrants and represents to the City that it is responsible for the technical accuracy of the Services (including, without limitation, the Design Documents contemplated in Schedule "A" hereto). Consultant further warrants and represents that the approved and permitted Construction Documents shall constitute a representation by Consultant to City that the Project, if constructed as required by the Contract Documents, will be fully functional, suitable and sufficient for its intended purposes. 2.5 The Consultant's Basic Services may consist of various tasks, including planning, design, bidding/award, preparation of a DCP, studies, construction administration, and Additional Services (as may be approved), all as further described in the Consultant Service Order; and shall also include any and all of Consultant's responsibilities and obligations with respect to the Project, as set forth in the General Conditions of the Contract for Construction. 9 2.6 RESPONSIBILITY FOR CLAIMS AND LIABILITIES: No action or omission by City shall waive or excuse Consultant's obligations under the Agreement and/or other Contract Documents and that Consultant shall remain fully liable for all work performed by Consultant including, without limitation, any design errors or omissions. Written decisions and/or approvals issued by the City shall not constitute nor be deemed a release of the responsibility and liability of the Consultant (or any Subconsultants), for the accuracy and competency of the Design Documents and Construction Documents, nor shall any City approval and/or decisions be deemed to be an assumption of such responsibility by the City for a defect, error or omission in the Design Documents and the Construction Documents. Moreover, neither the City's inspection, review, approval or acceptance of, nor payment for, any Services required under the Agreement shall be construed to relieve the Consultant (or any Subconsultant) of its obligations and responsibilities under the Agreement, nor constitute a waiver of any of the City's rights under the Agreement, or of any cause of action arising out of the performance of the Agreement. The Consultant shall be and remain liable to the City in accordance with Applicable Laws for all damages to City caused by any failure of the Consultant or to comply with the terms and conditions of the Agreement or by the Consultant's misconduct, unlawful acts, negligent acts, errors or omissions in the performance of the Agreement. 2.7 TIME: It is understood that time is of the essence in the completion of the Project and, in this respect, the parties agree as follows: 2.7.1 Term: The term of this Agreement shall commence upon execution by the City and Consultant, which shall be the Effective Date referred to on page 1 hereof, and shall be in effect for three (3) years ("Initial Term"), plus two (2), one (1) year renewal options, to be exercised at the sole discretion of the City Manager (Initial Term and any renewals shall be collectively referred to as the "Term"). Notwithstanding the preceding Term, Consultant shall adhere to any and all timelines and/or deadlines, as set forth in the Consultant Service Order, including the time for completion of the work and/or services for such Project (as set forth in the particular Consultant Service Order). 2.7.2 The Consultant shall perform the Services as expeditiously as is consistent with the standard of professional skill and care required by this Agreement, and the orderly progress of the Work. 2.7.3 Recognizing that the construction of other projects within the City may affect scheduling of the construction for the Project, the Consultant shall diligently coordinate performance of the Services with the City (through the Project Administrator) in order to provide for the safe, expeditious, economical and efficient completion of the Project, without negatively impacting concurrent work by others. The Consultant shall coordinate the Services with all of its Subconsultants, as well as other consultants, including, without limitation, City provided consultants (if any). 2.7.4 The Services shall be performed in a manner that shall conform to the Consultant Service Order. The Consultant may submit requests for an adjustment to the Consultant Service Order completion time, if made necessary because of undue delays resulting from untimely review taken by the City (or authorities having jurisdiction over the Project) to approve the Consultant's submissions, or any other portion of the Services requiring approval by the City (or other governmental authorities having jurisdiction over the Project). Consultant shall immediately provide the Project Administrator with written notice stating the reason for the particular delay; the requested adjustment (i.e. extension) to the Project Schedule; and a revised anticipated schedule of completion. 10 Upon receipt and review of Consultant's request (and such other documentation as the Project Administrator may require), the Project Administrator may grant a reasonable extension of time for completion of the particular work involved, and authorize that the appropriate adjustment be made to the Project Schedule. The Project Administrator's approval (if granted) shall be in writing. 2.8 Consultant shall use its best efforts to maintain a constructive, professional, cooperative working relationship with the Project Administrator, Contractor, and any and all other individuals and/or firms that have been contracted, or otherwise retained, to perform work on the Project. 2.9 The Consultant shall perform its duties under this Agreement, and under a Consultant Service Order, in a competent, timely and professional manner, and shall be responsible to the City for any failure in its performance, except to the extent that acts or omissions by the City make such performance impossible. 2.10 The Consultant is responsible for the professional quality, technical accuracy, completeness, performance and coordination of all Services required under the Agreement and under the Consultant Service Order (including the services performed by Subconsultants), within the specified time period and specified cost. The Consultant shall perform the Services utilizing the skill, knowledge, and judgment ordinarily possessed and used by a proficient consulting with respect to the disciplines required for the performance of such Services in the State of Florida. The Consultant is responsible for, and shall represent to City that the Services conform to the City's requirements, the Contract Documents and all Applicable Laws. The Consultant shall be and remain liable to the City for all damages to the City caused by the Consultant's negligent acts or errors or omissions in the performance of the Services. In addition to all other rights and remedies which the City may have, the Consultant shall, at its expense, re-perform all or any portion of the Services to correct any deficiencies which result from the Consultant's failure to perform in accordance with the above standards. The Consultant shall also be liable for the replacement or repair of any defective materials and equipment and re-performance of any non-conforming construction work resulting from such deficient Services (i) for a period from the Effective Date of this Agreement, until twelve (12) months following final acceptance of the Work, (ii) or for the period of design liability required by applicable law, whichever is later. The Project Administrator shall notify the Consultant, in writing, of any deficiencies and shall approve the method and timing of the corrections. 2.10.1 The Consultant shall be responsible for deficient, defective Services and any resulting deficient, defective construction work re-performed within twelve (12) months following final acceptance and shall be subject to further re-performance, repair and replacement for twelve (12) months from the date of initial re-performance, not to exceed twenty-four months (24) from final acceptance. 2.11 The City shall have the right, at any time, in its sole and absolute discretion, to submit for review to other consultants (engaged by the City at its expense) any or all parts of the Services and the Consultant shall fully cooperate in such review(s). Whenever others are required to verify, review, or consider any Services performed by Consultant (including, without limitation, contractors, other design professionals, and/or other consultants retained by the City), the intent of such requirement is to enable the Consultant to receive input from others' professional expertise to identify any discrepancies, errors or omissions that are inconsistent with industry standards for design or construction of comparable projects; or which are inconsistent with Applicable Laws; or which are inconsistent with standards, decisions or approvals provided by the City under this Agreement. Consultant will use reasonable care and skill, in accordance and 11 consistent with customary professional standards, in responding to items identified by other reviewers in accordance with this subsection. Consultant shall receive comments from reviewers, in writing, including, without limitation (and where applicable), via a set of marked-up drawings and specifications. Consultant shall address comments forwarded to it in a timely manner. The term "timely" shall be defined to mean as soon as possible under the circumstances, taking into account the timelines of the Project schedule. 2.11.1 The Consultant is advised that a performance evaluation of the Services rendered throughout this Agreement will be completed by the City and kept in the City's files for evaluation of future solicitations. 2.12 Consultant agrees that when any portion of the Services relates to a professional service which, under Florida Statutes, requires a license, certificate of authorization, or other form of legal entitlement to practice and/or perform such Service(s), it shall employ and/or retain only qualified duly licensed certified personnel to provide same. 2.13 Consultant agrees to designate, in writing, within five (5) calendar days after receiving a fully executed Consultant Service Order, a qualified licensed professional to serve as its project manager (hereinafter referred to as the "Project Manager"). The Project Manager shall be authorized and responsible to act on behalf of Consultant with respect to directing, coordinating and administrating all aspects of the Services. Consultant's Project Manager (as well as any replacement) shall be subject to the prior written approval of the City Manager or the Project Administrator. Replacement (including reassignment) of an approved Project Manager shall not be made without the prior written approval of the City Manager or his designee (i.e. the Project Administrator). 2.13.1 Consultant agrees, within fourteen (14) calendar days of receipt of written notice from the City Manager or the Project Administrator (which notice shall state the cause therefore), to promptly remove and replace a Project Manager, or any other personnel employed or otherwise retained by Consultant for the Project ( including, without limitation, any Subconsultants). 2.14 Consultant agrees not to divulge, furnish or make available to any third party(ies), any non-public information concerning the Services or the Project, without the prior written consent of the City Manager or the Project Administrator, unless such disclosure is incident to the proper performance of the Services; or the disclosure is required pursuant to Florida Public Records laws; or, in the course of judicial proceedings, where such information has been properly subpoenaed. Consultant shall also require Subconsultants to comply with this subsection. 2.15 The City and Consultant acknowledge that the Services, as described in the Agreement and the Consultant Service Order, do not delineate every detail and minor work task required to be performed by Consultant to complete the work and/or services described and delineated under a Consultant Service Order issued to Consultant by the City for a particular Project. If, during the course of performing work, services and/or tasks on a particular Consultant Service Order, Consultant determines that work and/or services should be performed (to complete the Project delineated under such Order) which is, in the Consultant's reasonable opinion, outside the level of effort originally anticipated in the Consultant Service Order, then Consultant shall promptly notify the Project Administrator, in writing, and shall obtain the Project Administrator's written consent before proceeding with such work and/or services. If Consultant proceeds with any such additional work and/or services without obtaining the prior written consent of the Project Administrator, said work and/or services shall be deemed to be a Basic Service under 12 this Agreement and shall also be deemed to be within the scope of services delineated in the Consultant Service Order (whether or not specifically addressed in the Scope of Services). Mere notice by Consultant to the Project Administrator shall not constitute authorization or approval by the City to perform such work. Performance of any such work and/or services by Consultant without the prior written consent of the Project Administrator shall be undertaken at Consultant's sole risk and liability. 2.16 Consultant shall establish, maintain, and categorize any and all Project documents and records pertinent to the Services and shall provide the City, upon request, with copies of any and all such documents and/or records. In addition, Consultant shall provide electronic document files to the City upon completion of the Project. 2.17 THE CITY HAS NO OBLIGATION TO ASSIST, FACILITATE AND/OR PERFORM IN ANY WAY THE CONSULTANT'S OBLIGATIONS UNDER THE AGREEMENT OR OTHER CONTRACT DOCUMENTS. THE CITY'S PARTICIPATION, FACILITATION AND/OR ASSISTANCE TO THE CONSULTANT SHALL BE AT ITS SOLE DISCRETION AND SHALL NOT, IN ANY WAY, BE CONSTRUED, INTERPRETED AND/OR CONSTITUTE AN ASSUMPTION BY THE CITY OF CONSULTANT'S OBLIGATIONS, A WAIVER OF CONSULTANT'S OBLIGATIONS AND/OR EXCUSE ANY BREACH BY CONSULTANT OF ITS OBLIGATIONS UNDER THE CONTRACT DOCUMENTS. THE PARTICIPATION IN THE PERFORMANCE OF ANY OF CONSULTANT'S OBLIGATIONS SHALL NOT PRECLUDE THE CITY FROM DECLARING CONSULTANT IN DEFAULT FOR CONSULTANT'S FAILURE TO PERFORM SUCH OBLIGATION, NOR SHALL IT LIMIT, IN ANY WAY, THE CITY'S RIGHTS AND REMEDIES IN CONNECTION THEREWITH. THE CONSULTANT EXPRESSLY ACKNOWLEDGES AND AGREES NOT TO RAISE OR ASSERT AS DEFENSE TO ANY CLAIM, ACTION, SUIT AND/OR OTHER PROCEEDING OF A SIMILAR NATURE, THE CITY'S PARTICIPATION, ASSISTANCE AND/OR FACILITATION IN THE PERFORMANCE OF CONSULTANT'S OBLIGATIONS. INCLUDING, WITHOUT LIMITATION, ASSISTING WITH OBTAINING PERMITS OR WITH COORDINATION WITH UTILITIES, OR OTHER MATTERS RELATED TO THE PROJECT. IN THE EVENT OF ANY CONFLICT BETWEEN THIS SECTION AND/OR ANY OTHER PROVISION OF THIS AGREEMENT OR OTHER CONTRACT DOCUMENTS, THIS SECTION SHALL GOVERN. 2.18 GREEN BUILDING STANDARDS: The Consultant shall comply with the requirements of Section 255.2575, Florida Statutes, and Chapter 100 of the City Code, as both may be amended from time to time, addressing applicable Leadership in Energy and Environmental Design (LEED) compliance requirements. 2.19 SUBCONSULTANTS: All services provided by Subconsultants shall be consistent with those commitments made by the Consultant in its Proposal and during the competitive solicitation selection process and interview. Such services shall be undertaken and performed pursuant to appropriate written agreements between the Consultant and the Subconsultants, which shall contain provisions that preserve and protect the rights of the City under this Agreement. Nothing contained in this Agreement shall create any contractual relationship between the City and the Subconsultants. The Consultant shall not retain, add, or replace any Subconsultant without the prior written approval of the City Manager, in response to a written request from the Consultant stating the reasons for any proposed substitution. The Consultant shall cause the names of Subconsultants responsible for significant portions of the Services to be inserted on the plans and specifications. 13 The Consultant shall be ultimately responsible for ensuring the Consultant's and all of its Subconsultants' compliance with the requirements of this Section and any other provision of the Agreement and/or Consultant Service Order. With respect to the performance of work by Subconsultants, the Consultant shall, in approving and accepting such work, ensure the professional quality, completeness, and coordination of the Subconsultant's work. The Consultant shall, upon the request of the City, submit to the City such documentation and information as the City reasonably requests to evidence the creation, standing, ownership and professional licensure of the Consultant (and Subconsultants), including organizational documents, operating agreements and professional licensure documentation, and copies of the Consultant's contracts with the Subconsultant with respect to the Project. However, the City's failure to request such documentation or evidence and/or failure to enforce in any way the terms and provisions of this Section, the Agreement and/or any other Consultant Service Order during the Project does not excuse, waive and/or condone in any way any noncompliance of the requirements set forth therein including, without limitation, the professional licensure requirements. Any approval of a Subconsultant by the City shall in no way shift from the Consultant to City the responsibility for the quality and acceptability of the services performed by the Subconsultant. Payment of Subconsultants shall be the sole responsibility of the Consultant, and shall not be cause for any increase in compensation to the Consultant for payment of the Services. ARTICLE 3. THE CITY'S RESPONSIBILITIES 3.1 The City Manager shall designate a Project Administrator, who shall be the City's authorized representative to act on City's behalf with respect to the City's responsibilities or matters requiring City's approval under the Contract Documents. The Project Administrator shall be authorized (without limitation) to transmit instructions, receive information, and interpret and define City policies and decisions with respect to the Services and the Project. The Project Administrator shall have full authority to require the Consultant to comply with the Contract Documents, provided, however, that any failure of the Project Administrator to identify any noncompliance, or to specifically direct or require compliance, shall in no way constitute a waiver of, or excuse, the Consultant's obligation to comply with the requirements of the Contract Documents. 3.2 The City shall make available to Consultant, for the convenience of the Consultant only, information that the City has in its possession pertinent to the Project. Consultant hereby agrees and acknowledges that, in making any such information available to Consultant, the City makes no express or implied certification, warranty, and/or representation as to the accuracy or completeness of such information and assumes no responsibility whatsoever with respect to, the sufficiency, completeness or accuracy of such information. The Consultant understands, and hereby agrees and acknowledges, that it is obligated to verify to the extent it deems necessary all information furnished by the City, and that it is solely responsible for the accuracy and applicability of all such information used by Consultant. Such verification shall include, without limitation, visual examination of existing conditions in all locations encompassed by the Project, where such examination can be made without using destructive measures (i.e. excavation or demolition). Survey information shall be spot checked to the extent that Consultant has satisfied itself as to the reliability of the information. 3.3 At any time, in his/her sole discretion, the City Manager may furnish accounting, and insurance counseling services for the Project (including, without limitation, auditing services to 14 verify the Consultant's applications for payment, or to ascertain that Consultant has properly remitted payment due to its Subconsultants or vendors). 3.4 If the City observes or otherwise becomes aware of any fault or defect in the Project, or non-conformance with the Contract Documents, the City, through the Project Administrator, shall give prompt written notice thereof to the Consultant. 3.5 The City, acting in its proprietary capacity as Owner and not in its regulatory capacity, shall render any administrative approvals and decisions required under this Agreement, in writing, as reasonably expeditious for the orderly progress of the Services and of the Work. 3.6 The City Commission shall be the final authority to do or to approve the following actions or conduct, by passage of an enabling resolution or amendment to this Agreement: 3.6.1 Except where otherwise expressly noted in the Agreement or the Contract Documents, the City Commission shall be the body to consider, comment upon, or approve any amendments or modifications to this Agreement. 3.6.2 The City Commission shall be the body to consider, comment upon, or approve any assignment, sale, transfer or subletting of this Agreement. Assignment and transfer shall be defined to also include sale of the majority of the stock of a corporate consultant. 3.6.3 The City Commission shall approve or consider all Contract Amendments that exceed the sum of fifty thousand dollars ($50,000.00) (or other such amount as may be specified by the City of Miami Beach Procurement Ordinance, as amended). 3.7 Except where otherwise expressly noted in this Agreement, the City Manager shall serve as the City's primary representative to whom administrative (proprietary) requests for decisions and approvals required hereunder by the City shall be made. Except where otherwise expressly noted in this Agreement or the Contract Documents, the City Manager shall issue decisions and authorizations which may include, without limitation, proprietary review, approval, or comment upon the schedules, plans, reports, estimates, contracts, and other documents submitted to the City by Consultant. 3.7.1 The City Manager shall have prior review and approval of the Project Manager (and any replacements) and of any Subconsultants (and any replacements). 3.7.2 The City Manager shall decide, and render administrative (proprietary) decisions on matters arising pursuant to this Agreement which are not otherwise expressly provided for in this Agreement. In his/her discretion, the City Manager may also consult with the City Commission on such matters. 3.7.3 At the request of Consultant, the City Manager shall be authorized, but not required, to reallocate monies already budgeted toward payment of the Consultant; provided, however, that the Consultant's compensation (or other budgets established by this Agreement) may not be increased without the prior approval of the City Commission, which approval (if granted at all) shall be in its sole and reasonable discretion. 3.7.4 The City Manager may approve Contract Amendments which do not exceed the sum of fifty thousand dollars ($50,000.00) (or other such amount as may be specified by 15 the City of Miami Beach Purchasing Ordinance, as amended); provided that no such amendments increase any of the budgets established by this Agreement. 3.7.5 The City Manager may, in his/her sole discretion, form a committee or committees, or inquire of, or consult with, persons for the purpose of receiving advice and recommendations relating to the exercise of the City's powers, duties, and responsibilities under this Agreement or the Contract Documents. 3.7.6 The City Manager shall be the City Commission's authorized representative with regard to acting on behalf of the City in the event of issuing any default notice(s) under this Agreement, and, should such default remain uncured, in terminating the Agreement (pursuant to and in accordance with Article 10 hereof). 3.8 The City's review, evaluation, or comment as to any documents prepared by or on behalf of the Consultant shall be solely for the purpose of the City's determining for its own satisfaction the suitability of the Project, or portions thereof, detailed in such documents for the purposes intended therefor by the City, and may not be relied upon in any way by the Consultant or any other third party as a substantive review thereof. ARTICLE 4. RESPONSIBILITY FOR CONSTRUCTION COST 4.1 The City shall establish a Construction Cost Budget for the Project, as set forth in the Consultant Service Order. Consultant shall design the Project so that the Construction Cost Budget for the Project is not exceeded. As part of the Basic Services, Consultant shall design and/or re-design the Project to the Construction Cost Budget in accordance with this Article 4, making all revisions necessary to maintain the Construction Cost Budget. Consultant shall attend meetings with the City to review and discuss cost estimates, cost-saving alternatives, and implementation or revision of the Design Documents and Construction Documents to address such items, as necessary to meet the established budget parameters set forth in the City Construction Budget. 4.2. Consultant shall provide and/or update the Statement of Probable Construction Cost at each stage of completion of the Design Documents and at completion of the Construction Documents, unless otherwise specified in the Consultant Service Order or other written directive of the Project Administrator. 4.2.1. At completion of the conceptual design (at such stage of completion of the Design Documents as may be specified by the Project Administrator), Consultant shall provide the City a Statement of Probable Construction Cost, which must include an estimated Construction Cost for the Project within a range of plus or minus fifteen percent (+/-15%) of the Construction Cost Budget. If at the foregoing stage of design the Consultant's Statement of Probable Construction Cost exceeds the City's Construction Budget by more than fifteen percent (15%), then the Project Administrator shall provide notice thereof to the Consultant. Consultant shall then identify the cause(s) for the difference and recommend in writing for the City's approval any modification in the Design Documents necessary to conform the Consultant's estimated total costs in the Statement of Probable Construction Cost to within fifteen percent (15%) of the City's Construction Budget. Upon obtaining City's approval of any proposed modifications, Consultant shall incorporate such modifications within the Design Documents as part of the Basic Services and at no additional cost to the City. 16 4.2.2. At the 30% and 60% completion of the Design Documents, Consultant shall update its Statement of Probable Construction Cost, which must include an estimated Construction Cost for the Project within a range of plus or minus ten percent (+/-10%) of the Construction Cost Budget. If at the foregoing stages of design the Consultant's Statement of Probable Construction Cost exceeds the City's Construction Budget by more than ten percent (10%), the Project Administrator shall provide notice thereof to the Consultant. Consultant shall then identify the cause(s) for the difference and recommend in writing for the City's approval any modification in the Design Documents necessary to conform the Consultant's estimated total costs in the Statement of Probable Construction Cost to within ten percent (10%) of the City's Construction Budget. Upon obtaining City's approval of any proposed modifications, Consultant shall incorporate such modifications within the Design Documents as part of the Basic Services and at no additional cost to the City. 4.2.3. At the 90% stage completion of the Design Documents and at completion of the Construction Documents, Consultant shall update its Statement of Probable Construction Cost, which must include an estimated Construction Cost for the Project within a range of plus or minus five percent (+/-5%) of the Construction Cost Budget. If at the foregoing stages of design the Consultant's Statement of Probable Construction Cost exceeds the City's Construction Budget by more than five percent (5%), the Project Administrator shall provide notice thereof to the Consultant. Consultant shall then identify the cause(s) for the difference and recommend in writing for the City's approval any modification in the Design Documents necessary to conform the Consultant's estimated total costs in the Statement of Probable Construction Cost to within five percent (5%) of the City's Construction Budget. Upon obtaining the City's approval, Consultant shall promptly modify the Design Documents or Construction Documents within the time period specified by the Project Administrator (which time period for completion shall not exceed ninety (90) days from the date Consultant is notified to re-design), as part of the Basic Services and at no additional cost to the City. 4.2.4. To ensure that the Construction Cost shall not exceed the City's Construction Budget, each Statement of Probable Construction Cost shall be in sufficient detail to identify the costs of each element and include a breakdown of the fees, general conditions and a reasonable and appropriate construction contingency. 4.3. Consultant shall certify and warrant to the City that the Statement of Probable Construction Cost and any update thereto, represents Consultant's best judgment of the Construction Cost for the Project as an experienced design professional familiar with the construction industry, provided, however, that Consultant cannot (and does not) guarantee that bids or negotiated prices will not vary from any estimates of Construction Cost or other cost evaluation(s) prepared (or otherwise provided) by Consultant. 4.4 If the lowest and best Base Bid exceeds the Consultant's final updated Statement of Probable Cost by more than ten percent (10%), the Project Administrator shall provide notice thereof to the Consultant, and the Consultant shall re-design the Project within the Project Scope, construction schedule, sequence of Work, or such other action, as deemed necessary, to reduce the Statement of Probable Construction Cost, and Consultant shall provide any required revisions to the Contract Documents (including, without limitation, the Construction Documents) within the time period specified by the Project Administrator (which time period for completion shall not exceed ninety (90) days from the date Consultant is notified to re-design), and shall provide re-bidding services, as many times as may be reasonably requested by the City, as part of the Basic Services and at no additional cost to the City, in order to bring any resulting, responsive and responsible bids within ten percent (10%) of the Consultant's final 17 updated Statement of Probable Cost. 4.5. The Construction Cost Budget shall not be exceeded without fully justifiable, extraordinary, and unforeseen circumstances (such as Force Majeure) which are beyond the control of the parties. Any expenditure above this amount shall be subject to prior City Commission approval which, if granted at all, shall be at the sole and reasonable discretion of the City Commission. The City Commission shall have no obligation to approve an increase in the Construction Cost Budget and, if such Construction Cost Budget is exceeded, the City Commission may, at its sole and absolute discretion, terminate this Agreement (and the remaining Services) without any further liability to the City. 4.6. The City Commission may, at its sole and absolute discretion, and without relieving Consultant of its obligations under this Agreement to design the Project to the Construction Cost Budget as set forth in Sections 4.1 through 4.5 above, separately elect any of the following options: (1) approve an increase to the Construction Cost Budget; (2) reject all bids, and (at its option) authorize rebidding of the Project; (3) abandon the Project and terminate the remaining Services without any further liability to the City; (4) select as many deductive alternatives as may be necessary to bring the lowest and best bid within the Construction Cost Budget. ARTICLE 5. ADDITIONAL SERVICES 5.1 Additional Services shall only be performed by Consultant following receipt of written authorization by the Project Administrator (which authorization must be obtained prior to commencement of any such additional work by Consultant). The written authorization shall contain a description of the Additional Services required; a lump sum to be negotiated at the time of the request for additional services or an hourly fee (in accordance with the rates in Schedule "B" hereto), with a "Not to Exceed" amount; Reimbursable Expenses (if any) with a "Not to Exceed" amount; the amended Construction Cost Budget (if applicable); the time required to complete the Additional Services; and an amended Project Schedule (if applicable). "Not to Exceed" shall mean the maximum cumulative hourly fees allowable (or, in the case of Reimbursable Expenses, the maximum cumulative expenses allowable), which the Consultant shall not exceed without further written authorization of the Project Administrator. The "Not to Exceed" amount is not a guaranteed maximum cost for the additional work requested (or, in the case of Reimbursables, for the expenses), and all costs applicable to same shall be verifiable through time sheets (and, for Reimbursables, expense reviews). 5.2 Additional Services include the following: 5.2.1 Appraisals: Investigation and creation of detailed appraisals and valuations of existing facilities, and surveys or inventories in connection with construction performed by City. 5.2.2. Unforeseen Conditions. Providing additional work relative to the Project which arises from subsequent circumstances and causes which could not reasonably have been foreseen at the time of the Consultant Service Order (excluding conditions determined by all prior studies available to Consultant and excluding circumstances and causes resulting from error, omission, inadvertence, or negligence of Consultant). 5.2.3. City-Requested Revisions to Construction Documents: Making revisions to Construction Documents resulting in or from City-requested changes in Scope of Work involving new program elements, when such revisions are inconsistent with written 18 approvals or instructions previously given by City and/or are due to causes beyond the control of Consultant. 5.2.4 Expert Witness: Except insofar as the Consultant is required by legal process or subpoena to appear and give testimony, preparing to serve or serving as an expert witness in connection with any state or federal court action to which the Consultant is not a party in its own name, that is not instituted by the Consultant or in which the performance of the Consultant is not in issue. 5.2.5 Procurement: Assistance in connection with bid protests, re-bidding, or re- negotiating contracts (except for Contract Document revisions and re-bidding services required under Section 4.4 hereof, which shall be provided at no additional cost to City). 5.2.6. Models: Preparing professional perspectives, models or renderings in addition to those provided for in this Agreement except insofar as these are otherwise useful or necessary to the Consultant in the provision of Basic Services. 5.2.7. Threshold Inspection/Material Testing and Inspection: Providing threshold inspection services and material testing/special inspection services, provided that Consultant, as part of the Basic Services, shall report on the progress the Work, including any defects and deficiencies that may be observed in the Work. 5.2.8 Pre-Design Surveys & Testing: Environmental investigations and site evaluations, provided, however, that surveys of the existing structure required to complete as-built documentation are not additional services. 5.2.9 Geotechnical engineering. Providing geotechnical engineering services or site surveys. Except as specified herein, services that are required for completion of the Construction Documents shall be part of Consultant's Basic Services. ARTICLE 6. REIMBURSABLE EXPENSES 6.1 Reimbursable Expenses must be authorized, in advance, in writing, by the Project Administrator. Invoices or vouchers for Reimbursable Expenses shall be submitted to the Project Administrator (along with any supporting receipts and other back-up material requested by the Project Administrator). Consultant shall certify as to each such invoice and/or voucher that the amounts and items claimed as reimbursable are "true and correct and in accordance with the Agreement." Reimbursable Expenses may include, but not be limited to, the following: Cost of reproduction, courier, and postage and handling of drawings, plans, specifications, and other Project documents (excluding reproductions for the office use of the Consultant and its Subconsultants, and courier, postage and handling costs between the Consultant and its Subconsultants). Costs for reproduction and preparation of graphics for community workshops. Permit fees required by City of Miami Beach regulatory bodies having jurisdiction over the Project (i.e. City permit fees). 19 ARTICLE 7. COMPENSATION FOR SERVICES 7.1 Consultant's "Lump Sum" or"Not to Exceed" fee for provision of the Services, or portions thereof, as may be set forth and described in the Consultant Service Order issued for a particular Project, shall be negotiated between the City and Consultant, and shall be set forth in the Consultant Service Order. 7.2 Payments for Services shall be made within forty-five (45) calendar days of receipt and approval of an acceptable invoice by the Project Administrator. Payments shall be made in proportion to the Services satisfactorily performed, so that the payments for Services never exceed the progress percentage noted in the Consultant's Progress Schedule (to be submitted with each invoice). No mark-up shall be allowed on subcontracted work. In addition to the invoice, the Consultant shall, for Hourly Rate authorizations, submit a progress report giving the percentage of completion of the Project and the total estimated fee to completion. 7.3 Approved Additional Services shall be compensated in accordance with the hourly rates set forth in Schedule "B," attached hereto. Any request for payment of Additional Services shall be included with a Consultant payment request. No mark-up shall be allowed on Additional Services (whether sub-contracted or not). 7.4 Approved Reimbursable Expenses shall be paid in accordance with Article 6 hereto, up to the "Not to Exceed" Reimbursable allowance amount in the Consultant Service Order hereto. Any request for payment of Reimbursable Expenses shall also be included with Consultant's payment request. No mark-up shall be allowed on Reimbursable Expenses. 7.5 ESCALATION: The initial hourly rates shall remain constant for the Initial Term of the agreement. Ninety (90) days prior to expiration of the Initial Term, the City may consider an adjustment to the preceding year's unit costs for the subsequent year. Only request for increases based on a corresponding increase in the Consumer Price Index for All Urban Consumers; U.S. City average (1982-84=100), as established by the United States Bureau of Labor Statistics ("CPI"), or material adjustments to the scope or requirements of the RFQ by the City, including (but not limited to) living wage increases, will be considered. In the event that the City determines that the requested increase is unsubstantiated, the Consultant agrees to perform all duties at the current cost terms. 7.6 No retainage shall be made from the Consultant's compensation on account of sums withheld by the City on payments to Contractor. 7.7 METHOD OF BILLING AND PAYMENT. Consultant shall invoice the Project Administrator in a timely manner, but no more than once on a monthly basis. Invoices shall identify the nature and extent of the work performed; the total hours of work performed by employee category; and the respective hourly billing rate associated therewith. In the event Subconsultant work is used, the percentage of completion shall be identified. Invoices shall also itemize and summarize any Additional Services and/or Reimbursable Expenses. A copy of the written approval of the Project Administrator for the requested Additional Service(s) or Reimbursable Expense(s) shall accompany the invoice. 7.7.1 If requested, Consultant shall provide back-up for past and current invoices that records hours for all work (by employee category), and cost itemizations for Reimbursable Expenses (by category). 20 ARTICLE 8. CONSULTANT'S ACCOUNTING AND OTHER RECORDS 8.1 All books, records (whether financial or otherwise), correspondence, technical documents, and any other records or documents related to the Services and/or Project will be available for examination and audit by the City Manager, or his/her authorized representatives, at Consultant's office (at the address designated in Article 15 ["Notices"]), during customary business hours. All such records shall be kept at least for a period of three (3) years after Consultant's completion of the Services. Incomplete or incorrect entries in such records and accounts relating personnel services and expenses may be grounds for City's disallowance of any fees or expenses based upon such entries. Consultant shall also bind its Subconsultants to the requirements of this Article and ensure compliance therewith ARTICLE 9. OWNERSHIP OF PROJECT DOCUMENTS 9.1 All notes, correspondence, documents, plans and specifications, designs, drawings, renderings, calculations, specifications, models, photographs, reports, surveys, investigations, and any other documents (whether completed or partially completed) and copyrights thereto for Services performed or produced in the performance of this Agreement, or related to the Project, whether in its native electronic form, paper or other hard copy medium or in electronic medium, except with respect to copyrighted standard details and designs owned by the Consultant or owned by a third party and licensed to the Consultant for use and reproduction, shall become the property of the City. Consultant shall deliver all such documents to the Project Administrator in their native electronic form, as required in the Consultant Service Order within thirty (30) days of completion of the Services (or within thirty (30) days of expiration or earlier termination of this Agreement as the case may be). However, the City may grant an exclusive license of the copyright to the Consultant for reusing and reproducing copyrighted materials or portions thereof as authorized by the City Manager in advance and in writing, In addition, the Consultant shall not disclose, release, or make available any document to any third party without prior written approval from the City Manager. The Consultant shall warrant to the City that it has been granted a license to use and reproduce any standard details and designs owned by a third party and used or reproduced by the Consultant in the performance of this Agreement. Nothing contained herein shall be deemed to exclude any document from Chapter 119, Florida Statutes. 9.2 The Consultant is permitted to reproduce copyrighted material described above subject to prior written approval of the City Manager. 9.3 At the City's option, the Consultant may be authorized, as an Additional Service, to adapt copyrighted material for additional or other work for the City; however, payment to the Consultant for such adaptations will be limited to an amount not greater than 50% of the original fee earned to adapt the original copyrighted material to a new site. 9.4 The City shall have the right to modify the Project or any components thereof without permission from the Consultant or without any additional compensation to the Consultant. The Consultant shall be released from any liability resulting from such modification. 9.5 The Consultant shall bind all Subconsultants to the Agreement requirements for re-use of plans and specifications. 21 ARTICLE 10. TERMINATION OF AGREEMENT 10.1 TERMINATION FOR LACK OF FUNDS: The City is a governmental entity and is subject to the appropriation of funds by its legislative body in an amount sufficient to allow continuation of its performance in accordance with the terms and conditions of this Agreement. In the event there is a lack of adequate funding either for the Services or the Project (or both), the City may terminate this Agreement without further liability to the City. 10.2 TERMINATION FOR CAUSE: The City, through the City Manager, may terminate this Agreement for cause, upon written notice to Consultant, in the event that the Consultant (1) violates any provision of this Agreement or performs same in bad faith; (2) unreasonably delays the performance of the Services or any portion thereof; or (3) does not perform the Services or any portion thereof in a timely and satisfactory manner. In the case of termination for cause by the City, the Consultant shall first be granted a thirty (30) day cure period (commencing upon receipt of the initial written notice of default from the City). 10.2.1 In the event this Agreement is terminated for cause by the City, the City, at its sole option and discretion, may take over the remaining Services and complete them by contracting with another consultant(s), or otherwise. The Consultant shall be liable to the City for any additional cost(s) incurred by the City due to such termination. "Additional Cost" is defined as the difference between the actual cost of completion of the Services, and the cost of completion of such Services had the Agreement not been terminated. 10.2.2 In the event of termination for cause by the City, the City shall only be obligated to pay Consultant for those Services satisfactorily performed and accepted prior to the date of termination (as such date is set forth in, or can be calculated from, the City's initial written default notice). Upon payment of any amount which may be due to Consultant pursuant to this subsection 10.2.2, the City shall have no further liability to Consultant. 10.2.3 As a condition precedent to release of any payment which may be due to Consultant under subsection 10.2.2, the Consultant shall promptly assemble and deliver to the Project Administrator any and all Project documents prepared (or caused to be prepared) by Consultant(including, without limitation, those referenced in subsection 9.1 hereof). The City shall not be responsible for any cost incurred by Consultant for assembly, copy, and/or delivery of Project documents pursuant to this subsection. 10.3 TERMINATION FOR CONVENIENCE: In addition to the City's right to terminate for cause, the City through the City Manager, may also terminate this Agreement, upon fourteen (14) days prior written notice to Consultant, for convenience, without cause, and without penalty, when (in its sole discretion) it deems such termination to be in the best interest of the City. In the event the City terminates the Agreement for convenience, Consultant shall be compensated for all Services satisfactorily performed and accepted up to the termination date (as set forth in the City's written notice), and for Consultant's costs in assembly and delivery to the Project Administrator of the Project documents (referenced in subsection 10.2.3 above). Upon payment of any amount which may be due to Consultant pursuant this subsection 10.3, the City shall have no further liability to Consultant. 10.4 TERMINATION BY CONSULTANT: The Consultant may only terminate this Agreement for cause, upon thirty (30) days prior written notice to the City, in the event that the City willfully 22 violates any provisions of this Agreement or unreasonably delays payment of the Services or any portion thereof. In the event of a termination for cause by Consultant, the City shall pay Consultant for any Services satisfactorily performed and accepted up to the date of termination; provided, however, that the City shall first be granted a thirty (30) day cure period (commencing upon receipt of Consultant's initial written notice). 10.4.1 The Consultant shall have no right to terminate this Agreement for convenience. 10.5 IMPLEMENTATION OF TERMINATION: In the event of termination (whether for cause or for convenience), the Consultant shall immediately, upon receipt of the City's written notice of termination: (1) stop the performance of Services; (2) place no further orders or issue any other subcontracts, except for those which may have already been approved, in writing, by the Project Administrator; (3) terminate all existing orders and subcontracts; and (4) promptly assemble all Project documents (for delivery to the Project Administrator). ARTICLE 11. INSURANCE 11.1 At all times during the Term of this Agreement, Consultant shall maintain the following required insurance coverage in full force and effect. The Consultant shall not commence any work until satisfactory proof of all required insurance coverage has been furnished to the Project Administrator: (a) Workers' Compensation and Employer's Liability per the Statutory limits of the State of Florida. (b) Commercial General Liability on a comprehensive basis in an amount not less than $1,000,000 combined single limit per occurrence for bodily injury and property damage. (c) Automobile Liability Insurance covering all owned, non-owned and hired vehicles used in connection with the work, in an amount not less than $500,000 combined single limit per occurrence for bodily injury and property damage. (d) Professional Liability Insurance in an amount not less than $1,000,000 with the deductible per claim, if any, not to exceed 10% of the limit of liability. 11.2 The City must be named as and additional insured on the liability policies; and it must be stated on the certificate. 11.3 The Consultant must give the Project Administrator at least thirty (30) days prior written notice of cancellation or of substantial modifications in any required insurance coverage. All certificates and endorsements shall contain this requirement. 11.4 The insurance must be furnished by an insurance company rated A:V or better, or its equivalent, according to Bests' Guide Rating Book, and by insurance companies duly authorized to do business in the State of Florida, and countersigned by the company's Florida resident agent. 11.5 Consultant shall provide the Project Administrator with a certificate of insurance of all required insurance policies. The City reserves the right to require a certified copy of such policies, upon written request to Consultant. 23 ARTICLE 12. INDEMNIFICATION AND HOLD HARMLESS 12.1 To the fullest extent permitted by Section 725.08, Florida Statutes, the Consultant shall indemnify and hold harmless the City and its officers, employees, agents, and instrumentalities, from liabilities, damages, losses, and costs, including, but not limited to, reasonable attorneys' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Consultant and other persons employed or utilized by the Consultant in the performance of this Agreement. The Consultant shall pay all claims and losses in connection therewith and shall investigate and defend all claims, suits, or actions of any kind or nature in the name of the City, where applicable, including appellate proceedings, and shall pay all costs, judgments, and attorney's fees which may issue thereon. Consultant expressly understands and agrees that any insurance protection required by this Agreement or otherwise provided by Consultant shall in no way limit its responsibility to indemnify, keep, and save harmless and defend the City or its officers, employees, agents, and instrumentalities as herein provided. 12.2 The Consultant agrees and recognizes that the City shall not be held liable or responsible for any claims which may result from any negligent, reckless, or intentionally wrongful actions, errors or omissions of the Consultant in which the City participated either through review or concurrence of the Consultant's actions. In reviewing, approving or rejecting any submissions by the Contractor, or other acts of the Consultant, the City in no way assumes or shares any responsibility or liability of the Consultant (including, without limitation its Subconsultants and/or any registered professionals (architects and/or engineers) under this Agreement). ARTICLE 13. ERRORS AND OMISSIONS 13.1 ERRORS AND OMISSIONS: It is specifically agreed that any construction changes categorized by the City as caused by an error, an omission, or any combination thereof in the Contract Documents that were prepared by the Consultant will constitute an additional cost to the City that would not have been incurred without the error. The damages to the City for errors, omissions or any combinations thereof shall be calculated as the total cost of any damages or incremental costs to the City resulting out of the errors or omissions by the Consultant, including, without limitation, the direct, indirect and/or consequential damages resulting from the Consultant's errors and/or omissions or any combination thereof. Damages shall include delay damages caused by the error, omission, or any combination thereof. Should the Consultant disagree that all or part of such damages are the result of errors, omissions, or any combination thereof, the Consultant may appeal this determination, in writing, to the applicable Assistant City Manager. The Project Administrator's decision on all claims, questions and disputes shall be final, conclusive and binding upon the parties hereto unless such determination is clearly arbitrary or unreasonable. In the event that the Consultant does not agree with the decision of the Project Administrator, the Consultant shall present any such objections, in writing, to the City Manager. The Project Administrator and the Consultant shall abide by the decision of the City Manager. This paragraph does not constitute a waiver of any party's right to proceed in a court of competent jurisdiction after the above administrative remedies have been exhausted. 24 ARTICLE 14. LIMITATION OF LIABILITY The City desires to enter into this Agreement only if in so doing the City can place a limit on its liability for any cause of action for money damages due to an alleged breach by the City of this Agreement, so that its liability for any such breach never exceeds the "not to exceed" amount of the fee paid to Consultant under this Agreement, less any amount(s) actually paid to Consultant hereunder. Consultant hereby expresses its willingness to enter into this Agreement, with Consultant's recovery from the City for any damages for action for breach of contract to be limited to Consultant's "not to exceed" fee under this Agreement, less any amount(s) actually paid by the City to the Consultant hereunder. Accordingly, and notwithstanding any other term or condition of this Agreement, Consultant hereby agrees that the City shall not be liable to Consultant for money damages due to an alleged breach by the City of this Agreement, in an amount in excess of the "not to exceed amount" of Consultant's fees under this Agreement, which amount shall be reduced by any amount(s) actually paid by the City to Consultant hereunder. Nothing contained in this subsection, or elsewhere in this Agreement, is in any way intended to be a waiver of the limitation placed upon City's liability, as set forth in Section 768.28, Florida Statutes. ARTICLE 15. NOTICE All written notices given to City by Consultant shall be addressed to: City Manager's Office City of Miami Beach 1700 Convention Center Drive Miami Beach, Florida 33139 Attn: Jimmy L. Morales, City Manager With a copy to: City Manager's Office City of Miami Beach 1700 Convention Center Drive Miami Beach, Florida 33139 Attn: Eric T. Carpenter, Assistant City Manager All written notices given to the Consultant from the City shall be addressed to: Edward Lewis Architects, Inc. 2100 Ponce de Leon Boulevard, Suite 825 Coral Gables, FL 33134 Attn: Edward Lewis Tele: (305) 234-0576 ext.111 or (305) 342-7893 Email: elewis @elamiami.com All notices mailed to either party shall be deemed to be sufficiently transmitted if sent by certified mail, return receipt requested. 25 ARTICLE 16. MISCELLANEOUS PROVISIONS 16.1 VENUE: This Agreement shall be governed by, and construed in accordance with, the laws of the State of Florida, both substantive and remedial, without regard to principles of conflict of laws. The exclusive venue for any litigation arising out of this Agreement shall be Miami-Dade County, Florida, if in state court, and the U.S. District Court, Southern District of Florida, in federal court. BY ENTERING INTO THIS AGREEMENT, CONSULTANT AND CITY EXPRESSLY WAIVE ANY RIGHTS EITHER PARTY MAY HAVE TO A TRIAL BY JURY OF ANY CIVIL LITIGATION RELATED TO, OR ARISING OUT OF, THIS AGREEMENT. 16.2 EQUAL OPPORTUNITY EMPLOYMENT GOALS: Consultant agrees that it will not discriminate against any employee or applicant for employment for work under this Agreement because of race, color, national origin, religion, sex, gender identity, sexual orientation, disability, marital or familial status, or age, and will take affirmative steps to ensure that applicants are employed and employees are treated during employment without regard to race, color, national origin, religion, sex, gender identity, sexual orientation, disability, marital or familial status, or age. 16.3 PUBLIC ENTITY CRIMES ACT: In accordance with the Public Entity Crimes Act (Section 287.133, Florida Statutes), a person or affiliate who is a consultant, who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to the City, may not submit a bid on a contract with the City for the construction or repair of a public building or public work, may not bid on leases of real property to the City, may not be awarded or perform work as a contractor, supplier, subcontractor, or subconsultant under a contract with the City, and may not transact business with the City in excess of the threshold amount provided in Section 287.017, Florida Statutes, for Category Two, for a period of 36 months from the date of being placed on the convicted vendor list. For violation of this subsection by Consultant, City shall have the right to terminate the Agreement without any liability to City, and pursue debarment of Consultant 16.4 NO CONTINGENT FEE: Consultant warrants that it has not employed or retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement, and that it has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. For the breach or violation of this subsection, City shall have the right to terminate the Agreement, without any liability or, at its discretion, to deduct from the contract price (or otherwise recover) the full amount of such fee, commission, percentage, gift, or consideration. 16.5 LAWS AND REGULATIONS: 16.5.1 The Consultant shall, during the Term of this Agreement, be governed by all Applicable Laws which may have a bearing on the Services involved in the Project. 16.5.2 Project Documents. In accordance with Section 119.07 (3) (ee), Florida Statutes, entitled "Inspection, Examination, and Duplication of Records; Exemptions," all building plans, blueprints, schematic drawings, and diagrams, including draft, preliminary, and final formats, are exempt from the provisions of 26 • Section 119.07(1), Florida Statutes (inspection and copying of public records), and s. 24(a), Article I of the State Constitution. Information made exempt by this paragraph, with prior written approval from the City Manager, may be disclosed to another entity to perform its duties and responsibilities; to a licensed architect, engineer, or contractor who is performing work on or related to the Project; or upon a showing of good cause before a court of competent jurisdiction. The entities or persons receiving such information shall maintain the exempt status of the information. 16.5.2.1 In addition to the requirements in this subsection 16.5.2, the Consultant agrees to abide by all applicable Federal, State, and City procedures, as may be amended from time to time, by which the documents are handled, copied, and distributed which may include, but is not limited to, each employee of Consultant and Subconsultants that will be involved in the Project being required to sign an agreement stating that they will not copy, duplicate, or distribute the documents unless authorized by the City Manager, in writing. 16.5.2.2 The Consultant and its Subconsultants agree in writing that the Project documents are to be kept and maintained in a secure location. 16.5.2.3 Each set of the Project documents are to be numbered and the whereabouts of the documents shall be tracked at all times. 16.5.2.4 A log is developed to track each set of documents logging in the date, time, and name of the individual(s) that work on or view the documents. 16.6 CORRECTIONS TO CONTRACT DOCUMENTS: The Consultant shall prepare, without added compensation, all necessary supplemental documents to correct errors, omissions, and/or ambiguities which may exist in the Contract Documents prepared by Consultant, including documents prepared by its Subconsultants. Compliance with this subsection shall not be construed to relieve the Consultant from any liability resulting from any such errors, omissions, and/or ambiguities in the Contract Documents and other documents or Services related thereto. 16.7 ASSIGNMENT: The Consultant shall not assign, transfer or convey this Agreement to any other person, firm, association or corporation, in whole or in part, without the prior written consent of the City Commission, which consent, if given at all, shall be at the Commission's sole option and discretion. However, the Consultant will be permitted to cause portions of the Services to be performed by Subconsultants, subject to the prior written approval of the City Manager. 16.8 SUCCESSORS AND ASSIGNS: The Consultant and the City each binds himself/herself, his/her partners, successors, legal representatives and assigns to the other party of the Agreement and to the partners, successors, legal representatives, and assigns of such party in respect to all covenants of this Agreement. The Consultant shall afford the City (through the City Commission) the opportunity to approve or reject all proposed assignees, successors or other changes in the ownership structure and composition of the Consultant. Failure to do so constitutes a breach of this Agreement by the Consultant. 27 16.9 PROVISION OF ITEMS NECESSARY TO COMPLETE SERVICES: In the performance of the Services prescribed herein, it shall be the responsibility of the Consultant to provide all salaries, wages, materials, equipment, Subconsultants, and other purchased services, etc., as necessary to complete said Services. 1 16.10 INTENT OF AGREEMENT: 16.10.1 The intent of the Agreement is for the Consultant to provide design and other services, and to include all necessary items for the proper completion of such services for a fully functional Project which, when constructed in accordance with the design, will be able to be used by the City for its intended purpose. The Consultant shall perform, as Basic Services, such incidental work which may not be specifically referenced, as necessary to complete the Project. 16.10.2 This Agreement is for the benefit of the parties only and it does not grant rights to a third party beneficiary, to any person, nor does it authorize anyone not a party to the Agreement to maintain a suit for personal injuries, professional liability, or property damage pursuant to the terms or provisions of the Agreement. 16.10.3 No acceptance, order, payment, or certificate of or by the City, or its employees or agents, shall either stop the City from asserting any rights or operate as a waiver of any provisions hereof or of any power or right herein reserved to the City or of any rights to damages herein provided. 16.11 This document incorporates and includes all prior negotiations, correspondence, conversations, agreements, or understandings applicable to the matters contained herein; and the parties agree that there are no commitments, agreements, or understandings concerning the subject matter of this Agreement that are not contained in this document. Accordingly, the parties agree that no deviation from the terms hereof shall be predicated upon any prior representations or agreements whether oral or written. It is further agreed that no modification, amendment or alteration in the terms or conditions contained herein shall be effective unless memorialized in written document approval and executed with the same formality and of equal dignity herewith. IN WITNESS WHEREOF, the parties hereto have hereunto caused these presents to be signed in their names by their duly authorized officers and principals, attested by their respective witnesses and City Clerk on the day and year first hereinabove written. X- - Atte F.� ; yOMI I -.�1 �V � �,44 S 41 .. 40-0\ E3 J Cl CLER -Y0f•V % '' 4951/ j&44___e.„....\_..,..„ # -. • , iAttest INCORP aI � � 0 ;rchite is c.. . • 'Signature/Secretary ••• OS f Pr-//94'" Vr I S q pRP TO �Iiii�/1�._i. ���] �1 _ O % J Print Name FORM &LANGUAGE Print Name &FOR EXECUTION 28 a"-Q...DAP'"C": 1 - 7-0-(6 , City Attorney RIR Date SCHEDULE A PROFESSIONAL SERVICES AGREEMENT BETWEEN THE CITY OF MIAMI BEACH AND EDWARD LEWIS ARCHITECTS, INC. CONSULTANT SERVICE ORDER Service Order No. for Consulting Services. TO: Edward Lewis Architects, Inc. 2100 Ponce de Leon Boulevard, Suite 825 Coral Gables, FL 33134 PROJECT NAME: Project Name DATE: Pursuant to the agreement between the City of Miami Beach and Consultant for PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED" BASIS (RFQ 2014-146-YG) you are directed to provide the following services: SCOPE OF SERVICES: Per attached proposal dated _ , to be considered part of this Agreement. Estimated calendar days to complete this work: Days Original Service Order Amount: $ Total From Previous Additional Service Orders: Fee for this Service Order is Lump Sum/Not to Exceed amount of: Total Agreement to Date: $ City's Project Date Coordinator/Manager Assistant Director Date Consultant. Date Project Administrator-Director Date 29 SCHEDULE B CONSULTANT COMPENSATION Schedule of Payments Planning Services * $XXXXXXXX Design Services* $XXXXXXXX Bidding and Award Services $XXXXXXXX Construction Administration ** $XXXXXXXX Reimbursable Allowance*** $XXXXXXXX Note*: These services will be paid lump sum based on percentage complete of each phase as identified in the individual tasks. Note**: Construction Administration will be paid on a monthly basis upon commencement of construction. In the event that, through no fault of the Consultant, Construction Administration services are required to be extended, which extension shall be subject to prior City approval, and what shall be at the City's sole discretion, the Consultant agrees to extend said services for $XX)OKXX, per month, for the duration required to complete the Project. Note***: The Reimbursable Allowance belongs to the City and must be approved in writing, in advance, by the Project Administrator. Unused portions will not be paid to the Consultant. 30 HOURLY BILLING RATE SCHEDULE Project Principal $172.50 Project Engineer (Coastal or $116.15 Other) Project Manager $138.00 Sr. Field Services Professional $116.15 Senior Civil Engineer $138.00 Field Services Professional $ 80.50 Civil Engineer $116.15 Threshold Inspector $138.00 Senior Electrical Engineer $138.00 Structural Special Inspector $109.25 Electrical Engineer $116.15 Technical Editor $ 74.75 Senior Mechanical Engineer $138.00 Senior GIS Specialist $116.15 Mechanical Engineer $116.15 GIS Specialist $ 86.25 Senior Structural Engineer $138.00 Staff Engineer/Geologist/Scientist $ 94.30 Structural Engineer $116.15 Landscape Designer $ 95.45 Senior Environmental Engineer $138.00 Planner $116.15 Environmental Engineer $116.15 Project Principal ( Structural Engineer) $172.50 Environmental Technician $ 74.75 Project Manager (Structural Engineer) $138.00 Environmental Specialist $ 63.25 CAD Technician (Structural) $ 63.25 Environmental Permit Specialist $ 63.25 Traffic Engineers $116.15 Project Scientist $120.75 Cost Estimator $ 74.75 Senior Surveyor $138.00 Specifications Writer $ 63.25 Surveyor $116.15 , Construction Administrator/Manager $ 94.30 Surveyor Support Staff $ 69.00 Senior Project Manager $138.00 Senior Architect $138.00 MEP Project Engineer $138.00 Architect $116.15 Horticultural/maintenance Consultant $ 86.25 Senior Designer $138.00 Irrigation Engineer $ 94.30 Designer $ 95.45 Job Captain $ 92.00 Senior Urban Planner $138.00 Interior Designer $ 95.45 Senior CAD Technician $ 69.00 Principal/Director of Design $138.00 CAD Technician $ 63.25 Senior Landscape Architect $138.00 Landscape Architect $116.15 Clerical $ 40.25 Administrative Assistant $ 40.25 Survey Crew Party of2 $140.68 Survey Crew Party of 2 w/ GPS $168.51 Survey Crew Party of 3 $170.44 Survey Crew Party of 3w/ GPS $197.01 Survey Crew Party of 4 $211.31 Survey Crew Party of 4 w/ GPS $250.13 Sr. Inspector (CEI) $103.50 Inspector (CEI, Field or $ 94.88 Construction) 31 SCHEDULE C APPROVED SUBCONSULTANTS SUBCONSULTANT: • No preapproved sub-consultants submitted with proposal. • 32 ATTACHMENT A RESOLUTION, COMMISSION ITEM, AND COMMISSION MEMORANDUM 33 RESOLUTION NO. 2015-29068 A RESOLUTION OF THE MAYOR AND CITY COMMISSION OF THE CITY OF MIAMI BEACH, FLORIDA, ACCEPTING THE RECOMMENDATION OF THE CITY MANAGER PERTAINING TO THE RANKING OF PROPOSALS PURSUANT TO REQUEST FOR QUALIFICATIONS (RFQ).NO. 2014-346-YG, FOR PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN AS-NEEDED-BASIS, FOR THE DISCIPLINES OF PLANNING AND URBAN DESIGN ARCHITECTURE, ENVIRONMENTAL ENGINEERING, INTERIOR DESIGN AND SPACE PLANNING ARCHITECTURE, AND STRUCTURAL ENGINEERING; AUTHORIZING THE ADMINISTRATION TO ENTER INTO NEGOTIATIONS WITH KEITH AND SCHNARS, P.A., AECOM TECHNICAL SERVICES, INC., - ZYSCOVICH, INC., AND THE CORRADINO GROUP, INC., FOR THE DISCIPLINE OF PLANNING AND URBAN DESIGN ARCHITECTURE; AUTHORIZING THE ADMINISTRATION TO ENTER INTO NEGOTIATIONS WITH KEITH AND SCHNARS, P.A., URS CORPORATION, E-SCIENCES, INC., CB&I ENVIRONMENTAL & INFRASTRUCTURE, INC., AND KIMLEY-HORN AND ASSOCIATES, INC., FOR THE DISCIPLINE OF ENVIRONMENTAL ENGINEERING; AUTHORIZING THE ADMINISTRATION TO ENTER INTO NEGOTIATIONS WITH EDWARD LEWIS ARCHITECTS, INC., FOR THE DISCIPLINE OF INTERIOR DESIGN AND SPACE PLANNING ARCHITECTURE; AUTHORIZING THE ADMINISTRATION TO ENTER INTO NEGOTIATIONS WITH DOUGLAS WOOD ASSOCIATES, INC., STANLEY CONSULTANTS, INC., THORNTON TOMASETTI, INC., BRINDLEY PIETERS & ASSOCIATES, INC., AND BCC ENGINEERING, FOR THE DISCIPLINE OF STRUCTURAL ENGINEERING; FURTHER, SHOULD THE ADMINISTRATION BE UNABLE TO NEGOTIATE AN AGREEMENT WITH ANY OF THE RECOMMENDED FIRMS, THE ADMINISTRATION IS AUTHORIZED TO NEGOTIATE WITH OTHER RANKED FIRMS IN ORDER OF RANK IN EACH CATEGORY; AND FURTHER AUTHORIZING THE MAYOR AND CITY CLERK TO EXECUTE AN AGREEMENT UPON CONCLUSION OF SUCCESSFUL NEGOTIATIONS BY THE ADMINISTRATION. WHEREAS, Request for Qualifications No. 2014-346-YG (the RFQ) was issued on September 18, 2014, with an opening date of December 2, 2014; and WHEREAS, a voluntary pre-proposal meeting was held on October 1, 2014 and on October 13, 2014; and WHEREAS, the City received proposals from a total of fifty-one (51)firms; and WHEREAS, because of the magnitude of the scope of the RFQ, including all the service categories requested, the Administration will evaluate and make recommendations for award by category group; and WHEREAS, on June 10, 2015, via Resolution 2015-29041, the Mayor and City Commission accepted the City Manager's recommendation pertaining to the ranking of proposals for the following disciplines/groups: Group 1 - Landscape Architecture; Group 2 - General Architecture, Town Planning Architecture and Historical Preservation Architecture; Group 3 - Civil Engineering and Land Surveying; and Group 4: Mechanical, Electrical, and Plumbing Engineering; and WHEREAS, this resolution only addresses an award recommendation for the following remaining disciplines/groups: Group 1 - Planning and Urban Design Architecture and Environmental Engineering; Group 2: Interior Design and Space Planning Architecture; and Group 4: Structural Engineering; and WHEREAS, on February 5, 2015, the City Manager via Letter to Commission (LTC) No. 054-2015, appointed an Evaluation Committee (the "Committee"), which included evaluation committee members for each category group; and WHEREAS, the Evaluation Committee (the "Committee") for Groups 1, 2, and 4 consisted of the following individuals: GROUP 1 —PLANNING AND URBAN DESIGN ARCHITECTURE, AND ENVIRONMENTAL ENGINEERING • Margarita Wells, Environment and Sustainability Specialist, Building Department, City of Miami Beach • Rogelio Madan, Principal Planner, Planning Department, City of Miami Beach • Humberto Cabanas, Division Director, CIP, City of Miami Beach; and GROUP 2—INTERIOR DESIGN/SPACE PLANNING ARCHITECTURE • Deborah Tackett, Preservation and Design Manager, Planning Department, City of Miami Beach • Rogelio Madan, Principal Planner, Planning Department, City of Miami Beach • Valeria Mejia, ADA Coordinator, Property Management, City of Miami Beach; and GROUP 4—STRUCTURAL ENGINEERING • Sabrina Baglieri, Sr. Capital Projects Coordinator, CIP, City of Miami Beach • Oniel Toledo, Construction Manager, Public Works, City of Miami Beach • Jose Perez, Capital Projects Coordinator, CIP, City of Miami Beach WHEREAS, the Committees convened to consider the proposals, as follows: the Committee for Group 1 convened on February 26, 2015; the Committee for Group 2 convened on March 19, 2015; and the Committee for Group 4 convened on April 8, 2015; and WHEREAS, the Committees were provided an overview of the project; information relative to the City's Cone of Silence Ordinance and the Government Sunshine Law; general information on the scope of services, references, and a copy of each proposal; and WHEREAS, the Committees were instructed to score and rank each proposal pursuant to the evaluation criteria established in the RFQ; and WHEREAS, the Committee's ranking for the discipline of Group 1 - Planning and Urban Design Architecture was as follows: Keith and Schnars, P.A., top ranked; AECOM Technical Services, Inc., second highest ranked; Bermello, Ajamil & Partners, Inc., third highest ranked, Zyscovich, Inc., fourth highest ranked; The Corradino Group, Inc., fifth highest ranked; and WHEREAS, the Committee's ranking for the discipline of Group 1- Environmental Engineering was as follows: Keith and Schnars, P.A., top ranked; URS Corporation, second highest ranked; E-Sciences, Inc., third highest ranked, CB&I Environmental & Infrastructure, Inc., fourth highest ranked; Kimley-Horn and Associates, Inc., fifth highest ranked; GFA International, Inc., and Stantec Consulting Services, Inc., are tied as the sixth highest ranked; Cummins Cederberg, Inc., eighth highest ranked, and WHEREAS, the Committee's ranking for the discipline of Group 2 - Interior Design and Space Planning Architecture was as follows: Bermello, Ajamil & Partners, Inc., top ranked; Edward Lewis Architects, Inc., second highest ranked; and WHEREAS, the Committee's ranking for the discipline of Group 4 - Structural Engineering was as follows: Douglas Wood Associates, Inc., top ranked; Stanley Consultants, Inc., second highest ranked; Thornton Tomasetti, Inc., third highest ranked; Brindley Pieters & Associates, Inc., fourth highest ranked; BCC Engineering, Inc., fifth highest ranked; CES Consultants, Inc., sixth highest ranked, and HAKS Engineers Architects and Land Surveyors, P.C., as the seventh highest ranked; and WHEREAS, the City Manager has considered the proposals received, the results of the evaluation committee process and Section 2-369 of the City Code, which states that in the award of contracts the following, shall be considered: (1) The ability, capacity and skill of the bidder to perform the contract. (2) Whether the bidder can perform the contract within the time specified, without delay or interference. (3) The character, integrity, reputation,judgment, experience and efficiency of the bidder. (4) The quality of performance of previous contracts. (5) The previous and existing compliance by the bidder with laws and ordinances relating to the contract; and WHEREAS, after careful review of the above, the City Manager recommends that the Administration be authorized to enter into negotiations as follows: Keith and Schnars, P.A., AECOM Technical Services, Inc., Zyscovich, Inc., and The Corradino Group, Inc., for the discipline of Planning and Urban Design Architecture. The City Manager does not recommend an award to Bermello, Ajamil & Partners in this group because of pending litigation with the City. Keith and Schnars, P.A., URS Corporation, E-Sciences, Inc., CB&I Environmental & Infrastructure, Inc., and Kimley-Horn and Associates, Inc., for the discipline of Environmental Engineering. Edward Lewis Architects, Inc., for the discipline of Interior Design and Space Planning Architecture. The City Manager does not recommend an award to Bermello, Ajamil & Partners in this group because of pending litigation with the City. Douglas Wood Associates, Inc., Stanley Consultants, Inc., Thornton Tomasetti, Inc., Brindley Pieters & Associates, Inc., and BCC Engineering, Inc., for the discipline of Structural Engineering. NOW, THEREFORE, BE IT DULY RESOLVED BY THE MAYOR AND CITY COMMISSION OF THE CITY OF MIAMI BEACH, FLORIDA, that the Mayor and City Commission hereby accept the recommendation of the City Manager pertaining to the ranking of proposals pursuant to Request For Qualifications (RFQ) No. 2014-346-YG, for Professional Architectural and Engineering Services In Specialized Categories On An As-Needed-Basis, for the disciplines of Planning and Urban Design Architecture, Environmental Engineering, Interior Design and Space Planning Architecture, and Structural Engineering; authorizing the Administration to enter into negotiations with Keith and Schnars, P.A., AECOM Technical Services, Inc., Zyscovich, Inc., and The Corradino Group, Inc., for the discipline of Planning and Urban Design Architecture; authorizing the Administration to enter into negotiations with Keith and Schnars, P.A., URS Corporation, E-Sciences, Inc., CB&I Environmental & Infrastructure, Inc., and Kimley-Horn and Associates, Inc., for the discipline of Environmental Engineering; authorizing the Administration to enter into negotiations with Edward Lewis Architects, Inc., for the discipline of Interior Design and Space Planning Architecture; authorizing the Administration to enter into negotiations with Douglas Wood Associates, Inc., Stanley Consultants, Inc., Thornton Tomasetti, Inc., Brindley Pieters & Associates, Inc., and BCC Engineering, for the discipline of Structural Engineering; further, should the Administration be unable to negotiate an agreement with any of the recommended firms, the Administration is authorized to negotiate with other ranked firms in order of rank in each category; and further authorizing the Mayor and City Clerk to execute an agreement upon conclusion of successful negotiations by the Administration. PASSED AND ADOPTED this 7 day of J4 2015. ATTEST: z. , R-fael . Granado Cit 1 Bic f, ilip -vines%►��ay;�r �i / s \P 1c �,,, • T:IAGENDA120151July1PR000RE 914 ..11"-YG!''•— siOnal Anvitectural and Engineering Services-Reso(Plan,Urban Design,Env• Eng,Int Design,Structural Eng).do INCORP ORATED: R )■.-7 . APPROVED AS TO FORM&LANGUAGE &FOR EXECUTION cao,...L,0„1= 11.1.(1.5 City Attorney Date COMMISSION ITEM SUMMARY Condensed Title: A RESOLUTION OF THE MAYOR AND CITY_ COMMISSION OF THE CITY OF MIAMI BEACH, FLORIDA, ACCEPTING THE RECOMMENDATION OF THE CITY MANAGER PERTAINING TO THE RANKING OF PROPOSALS PURSUANT TO REQUEST FOR QUALIFICATIONS (RFQ) NO. 2014-346-YG, FOR PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN AS-NEEDED-BASIS, FOR THE DISCIPLINES OF PLANNING AND URBAN DESIGN ARCHITECTURE, ENVIRONMENTAL ENGINEERING, INTERIOR DESIGN AND SPACE PLANNING ARCHITECTURE, AND STRUCTURAL ENGINEERING. Key Intended Outcome Supported: Streamline The Delivery Of Services Through All Departments Supporting Data (Surveys, Environmental Scan,etc: N/A Item Summa /Recommendation: The Administration issued RFQ 2014-346-YG to seek the proposals from consultants to provide Architectural and Engineering Services in Specialized Categories On An As-Needed-Basis, for projects in which construction costs do not exceed $2 Million or for study activities for which the fee does not exceed $200,000. The RFQ was approved for issuance by the City Commission on September 17, 2014. The RFQ was released on September 18, 2014. A pre-proposal conference to provide information to the proposers submitting a response was held on October 1, 2014. An additional pre-proposal conference was also held on October 13, 2014. On December 2, 2014, the City received proposals from fifty-one (51)firms. Via Resolution 2015-29041 passed and adopted June 10, 2015, the Mayor and City Commission accepted the City Manager's recommendation pertaining to the ranking of proposals for the disciplines of Landscape Architecture, General Architecture, Town Planning Architecture, Historical Preservation Architecture, Civil Engineering, Land Surveying, and Mechanical, Electrical, and Plumbing Engineering. This agenda item addresses an award recommendation for the following remaining disciplines: Planning and Urban Design Architecture, Environmental Engineering, Interior Design and Space Planning Architecture, and Structural Engineering. After reviewing the submission, the Evaluation Committee's rankings of proposals received and the City Code, the City Manager recommends that the Mayor and the City Commission, pursuant to RFQ No. 2014-346-YG, for Architectural and Engineering Services in Specialized Categories On An-Needed-Basis, authorize the Administration to enter into negotiations with the Proposers recommended for each discipline as noted beginning on page 5 of the attached memorandum. In the event that the Administration is unable to negotiate a mutually agreeable with any of the recommended firms, the City Manager recommends that the Mayor and City Commission authorize the Administration to negotiate with other ranked firms, in order of rank, in each category. Further, the City Manager recommends the Mayor and City Clerk be authorized to execute an Agreement upon conclusion of successful negotiations by the Administration. RECOMMENDATION Adopt the Resolution. Advisory Board Recommendation: N/A Financial Information: Source of Amount Account • Funds: 1 The cost of the related services, determined upon successful negotiations, are subject to funds availability approved through the City's budgeting process. OBPI City Clerk's Office Legislative Tracking: Alex Denis, Extension 6641 Sign-Offs: D/•ailment Director Assistant City Manager City er AS EC DM MT JL — ■ • T:IAGEN m #0151July1PROCUREMENT12014-346-YG RFQ-Professional Architectural and Engineering Services-Sumri a (Plan, Urban Design, Env Eng, t Design,Structural Eng).docx AGENDA ITEM C r al Eng).dN BATE 7-8-IS MIAMI BEACH . City of Miami Beach, 1700 Convention Center Drive,Miami Beach, Florida 33139, .miamibeachfl.gov C MMISSIO /MEMORANDUM TO: Mayor Philip Levine and Members of he City Comm sion FROM: Jimmy L. Morales, City Manager DATE: July 8, 2015 SUBJECT: A RESOLUTION OF THE MAYOR AND CITY COMMISSION OF THE CITY OF MIAMI BEACH, FLORIDA, ACCEPTING THE RECOMMENDATION OF THE CITY MANAGER PERTAINING TO THE RANKING OF PROPOSALS PURSUANT TO REQUEST FOR QUALIFICATIONS (RFQ) NO. 2014-346-YG, FOR PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN AS-NEEDED-BASIS, FOR THE DISCIPLINES OF PLANNING AND URBAN DESIGN ARCHITECTURE, ENVIRONMENTAL ENGINEERING, INTERIOR DESIGN AND SPACE PLANNING ARCHITECTURE, AND STRUCTURAL ENGINEERING. ADMINISTRATION RECOMMENDATION Adopt the Resolution. KEY INTENDED OUTCOME SUPPORTED Streamline The Delivery Of Services Through All Departments BACKGROUND Since June 9, 2010, the City has had contracts pursuant to Request for Qualifications (RFQ) 01-09/10 with various firms for professional architectural and engineering services in specialized categories on an "as-needed-basis". This contract provides access to architecture and engineering (A & E) firms in accordance with the requirements of the State of Florida, Consultant's Competitive Negotiation Act (CCNA). At its September 11, 2013 meeting, the Mayor and City Commission approved the recommendation of the Administration to exercise the last option for renewal of one (1) year, which extended the contract until September 29, 2014. Resolution 2014-28743, passed and adopted September 17, 2014, authorized the issuance of a new RFQ for professional architectural and engineering services in specialized categories on an "as-needed-basis". This resolution further authorized the Mayor and City Clerk to execute Amendment No. 1 to the Contracts executed pursuant to RFQ 01-09/10 to authorize month-to- month extensions until such time as a new RFQ process was completed and new contracts were executed. RFQ PROCESS On September 17, 2014, the City Commission approved the issuance of Request for Qualifications (RFQ) No. 2014-346-YG for Professional Architectural and Engineering Services in Specialized Categories On An "As-Needed-Basis". On September 18, 2014, the RFQ was issued. A pre-proposal conference to provide information to the proposers submitting a response was held on October 1, 2014. An additional pre-proposal conference was also held on October 13, 2014. RFQ responses were due and received on December 2, 2014. • Commission Memorandum Accepting the Recommendation of the City Manager Pertaining to the Ranking of Proposals-pursuant to Request For Qualifications(RFQ)No. 2014-346-YG, for Professional Architectural and Engineering Services In Specialized Categories On An As-Needed-Basis. July 8, 2015 Page 2 The City received proposals in response to the RFQ from the following fifty-one 51 firms: Y P P P 9 (51) AECOM Technical Services Marlin Engineering Bermello Ajamil & Partners, Inc. McHarry Associates BCC Engineering, Inc. Miller Legg BEA Architects MSA (Milian, Swain & Associates, Inc.) Bender&Associates Architects Pure Engineering Services Biscayne Engineering Company, Inc. R.J. Behar& Company, Inc. Brindley Pieters &Associates RAI CB&I Environmenatal & infrastructure Reines & Straz CES Consultants, Inc. RGD Chen Moore and Associates RJ Heisenbottle CIMA Robayna and Associates Coastal Systems International, Inc. Ross Engineering CPH, Inc. SBLM Architecs Craven Thompson and Associates Schwebke - Shiskin &Associates, Inc. Cummins Cederberg, Inc. Stanley Consultants Douglas Wood Stantec EAC Consulting, Inc. The Corradino Group ELA Architects Thorton Tomasetti E-Sciences TLC Engineering GFA International, Inc. Triangle Surveying Map Glavovic Studio URS Corporation HAKS Wade Trim Keith and Schnars, P.A. William B Medellin Architect P.A. Kimley Horn Wolfberg Alvarez and Partners Kobi Karp Zyscovich Architects Lockwood, Andrews & Newman, Inc. On June 10, 2015, via Resolution 2015-29041, the Mayor and City Commission accepted the City Manager's recommendation pertaining to the ranking of proposals for the following disciplines/groups: Group 1 - Landscape Architecture; Group 2 - General Architecture, Town Planning Architecture and Historical Preservation Architecture; Group 3 - Civil Engineering and Land Surveying; and Group 4: Mechanical, Electrical, and Plumbing Engineering. This agenda item only addresses an award recommendation for the following remaining disciplines/groups: Group 1 - Planning and Urban Design Architecture and Environmental Engineering; Group 2: Interior Design and Space Planning Architecture; and Group 4: Structural Engineering. On February 5, 2015, the City Manager appointed the Evaluation Committee via LTC # 054- 2015, which included evaluation committee members for each category group. The Evaluation Committee (the"Committee")for these groups consisted of the following individuals: GROUP 1 — PLANNING AND URBAN DESIGN ARCHITECTURE, AND ENVIRONMENTAL ENGINEERING • Margarita Wells, Environment and Sustainability Specialist, Building Department, City of Miami Beach • Rogelio Madan, Principal Planner, Planning Department, City of Miami Beach • Humberto Cabanas, Division Director, CIP, City of Miami Beach Commission Memorandum Accepting the Recommendation of the City Manager Pertaining to the Ranking of Proposals pursuant to Request For Qualifications(RFQ)No. 2014-346-YG,for Professional Architectural and Engineering Services In Specialized Categories On An As-Needed-Basis. July 8, 2015 Page 3 GROUP 2—INTERIOR DESIGN/SPACE PLANNING ARCHITECTURE • Deborah Tackett, Preservation and Design Manager, Planning Department, City of Miami Beach • Rogelio Madan, Principal Planner, Planning Department, City of Miami Beach • Valeria Mejia, ADA Coordinator, Property Management, City of Miami Beach GROUP 4—STRUCTURAL ENGINEERING • Sabrina Baglieri, Sr. Capital Projects Coordinator, CIP, City of Miami Beach • Oniel Toledo, Construction Manager, Public Works, City of Miami Beach • Jose Perez, Capital Projects Coordinator, CIP, City of Miami Beach For Group 1 — Planning and Urban Design Architecture, the Committee convened on February 26, 2015 to consider proposals received to score and rank each proposal pursuant to the evaluation criteria established in the RFQ. The evaluation process for the proposals received resulted in the ranking of proposers as indicated below. RFQ#2014-346-YG Professional Architectural and Engineering Services LOW (PLANNING&URBAN DESIGNS Margarita Rogelio Humberto AGGREGATE Wells Ranking Madan Ranking Cabanas Ranking TOTALS Rank KEITH AND SCHNARS, P.A. 96 1 95 1 93 1 3 1 AECOM TECHNICAL SERVICES,INC. 82 2 88 2 87 3 7 2 BERMELLO,AJAMIL& PARTNERS,INC. 79 5 78 3 88 2 10 3 ZYSCOVICH,INC. 80 4 78 3 85 4 11 4 THE CORRADINO GROUP,INC. 82 2 75 5 81 5 _ 12 5 Commission Memorandum Accepting the Recommendation of the City Manager Pertaining to the Ranking of Proposals pursuant to Request For Qualifications(RFQ) No. 2014-346-YG,for Professional Architectural and Engineering Services In Specialized Categories On An As-Needed-Basis. July 8, 2015 Page 4 For Group 1 — Environmental Engineering, the Committee convened on February 26, 2015 to consider proposals received to score and rank each proposal pursuant to the evaluation criteria established in the RFQ. The evaluation process for the proposals received resulted in the ranking of proposers as indicated below_. RFQ#2014-346-YG Professional Architectural and Engineering Services. LOW (ENVIRONMENTAL Margarita Rogelio Humberto AGGREGATE . ENGINEERING) Wells Ranking Madan Ranking Cabanas Ranking • TOTALS Rank KEITH AND SCHNARS, P.A. 96 1 99 2 94 1 4 1 URS CORPORATION 93 2 100 1 88 4 7 2 E-SCIENCES,INC. 89 4 80 4 89 2 10 3 CB&I ENVIRONMENTAL& INFRASTRUCTURE,INC. 92 3 88 3 87 5 11 4 KIMLEY-HORN AND ASSOCIATES,INC. 83 5 79 6 89 2 13 5 GFA INTERNATIONAL, INC. 82 6 80 4 76 8 18 6 STANTEC CONSULTING SERVICES,INC. 82 6 79 6 83 6 18 6 CUMMINS CEDERBERG, INC. 61 8 57 8 80 7 23 8 • For Group 2 — Interior Design and Space Planning, the Committee convened on March 19, 2015 to consider proposals received to score and rank each proposal pursuant to the evaluation criteria established in the RFQ. The evaluation process for the proposals received resulted in the rank_ing of proposers as indicated below. RFQ#2014-346-YG Professional . Architectural and Engineering Services LOW (INTERIOR DESIGN& . Deborah Rogelio Valeria AGGREGATE SPACE PLANNING) Tackett , Ranking Madan Ranking Mejia , Ranking TOTALS Rank BERMELLO AJAMIL& PARTNERS,INC. 92 1 92 1 88 1 3 1 EDWARD LEWIS ARCHITECTS,INC. 78 2 73 2 70 2 6 2 Commission Memorandum Accepting the Recommendation of the City Manager Pertaining to the Ranking of Proposals pursuant to Request For Qualifications(RFQ) No. 2014-346-YG,for Professional Architectural and Engineering Services In Specialized Categories On An As-Needed-Basis. July 8, 2015 Page 5 For Group 4—Structural Engineering, the Committee convened on April 8, 2015 to consider proposals received to score and rank each proposal pursuant to the evaluation criteria established in the RFQ. The evaluation process for the proposals received resulted in the ranking of proposers as indicated below. RFQ#2014-346-YG Professional Architectural and Engineering LOW Services Oniel Jose A. Sabrina AGGREGATE (STRUCTURAL ENGINEERING) Toledo Ranking Perez Ranking Baglieri Ranking TOTALS Rank DOUGLAS WOOD ASSOCIATES,INC. 100 1 94 1 94 4 6 1 STANLEY CONSULTANTS,INC. 100 1 91 3 96 2 6 1 THORNTON TOMASETTI,INC. 97 3 90 4 97 1 8 3 BRINDLEY PIETERS&ASSOCIATES, INC. 95 4 92 2 93 5 11 4 BCC ENGINEERING,INC. 90 5 89 5 95 3 13 5 CES CONSULTANTS,INC. 70 6 86 6 77 7 19 6 HAKS ENGINEERS,ARCHITECTS AND LAND SURVEYORS,P.C. 60 7 _ 80 7 78 6 20 7 Because of the large number of response for certain disciplines and the projected volume of work, staff is recommending that no more than five (5)firms be awarded in each category. MANAGER'S DUE DILIGENCE & RECOMMENDATION The City Manager has considered the proposals received, the results of the evaluation committee process and Section 2-369 of the City Code which states that in the award of contracts the following shall be considered: (1) The ability, capacity and skill of the bidder to perform the contract. (2) Whether the bidder can perform the contract within the time specified, without delay or interference. (3) The character, integrity, reputation,judgment, experience and efficiency of the bidder. (4) The quality of performance of previous contracts. (5) The previous and existing compliance by the bidder with laws and ordinances relating to the contract. After careful review of the above, the City Manager recommends that the Administration be authorized to enter into negotiations as follows: Keith and Schnars, P.A., AECOM Technical Services, Inc., Zyscovich, Inc., and The Corradino Group, Inc., for the'discipline of Planning and Urban Design Architecture. The City Manager does not recommend an award to Bermello, Ajamil & Partners in this group because of pending litigation with the City. Keith and Schnars, P.A., URS Corporation, E-Sciences, Inc., CB&I Environmental & Infrastructure, Inc., and Kimley-Horn and Associates, Inc., for the discipline of Environmental Engineering. Edward Lewis Architects, Inc., for the discipline of Interior Design and Space Planning Architecture. The City Manager does not recommend an award to Bermello, Ajamil & Partners in this group because of pending litigation with the City. Douglas Wood Associates, Inc., Stanley Consultants, Inc., Thornton Tomasetti, Inc., Brindley Pieters & Associates, Inc., and BCC Engineering, Inc., for the discipline of Structural Engineering. Commission Memorandum Accepting the Recommendation of the City Manager Pertaining to the Ranking of Proposals pursuant to Request For Qualifications(RFQ)No. 2014-346-YG,for Professional Architectural and Engineering Services In Specialized Categories On An As-Needed-Basis. July 8, 2015 Page 6 In the event that the Administration is unable to negotiate a mutually agreeable with any of the recommended firms, the City Manager recommends that the Mayor and City Commission authorize the Administration to negotiate with other ranked firms, in order of rank, in each category. The City Manager further recommends that the Mayor and City Clerk be authorized to execute an agreement upon conclusion of successful negotiations by the Administration. • CONCLUSION The Administration recommends that the Mayor and City Commission of the City of Miami Beach, Florida accept the recommendation of the City Manager pertaining to the ranking of proposals pursuant to Request for Proposals (RFP) 2014-346-YG for Professional Architectural and Engineering Services in Specialized, on an. as needed basis for the disciplines of Planning and Urban Design Architecture, Environmental Engineering, Interior Design and Space Planning Architecture, and Structural Engineering. JLM/MT DM/ EC/AD/YG T:\AGENDA\20151July1PROCUREMENT12014-346-YG RFQ-Professional Architectural and Engineering Services-Memo(Plan,Urban Design, Env Eng,Int Design,Structural Eng).docx • ATTACHMENT B REQUEST FOR QUALIFICATIONS (RFQ) 34 MIAMI BEACH City of Miami Beach, 1700 Convention Center Drive,Miami Beach,Florida 33139,www.miamibeachfi.gov DEPARTMENT OF PROCUREMENT MANAGEMENT Tel: 305-673-7490 Fax: 786-394-4002 ADDENDUM NO. 8 _ REQUEST FOR QUALIFICATIONS NO. 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN"AS-NEEDED-BASIS"(the"RFQ") NOVEMBER 24, 2014 This Addendum to the above-referenced RFQ is issued in response to questions from prospective proposers, or other clarifications and revisions issued by the City. The RFQ is amended in the following particulars only. 1. RFQ DUE DATE AND TIME. As a reminder to all Proposers, the deadline for the receipt of proposals is UNTIL 3:00 P.M., ON TUESDAY, DECEMBER 2, 2014, at the following location. Miami Beach City Hall Procurement Department 1700 Convention Center Drive, 3rd Floor Miami Beach, Florida 33139 Late proposals will not be accepted. Proposers are cautioned to plan sufficient time to allow for traffic or other delays for which the Proposer is solely responsible. 2. ANSWERS TO ADDITIONAL QUESTIONS RECEIVED. Q1: Proposer dropped off two proposal packages on November 4, 2014. Proposer received Addendum 7 and read that the due date has been extended to December 2. Proposer would like to know if it is okay to leave the package in the Procurement office `til then. Proposer also wanted to know that since its packages were dropped off on November 4, 2014, if Proposer's signature on the addendums is not required for Addendums 4, 5&6. Al: Proposers who have already submitted their Proposal package, prior to the release of Addendum No. 7, may leave their Proposal package in the Procurement Department. To acknowledge receipt of Addendums 4 through 8 (which includes this addendum), Proposers may submit a revised Page 4 from Appendix A in a sealed envelope to the Procurement Department. Or, Proposers may also wait for the Proposal evaluation period when the Procurement Department will request any missing documentation from the Proposer, which will include acknowledgement of published addendums. Q2: Some clarification is still needed on Question #71 in Addendum No. 7. If using a 330 form for TAB 2, Section 2.1 /2.2 — Do we need to re-arrange the order of the 330 form to reflect the order requested? The answer provided in Addendum No. 7 does not clarify the way it should be arranged. Can a clause page be included before these sections that states: "Sections 2.1 and 2.2 are covered in the following 330 form" instead of re-arranging the order of the standard 330 form? A2: The order of Standard Form 330 should not be re-arranged. As indicated in Tab 2, Page 12 of the RFQ, "Proposers may submit the below requested information utilizing the enclosed Standard Form 330 — Architect-Engineer Qualifications". In its response, Proposer may include a page indicating that the information requested in Sections 2.1 and 2.2 of Tab 2 is shown in Standard Form 330 and immediately following include the completed form. Proposer shall indicate which sections of Standard Form 330 correspond to Section 2.1 and 2.2 of Tab 2. Page 1 of 2 2 ( Miami Beach ADDENDUM NO.8 RFQ 2014-346-SR PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN"AS-NEEDED-BASIS" Q3: Would you consider re-formulating this RFQ from scratch and putting out a new deadline? This might serve both the City's and the potential proposers' interests best. A3: No, the City will not consider this option. Any questions regarding this Addendum should be submitted in writing to the Procurement Management Department to the attention of the individual named below, with a copy to the City Clerk's Office at RafaelGranado @miamibeachfl.gov. Procurement Contact Telephone: Email: Yusbel Gonzalez 305-673-7000, ext. 6230 YusbelGonzalez @miamibeachfl.gov Proposers are reminded to acknowledge receipt of this addendum as part of your RFQ submission. Potential proposers that have elected not to submit a response to the RFP are requested to complete and return the "Notice to Prospective Bidders" questionnaire with the reason(s) for not submitting a pro• - . Oft -446 Denis Procurement Director • MiAMI BEACH City of Miami Beach, 1700 Convention Center Drive,Miami Beach,Florida 33139,www.miamibeochfl.gov DEPARTMENT OF PROCUREMENT Tel: 305-673-7490 Fax: 786-394-4002 ADDENDUM NO. 7 REQUEST FOR QUALIFICATIONS NO. 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN"AS-NEEDED-BASIS" (the "RFQ") NOVEMBER 18, 2014 This Addendum to the above-referenced RFQ is issued in response to questions from prospective proposers, or other clarifications and revisions issued by the City. The RFQ is amended in the following particulars only. 1. RFQ DUE DATE AND TIME.The deadline for the receipt of proposals is extended UNTIL 3:00 P.M. ON TUESDAY, DECEMBER 2, 2014, at the following location. Miami Beach City Hall Procurement Department 1700 Convention Center Drive, 3`d Floor Miami Beach, Florida 33139 Late proposals will not be accepted. Proposers are cautioned to plan sufficient time to allow for traffic or other delays for which the Proposer is solely responsible. 2. DELETION. The following specialized areas of the RFQ have been deleted: • "Geotechnical", under Group B—Engineering, from Section 0200, Sub-Section 2. Purpose. "Acoustics, Noise Abatement"from Appendix C, Sub-Section C2., Scope of Work. "Storage Tank Repair and Monitoring"from Appendix C, Sub-Section C2., Scope of Work. 3. ADDITION. The following clause has been added to Appendix D—Special Conditions: 13. COMPETITIVE SPECIFICATIONS. It is the goal of the City to maximize competition for the project among suppliers &contractors. Consultant shall endeavor to prepare all documents, plans & specifications that are in accordance with this goal. Under no condition shall Consultant include means & methods or product specifications that are considered "sole source" or restricted without prior written approval of the City. ANSWERS TO QUESTIONS RECEIVED FROM PROSPECTIVE PROPOSERS: Q1: TAB 2 reads that proposers may submit the information requested under that Tab utilizing the SF330. Then item 2.1 of said Tab asks for 5 projects performed by the firm in the last five years. The SF 330 instruction usually allows for users to provide 10 projects. Does this mean the City is asking for 10 projects, or is it limiting the projects to 5? Could you please clarify? Al: Per Page 12 of the RFQ, Tab 2, Item 2.1, the Proposing Firm is only required to "submit five (5) relevant projects, performed in the last five (5) years as evidence of experience;"It is up to the Proposer's discretion should they want to list more than five relevant projects. 1 Q2: Section C1. Minimum Requirements under Appendix C, the first bullet states "Proposer must have a minimum of five (5) years' experience and successfully completed at least five (5) projects for public sector agencies." Please clarify the City's definition of "successfully completed". Is this completion of the design or substantially completed in construction? A2: Successfully completed refers to successful completion of the project in the design phase. Q3: Are complete AlE teams, including sub-consultants, required for this RFQ submission? Due to the fact that the specific projects to be awarded under all categories are unknown at this time, as well as the fact that this is a minimum three-year contract term,we strongly feel it would be in the City's best interest to allow prime firms to submit without sub- consultants in order to allow future flexibility in selecting the best possible sub-consultant team for each specific task order's scope. A3: In accordance with Page 13 of the RFQ, Tab 3 —Approach and Methodology, "It is the objective of the City that the majority of the services defined herein be performed directly by the Proposer (rather than through sub-consultants). To evaluate compliance with this objective, proposers shall explain how they plan to accomplish this, denoting which sections of the scope shall be performed directly by the Firm (with its own forces) and which sections are intended to be subcontracted." After award of contract, the prime Proposer would be allowed to add sub-consultants for each specific task as necessary and approved by the City through the City Manager. Q4: Do Form Based Code services fall under the Town Planning or Planning and Urban Design category. A4: Form based code services are not being sought at this time. Should a need arise in the future, the City may consider all its options, including (but not limited to) selecting a consultant pursuant to this RFQ or releasing a separate solicitation. Q5: Please provide copies of all sign in sheets scanned and have them sent out as an addenda as soon as possible. A5: Sign-in sheets for both pre-proposal conferences are attached to this addendum. Q6: At the pre-proposal conference, several firms asking for a deadline extension, especially because there is still the lingering question about team and grouping within a category or in multiple categories. We certainly would like to be informed of a deadline extension, as it could possibly impact the decision of small firms to pursue this solicitation. A6: As indicated in page 1 of this addendum, the deadline for receipt of proposals has been extended to Tuesday, December 2, 2014 at 3:00 PM. Proposers must be registered with Public Purchase to ensure receipt of all addenda. Q7: If we submit for more than one category, are we going to have to prepare a proposal for each or can we submit together(one proposal for all applicable categories)? A7: Per RFQ Section 0300—Submittal Instructions and Format, sub-section 3: Proposals shall clearly indicate if qualifications are being sought under Group A — Architecture and/or Group B — Engineering. Furthermore, firms are required to submit separate proposals for each specialized category under the respective 2 group for which they seek qualifications. Example: a firm which provides landscape architecture and interior design/space planning, shall respond under Group A — Architecture and shall submit two (2) proposals under said group; a proposal seeking qualifications under landscape architecture and a proposal seeking qualifications under interior design/space planning. Q8: Can we use our SF-330 which has the colors of our firm but is the exact same form? A8: Yes, that is allowed as long as the structure and contents of the form has not changed. Q9: We provide GiS services but have no Survey Department, can we submit a proposal or will you create a separate category for GIS? A9: Per this RFQ, the GIS services are limited to Survey and collecting GIS features. The City anticipates creating a separate broader GiS RFQ in the future. Q10: Will the relevant experience still be completed projects or can ongoing projects be included (discrepancy between page 12 and Appendix C) A10: Per Appendix C, Section C.1, Minimum Requirements, the relevant project experience must be for successfully completed projects. Q11: To follow up on the discussion at yesterday's Pre-Bid meeting,we would like to know if we can submit for Multiple Categories in one package. For example: Civil and Environmental in Group B - Engineering. This would greatly reduce the work effort (not to mention excess paper!) for both the City and the consultants. If this is not possible, then we respectfully request that you consider a time extension to allow firms adequate time to prepare numerous submissions. • A11: Please refer to the answer written for Question #7 in this Addendum. Q12: Please indicate teaming restrictions, if any, on sub-consultants. Thank you. Al2: Per Page 13 of the RFQ, Tab 3, "it is the objective of the City that the majority of the services defined herein be performed directly by the Proposer (rather than through sub-consultants). To evaluate compliance with this objective, proposers shall explain how they plan to accomplish this, denoting which sections of the scope shall be performed directly by the Firm (with its own forces) and which sections are intended to be subcontracted.". As indicated above, Proposers must clearly indicate in their proposal which sections of the scope will be performed directly by the Firm (with its own forces) and which sections are intended to be subcontracted. Q13: Section 0300 3. Statements of Qualifications Format. Tab 1 - Item 1.3 Minimum Qualification Requirements (a), Requires LEED, ULi, AICP,APA Certifications for Planning, Urban and Historical Preservation Architects. Please clarify why Historic Preservation architects require such certifications. • A13: Please note that, pursuant to Appendix C, section C1. Minimum Requirements, Planning, Urban, and Historical Preservation Architects certified by or members of LEED, ULI, AICP, APA is a preference and not a requirement. As such, firms that do not have architects certified by or members of LEED, ULI, AICP, APA will not be penalized. 3 Q14: Please clarify the ambiguity in the RFQ 2014-346-YG as to teaming: whether an architectural firm can submit as a lead firm with a roster of subconsultants who, together, cover specialties in both of the listed areas. Also, please clarify whether subconsultants can, in their turn, use specialty subconsultants to cover any gaps in their own team's expertise. A14: While proposers are not precluded from including sub-consultants as part of its team, per Page 13 of the RFQ, Tab 3, "It is the objective of the City that the majority of the services defined herein be performed directly by the Proposer (rather than through sub-consultants). To evaluate compliance with this objective, proposers shall explain how they plan to accomplish this, denoting which sections of the scope shall be performed directly by the Firm (with its own forces) and which sections are intended to be subcontracted." Q15: Regarding the RFQ for Professional Architectural and Engineering Services in Specialized Categories on an "As-Needed Basis", will there be an additional addendum published addressing the teaming clarification that was brought up during the first pre-proposal meeting? The second meeting is not until 10/13 and the RFQ packages are due on 10/23; this is a very small time-frame to gather a team if need be. A15: Please refer to the answer written for Question #3 and #14 in this addendum. As indicated in page 1 of this addendum, the deadline for receipt of proposals has been extended to Tuesday, December 2, 2014 at 3:00 PM. Proposers must be registered with Public Purchase to ensure receipt of all addenda. Q16: For submission for Environmental Engineering, the City states per the RFQ that it is searching for submissions in the following sub-categories: general environmental services, environmental & coastal permitting, and contamination assessment. According to your Environmental Department representative, the City prefers for a firm to do this in- house, correct? If we cannot do all these 3 services in-house, can we submit just to the 1 service that we are able to do in-house, or does the City prefer that we team with sub- consultants to be able to submit for all 3 services under Environmental Engineering? A16: In accordance with RFQ Page 13, Tab 3 —Approach and Methodology, "It is the objective of the City that the majority of the services defined herein be performed directly by the Proposer(rather than through sub-consultants). To evaluate compliance with this objective, proposers shall explain how they plan to accomplish this, denoting which sections of the scope shall be performed directly by the Firm (with its own forces) and which sections are intended to be subcontracted." In accordance with the above language, the City prefers that Proposers perform services in- house (with its own forces); however should they be unable to, Proposers must indicate which sections of the scope will be subcontracted. Q17: Under section C2. Scope of Work required, does Coastal Engineering and Coastal Surveys fall under the Civil Engineering discipline? A17: Yes, Coastal Engineering and Coastal Surveys fall under Civil Engineering. Q18: Please confirm that if we are to submit to Civil and Environmental Engineering, that the City requires 2 separate proposals. A18: Please refer to the answer written for Question #7 in this Addendum. 4 Q19: The question is regarding whether the City expects a complete team to be put together for each of the categories depending on the types of projects. For example, if the City intends on doing a pump station project under the Civil Group, do we need to include electrical and mechanical resumes or firms on our team for that category? A19: As part of their submittal, a Civil Engineering firm may include in its proposal qualifications of mechanical and electrical engineers. Please note however, per Page 13 of the RFQ, Tab 3, "It is the objective of the City that the majority of the services defined herein be performed directly by the Proposer (rather than through sub-consultants). To evaluate compliance with this objective, proposers shall explain how they plan to accomplish this, denoting which sections of the scope shall be performed directly by the Firm(with its own forces) and which sections are intended to be subcontracted" Q20: Is a submittal required for each category a firm may be interested in under Groups A& B? A20: Please refer to the answer written for Question #7 in this Addendum. Q21: Are firms permitted to develop a comprehensive team for each category. A21: Please refer to the answer written for Question#3 and #14 in this addendum. Q22: Are there teaming restrictions? Can a prime firm go as a subconsultant to a firm for any category? A22: Please refer to the answer written for Question# 12 in this Addendum. Q23: I have an inquiry regarding what defines the "General" under the Group A - Architecture Category. Is there a list breakdown of services that can be provided to demonstrate/define "General"? A23: General Architecture is defined as the planning, programming, design, preparation of construction documents, permitting and construction supervision for single and multi-purpose facilities and their sites. These facilities may include, but may not be limited to: parking garages, park facilities, fleet maintenance and storage buildings, etc. Q24: At the top of Page 13 of RFQ 2014-346-YG it indicates that a copy of staff's accredited college diploma or bachelor's degree in Environmental Sciences or related field should be provided for Environmental Engineering Firms. I have two questions: Can a Florida licensed Professional Engineer's certificate satisfy this criteria as Florida licenses PEs only with degrees in engineering from accredited schools? Will an official transcript or other documentation from the school suffice in lieu of a copy of a diploma if that transcript/document clearly states that the individual received a bachelor's degree in an environmental science or related field? A24: Yes, a Florida licensed Professional Engineer's certificate may be provided. Environmental Engineering firms providing General Environmental Services, Environmental and Coastal Permitting, and Contamination Assessment, must provide copies of the following: Staff's accredited college diploma or Bachelor's degree in Environmental Sciences or related field. Q25: It is a burden on the firms to submit multiple proposals for one, the architecture and engineering categories and then also for the subcategories. It will also slow down the review process by the City. Will the city consider providing a check list for areas of interest and in which the firms are qualified for and for it to be included in the proposal? 5 A25: Please refer to the answer written for Question #7 in this Addendum. Q26: The RFQ states that Landscape Architects must be certified by the International Society of Arboriculture, Landscape Inspectors Association of Florida and FNGLA. These are not certifications normally held by Landscape Architects. Can an ISA certified Arborist be added as a sub consultant to satisfy this requirement? A26: Yes. Q27: If the submitting firm desires to submit proposals for multiple categories, would the City consider allowing the submitting firm to submit one proposal in which the firm describes what categories they may qualify for? It is not clear in the RFP if the City's intent is for submitting firms to form teams. For example, it is typical for a Civil engineering firm to submit as part of its team a surveyor and geotechnical firm that they have a working relationship with. Is it the City's intent to pair firms qualified under separate categories to complete a task order under this contract? Furthermore, the RFP encourages that the submitting firm should self-perform the work proposed under the desired category, however it goes on to encourage the use of DBE sub-consultants. This is somewhat contradictory, Please clarify? A27: Please refer to the answer written for Question #3, #7, and #14 in this Addendum. Q28: If the instructions in the RFQ prevail and proposers are to submit one individual proposal (1-original/11 copies) per discipline, would the City consider giving an extension of the current deadline or staggering the due dates for each the disciplines (e.g. civil, structural, environmental, mechanical etc)? A28: Please refer to the answer written for Question # 7 in this Addendum. As indicated in page 1 of this addendum, the deadline for receipt of proposals has been extended to Tuesday, December 2, 2014 at 3:00 PM. Proposers must be registered with Public Purchase to ensure receipt of all addenda. Q29: Will a State issued DBE certification suffice as"verifiable evidence" of Proposer's intent to use DBEs on this contract? A29: Yes. Per Page 13 of the RFQ, Tab 3 —Approach and Methodology, "Accepted DBE certifications include the Small Business Administration (SBA), State of Florida, or Miami-Dade County." Q30: Do the 5 projects being requested as "Qualifications of Proposing Firm", Tab 2-Section 2.1, need to be completed? A30: Yes. Per Appendix C, Section C.1, Minimum Requirements, the relevant project experience must be for successfully completed projects. Q31: Do the 5 projects being requested as "Qualifications of the Proposer Team (Architects and Engineers)Tab 2-Section 2.2, need to be completed? A31: Yes. Per Appendix C, Section C.1, Minimum Requirements, the relevant project experience must be for successfully completed projects. Q32: Is it the intent of the RFQ that submitting firms only show 5 relevant projects in the SF 330, as requested in Tab 2-Section 2.1? 6 A32: Please refer to the answer written for Question# 1 in this Addendum. Q33: In speaking to D & B they say an SQR is not something most people are subscribed, but a Comprehensive Report can substitute in many cases since they are similar. Is the SQR mandatory or is there an alternative? A33: The submittal of the SQR is mandatory. Per Page 12 of the RFQ, Tab 2, Item # 2.3, "Each proposer shall arrange for Dun & Bradstreet to submit a Supplier Qualification Report (SQR) directly to the Procurement Contact named herein. No proposal will be considered without receipt, by the City, of the SQR directly from Dun &Bradstreet." Q34: Is the 2"d underlined area a repetitive requirement of the 1St underlined area? Or are you requesting 2 different sets of five (5) relevant projects? RFQ Page 12 2.1 Qualifications of Proposing Firm. Submit detailed information regarding the firm's history and relevant experience and proven track record of providing the scope of services as identified in this solicitation, including experience in providing scope of services to public sector agencies. Proposer must submit five(5) relevant proiects, performed in the last five (5) years as evidence of experience; the following is required: project description, agency name, agency contact, contact telephone & email, and year(s)and term of engagement. 2.2 Qualifications of Proposer Team (Architects and Engineers). Provide an organizational chart of all personnel and consultants to be used for this project if awarded, the role that each team member will play in providing the services detailed herein and each team members'qualifications. A resume of each individual, including education, experience, and any other pertinent information, shall be included for each respondent team member to be assigned to this contract. For each architect and engineer, include information for five (5) relevant proiects, performed in the last five(5)years for public sector clients. Relevant proiects shall include those proiects similar in scope to those services listed in this RFQ. A34: The requirements indicated in Page 12 of the RFQ, Tab 2, Item # 2.1 are applicable to the "Proposing Firm". The requirements indicated in Page 12 of the RFQ, Tab 2, Item # 2.2 are applicable to the "Architect and Engineer"in each firm/team. Q35: If we are to have D&B send the SQR directly to the City what information should we include in this tab for our submittal? 2.3 Financial Capacity. Each proposer shall arrange for Dun & Bradstreet to submit a Supplier Qualification Report(SQR) directly to the Procurement Contact named herein. No proposal will be considered without receipt, by the City, of the SQR directly from Dun & Bradstreet. A35: Given that the SQR must be submitted directly to the Procurement Contact named in the RFQ, Proposers are not required to include information in their proposal under Item # 2.3 of Tab 2, Page 12 of the RFQ. Q36: Do relevant projects have to be completed projects or can they be currently in progress? A36: Please refer to the answer written for Question # 10 in this Addendum. 7 Q37: Under Section C1. MINIMUM REQUIREMENTS: Planning, Urban, and Historical Preservation Architects certified or members of LEED, ULI, AICP, APA is preferred. However, since this is the City's preference and not a minimum requirement, if the firm does not hold any of these certifications will the proposal be deemed non-responsive and not be considered? A37: No, this is a preference and not a requirement. Q38: Given that many firms will be able to Prime various disciplines in Group A and Group B, would the City consider changing the requirements in the current RFQ and requesting that one proposal address all the disciplines for which the firm is able to Prime? A38: Please refer to the answer written for Question # 7 in this Addendum. Q39: Our firm is submitting proposals in four disciplines and our corporate offices are questioning the need for 4 separate Dun & Bradstreet SQR Reports. Can we submit one for the firm since they are costly, and the information will be the same on all four? A39: Yes. Q40: If the City intends to select twelve separate firms, then will the City be providing the coordination between disciplines or will one of the twelve firms be required to provide the overall coordination? A40: The City is not limited to awarding only one Proposer per specialized category. The City may award more than one Proposer per specialized category. When professional services are required, a proposed project will be analyzed in terms of the predominant professional specialty required, and a firm will be selected by the City from the appropriate specialization list. The prime proposer will be responsible to hire the applicable or required sub-consultants and coordinate the work. Q41: If the City intends to select twelve separate firms, then why does the sample contract call for written approval of all sub-consultants? A41: Please note that the City does not intend to select only twelve separate firms (firm per specialized area). Multiple firms may be qualified per category. Proposers are not precluded from including sub-consultants as part of its team. Per Page 13 of the RFQ, Tab 3, "It is the objective of the City that the majority of the services defined herein be performed directly by the Proposer(rather than through sub-consultants). To evaluate compliance with this objective, proposers shall explain how they plan to accomplish this, denoting which sections of the scope shall be performed directly by the Firm (with its own forces) and which sections are intended to be subcontracted." As indicated in the last part of the above cited language, Proposers shall indicate the sections of the services the Proposer intends to sub-contract. Q42: If the City intends to select A/E Teams already put together by the Consultant, then why does the RFQ require each discipline to submit separate proposals? This would result in twelve (12) original proposals and one hundred and twenty (120) copies be submitted for one full A/E Team of all disciplines. A42: Please refer to the answer written for Question #7 in this Addendum. 8 Q43: Is it the City's intent to select Architecture/ Engineering Teams for this contract or to make twelve (12) separate selections of firms, one for each discipline listed on page 3 of the RFQ and require these twelve firms to work together as a team? Of course a firm could be selected for more than one discipline... A43: The City is not limited to awarding only one Proposer per specialized category. The City may award more than one Proposer per specialized category. Q44: Is it possible to get a copy of the attendee list for both pre-proposal meetings or will they be posted online? A44: Copies of the sign-in sheets for both pre-proposal meetings are attached to this Addendum. Q45: If a firm was interested in pursuing Park work, which category should they submit under, "Landscape"or"Planning and Urban Design"? A45: A firm may submit under both categories. A firm designing a Park, will need to have planners/urban designers. If the firm is only interested in doing the landscaping for the Park, then they may submit under Landscape only. Q46: We will be submitting for the Civil category with subs that will be needed to carry out the task. How will our proposal be evaluated in relation to the proposal submitted by an architectural team who will have sub-consultants which may also include civil? A46: All proposals will be evaluated in accordance with the evaluation criteria stipulated in Section 0400—Statements of Qualifications Evaluation, Page 14 of the RFQ. Q47: Tab 2 (Section 2.2- Qualifications of Proposer Team) — Do we have to provide 5 relevant projects for each of the sub-consultants on our team? A47: Section 2.2 of Tab 2 indicates: "For each architect and engineer, include information for five (5) relevant projects, performed in the last five (5) years for public sector clients. Relevant projects shall include those projects similar in scope to those services listed in this RFQ." If the sub- consultant team includes architects and engineers, then Proposer shall also list five (5) relevant projects in the last five (5) years for public sector clients. Q48: Minimum Qualifications Requirements, C1 Minimum Requirements. Architects and engineers must be licensed by the Florida Department of Business and Professional Regulation. -Landscape Architects must be certified by International Society of Arboriculture Certification, Landscape Inspectors Association of Florida Certification, FNGLA Certification. Are Landscape Architects are specifically required to have all three additional certifications? Typically the Florida Department of Business Landscape Architecture Professional Regulation License will suffice in lieu of these requirements. A48: The Florida Department of Business Landscape Architecture Professional Regulation License is acceptable. 9 • Q49: We will be submitting for Mechanical, Electrical, and Plumbing — You stated that you all prefer that each discipline be submitted separately; When I submit my staff and firms qualifications for each discipline, how exactly to you all want that formatted? A49: Please refer to the "Clarification" provided in Page 1 of this Addendum. Also, please refer to RFQ Page 11, Section 0300—Submittal Instructions and Format. Q50: City mentioned at the second pre-proposal conference that the deadline may be pushed back — can you please tell me where I can find the answers to my questions and also see the answers to the other attendees questions? A50: This addendum contains responses to all questions received prior to the deadline for receipt of questions and clarifications. Proposer must be registered with Public Purchase to ensure receipt of this addendum. Q51: Can you tell us who will be on the selection committee? A51: This information is unknown at this moment. Q52: Page 12, Tab 1, 1.3 item d) a — it will be very difficult to obtain copies of our environmental staff's diplomas in a timely manner. Will copies of their licenses and certifications suffice? A52: Please refer to the answer provided for question#24 in this Addendum. Q53: Page 12, Tab 2, 2.1 — For each project we have to provide the "year(s) and term of engagement." What exactly are you looking for w/regards to"term of engagement"? A53: Term of engagement refers to the term (number of months or years) the firm was engaged in a particular project or assigned task. Q54: Page 12, Tab 2, 2.3 - Our accounting staff attempted to arrange for Dunn & Bradstreet to submit a SQR to you; however, the D&B site requires your "user name." Can you please provide us w/this as soon as possible? A54: The"user name" is the same as the"email address": vusbelqonzalezmiamibeachfl.qov Q55: Appendix C, C.2 Scope of Work Required — In addition to environmental and geotechnical services, our firm provides the following services that are listed in your scope of work: lab testing services as well as testing and inspection services. Typically the lab testing can fall under geotechnical and construction materials testing (CMT) whereas testing and inspections would fall under CMT. CMT is not listed in your RFQ. Some public entities tend to lump geotechnical and CMT together. Should we highlight these services in under geotechnical? A55: As indicated in Page 1 of this addendum, "Geotechnical" has been removed from Group B — Engineering of this RFQ. Q56: The scope also says "Any other professional services..." Our firm also offers facilities services (i.e. building envelope, roofing, waterproofing). Should we highlight this in the submittal? If so, where should we address it? Or should we just stick to the services that are under Group A& Group B? 10 A56: As indicated in Appendix C, the scope of this RFQ will include "Any other professional service pursuant to Section 287.055, Florida Statutes, commonly known as the Consultants' Competitive Negotiation Act (CCNA)." Proposers may highlight in their response any other professional services that falls under Section 287.055, Florida. Proposers may list this information under Tab 3 —Approach and Methodology as indicated in Page 13 of the RFQ. Q57: Submitting separate books for each specialized area that apply to our firm will be not only be costly, but time consuming. Please consider allowing us to submit one book & distinguish the specialized area in each section with a sub tab labeled with that specialized area or simply by using a page break in our documents. A57: Please refer to the answer written for Question#7 in this Addendum. Q58: Can you please provide a list of the firms that are the incumbents for this contract? A58: The incumbents under the City's current agreement for these services are: AECOM USA, INC. HADONNE CORP ARCHITEKNICS KOBI KARP ARCHITECTS& ATKINS NORTH AMERICA, INC. LIVS ASSOCIATES AVINO&ASSOCIATES, INC. LOCKWOOD,ANDREWS&NEWMAN INC BCC ENGINEERING, INC MC HARRY& ASSOCIATES INC BEA ARCHITECTS, INC MILIAN SWAIN&ASSOCIATES BENDER&ASSOCIATES ARCHITECTS MILLER LEGG BERMELLO,AJAMIL&PARTNERS O'LEARY RICHARDS DESIGN BISCAYNE ENGINEERING COMPANY PILLAR CONSULTANTS, INC. BORRELLI&PARTNERS,INC. RED DESIGN GROUP BRINDLEY PIETERS&ASSOCIATES ROBAYNA AND ASSOCIATES, INC. BRUCE HOWARD&ASSOCIATES ROSENBERG DESIGN GROUP,INC. CALVIN,GIORDANO&ASSOCIATES SAVINO MILLER DESIGN STUDIO CASHIN ASSOCIATES PC SBLM ARCHITECTS PC CDM SMITH INC SCHWEBKE-SHISKIN&ASSOC INC CES CONSULTANTS,INC. SHULMAN&ASSOCIATES DOUGLAS WOOD&ASSOCIATES, INC TERRA CIVIL ENGINEERING E SCIENCES INCORPORATED THE RUSSELL PARTNERSHIP, INC EASTERN ENGINEERING GROUP COMP TLC ENGINEERING FOR EDSA, INC. WILLIAM LANE ARCHITECTS FORBES ARCHITECTS ZYSCOVICH, INC. Q59: Is Mechanical, Electrical, and Plumbing considered one specialized category or three separate specialized categories? A59: Mechanical, Electrical, and Plumping Engineering are considered one specialized category. Q60: Please clarify which of the bulleted items described in the Scope of Work fall under each specialized category. A60: The architectural and engineering services listed in Appendix C, Section C2. Scope of Work are only a representative list of the various services the City may utilize throughout the term of the contract. After award, when professional services are required, a proposed project will be 11 analyzed in terms of the predominant professional specialty required, and a firm will be selected from the appropriate specialization list. Q61: Due to the inadvertent error with the time of the original pre-proposal meeting, several firms have a nearly a two-week advantage with information received at the original pre- proposal meeting that many did not receive until the second pre-proposal meeting. For this reason,we are requesting a time extension for the Statement of Qualifications. A61: As indicated in page 1 of this addendum, the deadline for receipt of proposals has been extended to Tuesday, December 2, 2014 at 3:00 PM. Proposers must be registered with Public Purchase to ensure receipt of all addenda. Q62: We understand that consultants are not allowed to cite City Employees as references in the proposal response for the above reference RFQ. We would like to receive clarification on this because based on Tab 2.1 and the SF-330 Section F, when showing project examples, we must list the Project Owner and Contact Person/Phone/E-mail. Please advise how we should address this section while still complying with the City's submittal requirements? A62: Please note that Proposers are not prohibited from citing City Employees as a contact in their proposal response for a particular project. Q63: The package stated we need to have 5 relevant project examples, can we have more than 5 project sheets, or only 5 is permitted? A63: Please refer to answer written for Question # 1 in this Addendum. Q64: In regard to RFQ 2014-346-YG Professional Architectural & Engineering Services, the RFQ states on page 12 that you request 5 relevant projects performed in the last 5 years. However, on the SF330 form, it allows up to 10 projects to be shown. Do you wish to have a maximum of 5 projects or can we include more on the SF330 form? A64: Please refer to answer written for Question# 1 in this Addendum. Q65: Can we submit more than 5 project examples? A65: Please refer to answer written for Question# 1 in this Addendum. Q66: Can we suggest that a single proposal be required to cover multiple specialties but still require separate proposals for either Group A or Group B. In the cover letter we could then highlight which specialties that we are referring to within the remainder of the document. Should this be acceptable, can we increase the number of projects provided to 10 to cover the wider scope? A66: Please refer to the answer written for Question #7 in this Addendum. Q67: We understand that the City may have projects related to neighborhood improvements and possibly pump stations which would require multiple disciplines. If this type of project were to fall in the civil engineering category, would we need to include mechanical and electrical personnel in our submittal as that may be required for this type of project? A67: Please refer to the answer written for Question # 19 in this Addendum. 12 Q68: Our firm and staff are fully licensed in landscape architecture and we have certified arborists on staff so we believe we are fully qualified to meet the RFQ requirements for landscape architecture services. With these qualifications, is it still necessary to include certifications from the Landscape Inspectors Association of Florida and the FNGLA in the RFQ response? These two certifications are not typical for landscape architects to have. Can those requirements be dropped or if they can't be dropped, can they be provided through a horticultural sub consultant. A68: International Society of Arboriculture Certification is acceptable. Q69: How should we document the consultants involved in the projects presented (TAB 2.1 Page 12)? (what portions of the SF 330 should be used?) A69: Proposers shall utilize the corresponding sections of SF3330 to document the information requested under RFQ Tab 2, #2.1 -Qualifications of Proposing Firm. Q70: Does Appendix E (Insurance Requirements) and F (sample contract) have to be included in the submittal? A70: No. Only the information requested under Section 0300 — Submittal Instructions and Format needs to be included in the response. Q71: Under Section 0300—Submittal Instructions and Format-TAB 2- Experience & Qualifications,we are required to submit Standard Form 330 to complete the following items: 2.1 Qualifications of Proposing Firm 2.2 Qualifications of Proposer Team Should we divide the SF330 in the following order to provide our responses? To respond item 2.1 —should we include Part I -Sections, A-C; and sections F- Example Projects; G -Key Personnel Participation in Example Projects; H - Additional Information, and Part II —General Qualifications To respond item 2.2, should we include sections D-Organizational Chart and E— Resumes of Key Personnel, to provide relevant project experience of each key staff personnel. Please clarify the proper distribution of the SF 330 Sections to provide our responses. A71: Proposers shall utilize the corresponding sections of SF3330 to document the information requested under RFQ Tab 2, #2.1 -Qualifications of Proposing Firm. Q72: Under "specialized areas: GROUP A ENGINEERING General Environmental Interior Design / Space Planning Civil" ....do you mean General Environmental and Interior...? And can we submit under Category A for just General Environmental? A72: The column titled "Group A—Architecture", has the following specialized areas: General, Interior Design/Space Planning, Landscape, Planning and Urban Design, Town Planning, Historical Preservation. The column titled "Group B — Engineering", as amended, has the following specialized areas: Environmental, Civil, Mechanical, Electrical, and Plumbing, Structural, and Land Surveying Services. Please also refer to the answer written for Question # 7 in this Addendum. 13 Q73: is it the intent of the City that if a civil engineering task arises that requires geotechnical services, the prime firm use the services of the Geotechnical firm selected as part of this procurement? A73: Page 13 of the RFQ, Tab 3, `It is the objective of the City that the majority of the services defined herein be performed directly by the Proposer(rather than through sub-consultants). After award, when professional services are required, a proposed project will be analyzed in terms of the predominant professional specialty required, and a firm will be selected from the appropriate specialization list. Q74: The RFQ identifies two groups (A& B)which are further broken down into 16 specialized categories (by type of service). Instructions require that respondent submit separately for each category. Our questions are as follows: a. Is the intent to award for each specialized category(minimum of 16 rewards)? b. Is the intent to award to multiple firms within a category? c. Given that each discipline must submit separately, unless providing the same specialized services, how can there be sub-consultant's under this format? A74: The City is not limited to awarding only one Proposer per specialized category. The City may award more than one Proposer per specialized category. The City will evaluate each Proposal in accordance with the evaluation criteria indicated in Page 14 of the RFQ, Section 0400. Furthermore, as indicated Page 13 of the RFQ, Tab 3, "It is the objective of the City that the majority of the services defined herein be performed directly by the Proposer(rather than through sub-consultants). To evaluate compliance with this objective, proposers shall explain how they plan to accomplish this, denoting which sections of the scope shall be performed directly by the Firm (with its own forces) and which sections are intended to be subcontracted Q75: Group A & B defines the 16 specialty categories. Appendix `C', section C2, identifies the types of services required. There is no correlation of services to specialties. This leaves it up to each consultant to determine which services are to be provided under the category they're submitting on. This interpretation could result in an incomplete submittal andlor gaps in services provided. Is it the intent to let the consultants determine which services should be address in the specialty they are submitting for? A75: Yes. The services identified in Appendix C, sub-section C2 lists general descriptions of services that the City may need throughout the term of the awarded contract. As indicated in Page 13, Tab 3, of the RFQ, each proposer shall submit information on how it plans to accomplish the proposed scope of services. Any questions regarding this Addendum should be submitted in writing to the Procurement Management Department to the attention of the individual named below, with a copy to the City Clerk's Office at RafaelGranado @miamibeachfl.gov. Procurement Contact: Telephone: Email: Yusbel Gonzalez 305-673-7000, ext. 6230 YusbelGonzalez @miamibeachfl.gov Proposers are reminded to acknowledge receipt of this addendum as part of your RFQ submission. Potential proposers that have elected not to submit a response to the RFP are requested to complete and return the "Notice to Prospective Bidders" questionnaire with the reason(s) for not submitting a propos- ..`_,AA � ?�� Denis ' I " Procurement Director 14 PRE-PROPOSAL MEEETING SIGN-IN SHEET OCTOBER 1 , 2014 15 M CITY OF MIAMI BEACH PRE- PROPOSAL MEETING SIGN-IN SHEET DATE: October I, 2014 TITLE: RFQ 2014-346-YG-PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" NAME COMPANY NAME PHONE# FAX# (PLEASE PRINT) E-MAIL ADDRESS Yusbel Gonzalez Procurement - CRIB 305-673-7000 786-394-4073 vusbeItzonzalez( iamibeachtl.u.ov ext. 6230 Tru,m 'RAUL S. MiASTRA?A 12.055 t 8Apa)zgt)4I Sn5 5!o-613o �rmgs�',rgPa@ vossbav; cowl FeelJANDO LAcziOS NtisTate. NE 1 .1,-,61) (NG . 5-23+x- 7,J 5I- eP4 - iceio*e rnatr n .co(r% J. NsE5 Reotaw 3702 yo5'06o 3749 Kl1tt�' C�,Y�\rl �ti���S Ct BeaQ� A 1\1\ ils Co∎kNi MbeoeV.f-t.cco j 3c�5 5�-ZiW 3o5- �N t 77y..6'L77 aw ro..'ice.\t'`.‘a-:) .• .(v 7C P 3&s. G/1. 3°S. mpion, To 17'4 k- -, c n 1 '7 . —73 rwae bbAcA`lk,�tnn IWMA..%tle4e.34 rt..Co du 9v6 MIA T/nfZ G it/ /3 - /� rr Dfiv a)114 Air hvgz 1,1rn K 6 ?" 'id-79 7/ (od'2- 77cI Filet „PE 4e4 to z9 r arzrzozA, behQr'. co r1 � Diu 'D err! 40.441 iLI11I2c.. s" 3 o r ' ko 04-146/4 R o/.1 46--Au. .Z614 t� 2-913 3S4�ZS2 Lou rd i-11- �� c.rut 34 cli iploescr MIAMIBEACH CITY OF MIAMI B EACH PRE-PROPOSA.L MEETING SIGN-IN SHEET NAME COMPANY NAME PHONE# FAX# (PLEASE PRINT) E-MA.IL ADDRESS Ifgat';ew7. .A.i '6,-ted1,,5"/�,z(d_ ,6e-c; / f\ �� COQ: Sv -��3�'�2a GG , „ (l�� (,� � L. ' C7 o @ Igo v � 2 ill- MEL) 1 S$._1V A.. sc...i 3Dct St ki-t r)6--‘ l7uwv��Jo�v� S blvtk L . e'nw 4 ry--Avi Afrt)74 fi L75 z /is./ Sri• Y 7-41'1 15. ��. /+v G R a s X61 .361 51q-7 561 391 4116 &Oil?) 11001SOA _ t-lorove% 4 11(901*o/1 0 Gil r.• Lori • -I MIAMIBEACH CITY OF MIIA vII BEACH PRE- PROPOSAL MEETING SIGN-IN SHEET DATE: October 1,2014 TITLE: RFQ 2014-346-YG-PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES N SPECIALIZED CATEGORIES ON AN"AS-NEEDED-BASIS" NAME COMPANY NAME PHONE# FAX# (PLEASE PRINT) E-MAIL ADDRESS Yusbel Gonzalez Procurement - CRIB 305-673-7000 786-394-4073 vusbelwnzalezemiarnibeachtl.<_ov ext. 6230 Je-cce,y, C s 4 CEN Te SA L 44.14 po5)40-54-81 (3os544)-S494 J //a r m csasro eta &A i. 7362 -. J2 4 kcSOI7 /"Gez6 ( o8)y zc,-- Ty L i ) ' riu i94/4--L, cos- � 3 nil �s 019 ,9 vi PO .,\-e-r)ci I 775 -?e_ hili7, ,e-0 'UA N CAALOS uC 144: //243A 35- /o1 - IiERNPcN D et,rctilciee.e.)14q,i fire •eoill 32.Cot KA(:)( 1 M l 1\14(csc tE FC.C� �c-L L-1 0 -it. XaCkINI)) t.k1 Pik) ,C,N eec:' n5 to 7 B crD Cu es p q h • &kelt.+"‘ .3"0 C .ccL U ill JCL C,5'&5 B(SIC I_ral,Ad-(4 -- y - VA\Gaa (i'‘OWGC- 1S. (6W) -3\3 LAZ-0 ,err= 4.4 ! D * MIAMIBEACH CI lY OF MI=BMI BEACH PRE- PROPOSAL MEETING SIGN-IN SHEET DATE: October 1,2014 TITLE: RFQ 20 14-346-YG-PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" NAME COMPANY NAME PHONE# FAX# (PLEASE PRLNT) E-MAIL ADDRESS Yusbel Gonzalez Procurement - CVIB 305-673-7000 786-394-4073 vusbeltzonza 1eznuamibeachtl.�,ov ext. 6230 (cL ��riskia &GG 6n uteri acs-L-c n� � ins-6,0-d3s1 rtC tA l n 0 i 40�b d—el s COW) 91-eve pith; utiva /ie<19/ -41 R fec,/6L .36' -)7P2-/ 21-s 7(66-.6 S AC Yi � So T.Y. C,,.� Ir��.�na�►�-.� j e tj N olPL ft �. 305)>l1 i��D�O ���51 M-111 o,n o 1) J dal � � (271,e_itsq 'Pct 3Fa-d�C�s �occoiL4 l Cow oZ6-s--S 20- L. AOa�n BU• (IJiu'AH�.frpo L.Lj21 -6 • 3oce72'.496a Ccask7c, c3C5--C74. t-6233 &-(d,t - ■‘,LVt- V %‘.7 x.25 GAG,.. �, et N 1 305.Z1-{ T. 43,431 -a 24 -W C /n �f 5 t "- �. Q rl`Cl �' 1 ��'y-167 2-/o ree, �y 61 crs-.6 Lcv, y%„ . Lci.c. 3o5 -6-43 ,I-V AbA,41 ,ei24n rc e4-rc i$ ch-f 080_ {F � MIAMIBEACH CITY OF MIAMI BEACH PRE-PROPOSAL MEETING SIGN-IN SHEET NAME COMPANY NAME (PLEASE PRINT) EMAIL ADDRESS PHONE# FAX# -ma t s A5 per .��, - rS y)s -t she & I.Swi/Ms. uirn (1113-1q(5 Nod-creciy. )ic. 4/44 '4'7 =�- nc,,r j. ✓a w r6I4.►�r��.i5•<�� 2r • MIAMIBEACH CITY OF MIAMI BEACH PRE- PROPOSAL MEETING SIGN-IN SHEET (PARTICIPANTS ON THE PHONE) DATE: October 1, 2014 TITLE: RFQ 2014-346-YG—PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" NAME COMPANY NAME PHONE# FAX# (PLEASE PRINT) E-MAIL ADDRESS Yusbel Gonzalez Procurement- CMB 305-673-7000 786-394-4073 vusbel,onzalez(rniamibeachfl.g.ov ext. 6230 Ken Boyer Douglass Wood Associates Jose Lopez Schwebke-Shiskin&Associates, Inc. (954)435-7010 • • Sandra Castillo Milian, Swain & Associates (305)441-0123 . i Stephanie Theard BCC Engineering (305) 670-2350 Kathia Dash R.J. Heisenbottle Architects, P.A. (305) 446-7799 Ileana Gonzalez Robayna& Associates (305) 823-9316 Natalie Lockwood, Andrews& Newman (305)444-6454 Toni Decker Wolfberg Alvarez & Partners 305)666-5474 Victor Herrera NV5 (954)495-2112 • Douglass Man CB&I 561.361.3148 MIAMIBEACH CITY OF MIAMI BEACH PRE-PROPOSAL MEETING SIGN-IN SHEET (PARTICIPANTS ON THE PHONE) NAME COMPANY NAME (PLEASE PRINT) PHONE# FAX# E-MAIL ADDRESS Marrie Bennetham Jennifer Creed GOE Associates Daniel Goodman DEA Architects Sherry Miller Legg (305) 599-6381 Cathy O'Leary O'Leary Richards Design Associates (305) 596-6628 Stephanie Marlin Engineering (305)477-7575 Antonio Garate ALVAREZ-D[AZ &VILLALON 786.497.1906 Jake Ozyman Haks Engineers, Architects and Land (212) 747-1997 Surveyors, P.C. Michael EAC Consulting (305) 265-5400 Shawn Stanley Consultants 786.762.4115 1 Mark URS Corporation (305) 262-7466 4 PRE-PROPOSAL MEEETING SIGN-IN SHEET OCTOBER 13, 2014 16 a '. MIAMIBEACH CITY OF MIAMI B EAC H PRE- PROPOSAL MEETING (ADDITIONAL) SIGN-IN SHEET DATE: October 13, 2014 TITLE: RFQ 2014-346-YG-PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" NAME COMPANY NAME PHONE# - FAX# (PLEASE PRLNT) E-MAIL ADDRESS Yusbel Gonzalez Procurement-CMB 305-673-7000 786-394-4073 vusbel uonzalez()miamibeach l.t Rov ext. 6230 f)A-N 1 L- F,C-71 Nt A- G---r1(v el(.) 2 E.--A, ;.-e.)A4 3,-.---:.,_.-,, .t-6--,( 3r.f, 631- A 6',I)ivi A-N `_.C,S ;�t- i 24 CS`1 1 J c<E 1-505 ) ---*j- A74 5:,NG•ALC=2 -(7'5,Z4 1-CA/ I D A/ 5v5 3 7 32�, 767( ;z�t,oe°� 4 c i e -4-b4rc C` bisc.c,re e ,:s., - e er7,15: ,,,-� t./�,Q1QL-1. Avg e'4 -i k ( 00s) ErneS e P k . Aif r &7'— 91,1 IkL C (,_k_ c,5) _,,,<ri.)-\?0- Cl\ -1-AKiizi 1/4)0-ck,IQ • Scev.-Qv `� 0,e(. 0 .-(c)„, %LI ; -35" '77 ),-.....k AZ-a-LA K,L4 \•)4 c'. 1'. 7__ C(1-1 c_L t(ca... �' �3=tom`'" "Sj:,,".c_,c..1..:. eAA(Mill • Ei KA c, r `` I G ,_..4 p(oc44,Q So c 05-3°11-1O16 v-3°►�-141� p D stAL US f c ca .ONCI_ oycr.l Cf.J@(ZOOKLC6altb4E12-,GOr1 lieed,ted-rE. 305'M5-2?CO bcooV--.u._,dre_e -ic..f\-k (_•C OW1 • ---;1--- L_ , cA-;-,e--,_ iv\‘,.(L4-4- ei\--r.p--6- .:,-e 6111-7--if 6Q 1-ez--6 I-- , -/- �EAN-- oS -eeA h J .,di-74.r+,_ 2 D • MIAMIBEACH CITY OF MIAMI BEACH PRE- PROPOSAL MEETING (ADDITIONAL) SIGN-IN SHEET DATE: October 13, 2014 TITLE: RFQ 2014-346-YG—PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN"AS-NEEDED-BASIS" NAME COMPANY NAME PHONE# FAX# (PLEASE PRINT) , . . E-1,LkIL ADDRESS Yusbel Gonzalez Procurement- CMIB 305-673-7000 786-394-4073 vusbe hwnzalez, L?miamibeachtl.cov ext. 6230 J e.ine ° Ck ce�6,�,�l��Fit. 30c477- 4., /)i cC /'/ow' a MI?) — C 1p 3D S- 4,7 3 - C1 pAa ct'a cCrvul wti t ict im i le Q cti-r-i- o v `1.o'-I I Vanef-S5 4-- ILL r`119r'j t PY r 1 i.t j 30 7erin 'de2- - Ler�Yiv 7 ���, s I�GYIISSC• vote � iT�C-c't�t •Goy' oloi gar p 1 Ic aC Uv'a 3.5 G73 tI24bt+6, VV t oli e ca61cikW ber ciloy MIAMIBEACH CITY OF MIAMI BEACH PRE- PROPOSAL MEETING (ADDITIONAL) SIGN-IN SHEET (PARTICIPANTS ON THE PHONE) DATE: October 13, 2014 TITLE: RFQ 2014-346-YG—PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" NAME COMPANY NAME PHONE# FAX# (PLEASE PRINT) E-MAIL ADDRESS Yusbel Gonzalez Procurement-CMB 305-673-7000 786-394-4073 vusbele:onzalez cDmiamibeachtl.Rov ext. 6230 Lance Olsen Innovtec 352-459-1974 lance@innovtec.com James Kahn Keith and Schnars, PA 954-776-1616 ikahn«.kstla.com Sharman Ciddi EAC Consulting 305-264-2557 Torn Brzezinski WadeTrim 813-882-4373 tbizezinkski @wadetrim.com Jenny Alonso T.Y. Lin International 305-567-1888 Jennv.alonso a.tvlin.com Ext. 4034 Staci L. Bolinger Dunkelberger Engineering&Testing 561-494-7006 slbolin<_er aerracon.com William Craven Pure Technologies 407-408-7631 William.craven«.puretechltd.com Jennifer Priem GLE Associates 813-241-8350 ipriem @gleassociates.com Judith A. Kemp Brindley Pieters & Associates 407-830-8700 jkemp(rD.bpa-enu.ineers.com Helmut J. Mueller Mueller& Associates, LLC 305-600-9070 muellerandassociates@c.T.mail.com MIAMIBEACH CITY OF MIAMI BEACH PRE-PROPOSAL MEETING (ADDITIONAL) SIGN-IN SHEET (PARTICIPANTS ON THE PHONE) NAME COMPANY NAME (PLEASE PRINT) PHONE# FAX# E-MAIL ADDRESS Ilker Uzun CPH Corp 305-274-4805 iuzun iDcpicopr.com Brenda Kimley-Horn 407-898-1511 Iraldy Martin LIVS Associates 305-443-2933 imartin @livs.net Nadia E-Sciences (786) 517-2632 Rothie Franko OCI Associates (561)688-6575 Steve Pines Bermello Ajamil & Partners (305) 859-2050 Dina CSA Group (305) 461-5484 Eric Propes EDSA 954.524.3330 Jose Lopez Schwebke-Shiskin&Associates, Inc. (954)435-7010 MIAMI BEACH City of Miami Beach,1700 Convention Center Drive,Miami Beach,Florida 33139,www.miamibeachfl.gov DEPARTMENT Of PROCUREMENT MANAGEMENT Tel: 305-673-7490 Fax: 786-394-4002 ADDENDUM NO. 6 REQUEST FOR QUALIFICATIONS NO. 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" (the"RFQ") NOVEMBER 12,2014 This Addendum to the above-referenced RFQ is issued in response to questions from prospective proposers, or other clarifications and revisions issued by the City. The RFQ is amended in the following particulars only. 1. RFQ DUE DATE AND TIME. The deadline for the receipt of proposals is extended UNTIL 3:00 P.M., ON TUESDAY, NOVEMBER 25, 2014, at the following location. Miami Beach City Hall Procurement Department 1700 Convention Center Drive, 3rd Floor Miami Beach, Florida 33139 Late proposals will not be accepted. Proposers are cautioned to plan sufficient time to allow for traffic or other delays for which the Proposer is solely responsible. A FORTHCOMING ADDENDUM WILL CONTAIN ANSWERS TO THE QUESTIONS RECEIVED. Any questions regarding this Addendum should be submitted in writing to the Procurement Management Department to the attention of the individual named below, with a copy to the City Clerk's Office at RafaelGranado @miamibeachfl.gov. Procurement Contact: Telephone: Email: Yusbel Gonzalez 305-673-7000, ext. 6230 YusbelGonzalez @miamibeachfl.gov Proposers are reminded to acknowledge receipt of this addendum as part of your RFQ submission. Potential proposers that have elected not to submit a response to the RFP are requested to complete and return the "Notice to Prospective Bidders" questionnaire with the reason(s) for not submitting a proposal. Sincerely, a Alex Denis Procurement Director Page 1 of 1 MIAMIBEACH City of Miami Beach, 1700 Convention Center Drive,Miami Beach,Florida 33139,www.miamibeachfl.gov DEPARTMENT OF PROCUREMENT MANAGEMENT Tel: 305-673-7490 Fax: 786-394-4002 ADDENDUM NO. 5 REQUEST FOR QUALIFICATIONS NO. 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN"AS-NEEDED-BASIS" (the "RFQ") OCTOBER 31, 2014 This Addendum to the above-referenced RFQ is issued in response to questions from prospective proposers, or other clarifications and revisions issued by the City. The RFQ is amended in the following particulars only. 1. RFQ DUE DATE AND TIME. The deadline for the receipt of proposals is extended UNTIL 3:00 P.M.. ON TUESDAY, NOVEMBER 18, 2014, at the following location. Miami Beach City Hall Procurement Department 1700 Convention Center Drive, 3rd Floor Miami Beach, Florida 33139 Late proposals will not be accepted. Proposers are cautioned to plan sufficient time to allow for traffic or other delays for which the Proposer is solely responsible. A FORTHCOMING ADDENDUM WILL CONTAIN ANSWERS TO THE QUESTIONS RECEIVED. Any questions regarding this Addendum should be submitted in writing to the Procurement Management Department to the attention of the individual named.below, with a copy to the City Clerk's Office at RafaelGranado@miamibeachfl.gov. Procurement Contact Telephone: Email: Yusbel Gonzalez 305-673-7000, ext. 6230 ` YusbelGonzalez @miamibeachfl.gov Proposers are reminded to acknowledge receipt of this addendum as part of your RFQ submission. Potential proposers that have elected not to submit a response to the RFP are requested to complete and return the "Notice to Prospective Bidders" questionnaire with the reason(s) for not submitting a proposal. • cfi eel , i �■101.i 1,1 - ��''- n S °rocurement Director Page 1 of 1 M1AMIBEACH City of Miami Beach, 1700 Convention Center Drive,Miami Beach,Florida 33139,www.miamibeachfl.gov DEPARTMENT OF PROCUREMENT MANAGEMENT Tel: 305-673-7490 Fax: 786-394-4002 ADDENDUM NO.4 REQUEST FOR QUALIFICATIONS NO. 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" (the"RFQ") OCTOBER 17, 2014 This Addendum to the above-referenced RFQ is issued in response to questions from prospective proposers, or other clarifications and revisions issued by the City. The RFQ is amended in the following particulars only. 1. DEADLINE FOR RECEIPT OF QUESTIONS. The deadline for receipt of questions for this RFQ was October 14, 2014 at 5:00 PM. No more further questions will be allowed. 2. RFQ DUE DATE AND TIME. The deadline for the receipt of proposals is extended until 3:00 p.m., on Monday, November 3, 2014, at the following location. Miami Beach City Hall Procurement Department 1700 Convention Center Drive, 3`d Floor Miami Beach, Florida 33139 Late proposals will not be accepted. Proposers are cautioned to plan sufficient time to allow for traffic or other delays for which the Proposer is solely responsible. A forthcoming addendum will contain answers to the questions received. Any questions regarding this Addendum should be submitted in writing to the Procurement Management Department to the attention of the individual named below, with a copy to the City Clerk's Office at RafaelGranado @miamibeachfi.gov. Procurement Contact: Telephone: Email: Yusbel Gonzalez 305-673-7000, ext. 6230 YusbelGonzalez @miamibeachfl.gov Proposers are reminded to acknowledge receipt of this addendum as part of your RFQ submission. Potential proposers that have elected not to submit a response to the RFP are requested to complete and return the "Notice to Prospective Bidders" questionnaire with the reason(s) for not submitting a proposal. Sincerely, — I- � Alex Denis Procurement Director Page 1 of 1 MIAMI BEACH City of Miami Beach, 1700 Convention Center Drive,Miami Beach,Florida 33139,www.miamibeachfl.gov DEPARTMENT OF PROCUREMENT MANAGEMENT Tel: 305-673-7490 Fax: 786-394-4002 ADDENDUM NO. 3 REQUEST FOR QUALIFICATIONS NO. 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS"(the"RFQ") OCTOBER 7,2014 This Addendum to the above-referenced RFQ is issued in response to questions from prospective proposers, or other clarifications and revisions issued by the City. The RFQ is amended in the following particulars only. 1. RFQ SOLICITATION DOCUMENT. It has been brought to our attention that some proposers are receiving an error message when attempting to download the RFQ solicitation document. Via this Addendum, the RFQ solicitation document has been re-loaded to the solicitation page in www.publicpurchase.com. No changes have been made to the RFQ solicitation document since it was initially published on September 18, 2014. • 2. ADDITIONAL PRE-PROPOSAL CONFERENCE. Due to an inadvertent error with the time indicated for the pre-proposal conference held on October 1, 2014, an additional pre-proposal conference has been scheduled for the date, time, and location indicated below. Proposers that attended the pre- proposal conference held on October 1, 2014 are not required to attend this second pre-proposal conference. Date: October 13, 2014 at 2:00 PM Location: City of Miami Beach City Hall -4th Floor City Manager's Large Conference Room 1700 Convention Center Drive Miami Beach, Florida 33139 Proposers interested in participating in the Pre-Proposal Submission Meeting via telephone must follow these steps: (1) Dial the TELEPHONE NUMBER: 1-888-270-9936 (Toll-free North America) (2) Enter the MEETING NUMBER: 1142644 Proposers who are interested in participating via telephone should send an e-mail to the contact person listed in this RFQ expressing their intent to participate via telephone. Any questions regarding this Addendum should be submitted in writing to the Procurement Management Department to the attention of the individual named below, with a copy to the City Clerk's Office at RafaelGranado @miamibeachfl.gov. Procurement Contact: Telephone: Email: Yusbel Gonzalez 305-673-7000, ext. 6230 YusbelGonzalez @miamibeachfl.gov Proposers are reminded to acknowledge receipt of this addendum as part of your RFQ submission. Potential proposers that have elected not to submit a response to the RFP are requested to complete and return the "Notice to Prospective Bidders" questionnaire with the reason(s) for not submitting a proposal. Sincerely, - • Alex Denis Procurement Director Page 1 of 1 MIAMI BEACH City of Miami Beach, 1700 Convention Center Drive,Miami Beach,Florida 33139,www.miamibeachfl.gov DEPARTMENT OF PROCUREMENT MANAGEMENT Tel: 305-673-7490 Fax: 786-394-4002 ADDENDUM NO. 2 REQUEST FOR QUALIFICATIONS NO. 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" (the "RFQ") SEPTEMBER 30, 2014 This Addendum to the above-referenced RFQ is issued in response to questions from prospective proposers, or other clarifications and revisions issued by the City. The RFQ is amended in the following particulars only. CLARIFICATION# 1: The RFQ solicitation file published on September 18, 2014 was corrupt. As such, many proposers were unable to download the RFQ document. On September 19, 2014, at approximately 8:25 AM, an updated RFQ was uploaded to the solicitation page in Public Purchase, which created "Addendum No. 1" in Public Purchase. CLARIFICATION#2: Although indicated in the RFQ solicitation document, the pre-proposal conference date, time, and location was inadvertently left out from the solicitation page in Public Purchase. This information has now been added. As a reminder to all proposers, the pre-proposal conference will take place on October 1, 2014 at 10:00 AM at the following location: City of Miami Beach City Hall -4th Floor City Manager's Large Conference Room 1700 Convention Center Drive Miami Beach, Florida 33139 Attendance (in person or via telephone) is encouraged and recommended as a source of information, but is not mandatory. Proposers interested in participating in the Pre-Proposal Submission Meeting via telephone must follow these steps: (1) Dial the TELEPHONE NUMBER: 1-888-270-9936 (Toll-free North America) (2) Enter the MEETING NUMBER: 1142644 Proposers who are interested in participating via telephone should send an e-mail to the contact person listed in this RFQ expressing their intent to participate via telephone. Any questions regarding this Addendum should be submitted in writing to the Procurement Management Department to the attention of the individual named below, with a copy to the City Clerk's Office at RafaelGranado @miamibeachfl.gov. Procurement Contact: Telephone: Email: Yusbel Gonzalez 305-673-7000, ext. 6230 YusbelGonzalez @miamibeachfl.gov Proposers are reminded to acknowledge receipt of this addendum as part of your RFQ submission. Potential proposers that have elected not to submit a response to the RFP are requested to complete RFP No. 10-08/09 Building Development Process Fee Study Addendum#1 10/112014 Page 1 of 1 2 I Miami Beach RFQ 2014-346-SR PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN"AS-NEEDED-BASIS' and return the "Notice to Prospective Bidders" questionnaire with the reason(s) for not submitting a proposa Since e r,,, , i vaenis— Procurement Director r i REQUEST FOR QUALIFICATIONS ( RFQ PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" RFQ 2014-346-YG RFQ ISSUANCE DATE: SEPTEMBER 19, 2014 STATEMENTS OF QUALIFICATIONS DUE: OCTOBER 23, 2014 @ 3:00 PM ISSUED BY: YUSBEL GONZALEZ, CPPB MIAMI BEACH Alex Denis, Director DEPARTMENT OF PROCUREMENT 1700 Convention Center Drive, Miami Beach, FL 33139 305.673.74901 adenis @miamibeachfl.gov www.miamibeachfl.gov MIAMI BEACH TABLE OF CONTENTS SOLICITATION SECTIONS: PAGE 0100 NOT UTILIZED N/A 0200 INSTRUCTIONS TO RESPONDENTS & GENERAL CONDITIONS 3 0300 SUBMITTAL INSTRUCTIONS & FORMAT 11 0400 EVALUATION PROCESS 13 APPENDICES: PAGE APPENDIX A RESPONSE CERTIFICATON, QUESTIONNAIRE AND AFFIDAVITS 16 APPENDIX B "NO BID" FORM 23 APPENDIX C MINIMUM REQUIREMENTS &SPECIFICATIONS 25 APPENDIX D SPECIAL CONDITIONS 29 APPENDIX E INSURANCE REQUIREMENTS 31 APPENDIX F SAMPLE CONTRACT 33 RFQ 2014-346-YG 2 MIAMIBEACH SECTION 0200 INSTRUCTIONS TO RESPONDENTS&GENERAL CONDITIONS 1.GENERAL.This Request for Qualifications(RFQ) is issued by the City of Miami Beach, Florida(the"City"), as the means for prospective Proposer to submit their qualifications, proposed scopes of work and cost Statement of Qualifications (the "proposal") to the City for the City's consideration as an option in achieving the required scope of services and requirements as noted herein. All documents released in connection with this solicitation, including all appendixes and addenda, whether included herein or released under separate cover, comprise the solicitation, and are complementary to one another and together establish the complete terms, conditions and obligations of the Proposer and, subsequently,the successful proposer(s)(the"contractor[s]")if this RFQ results in an award. The City utilizes PublicPurchase (www.publicpurchase.com) for automatic notification of competitive solicitation opportunities and document fulfillment, including the issuance of any addendum to this RFQ. Any prospective proposer who has received this RFQ by any means other than through PublicPurchase must register immediately with PublicPurchase to assure it receives any addendum issued to this RFQ. Failure to receive an addendum may result in disqualification of proposal submitted. 2. PURPOSE. The City of Miami Beach is accepting qualifications for Architectural and Engineering Services in various professional categories on an "as-needed basis. Each proposed contract shall be for a three(3)year contract term, with two(2)one year renewal options at the City's option. It is the intent of the Administration to use the RFQ process to select firms who are qualified to provide services in each of the categories of professional specialization. When professional services are required, a proposed project will be analyzed in terms of the predominant professional specialty required, and a firm will be selected from the appropriate specialization list. In accordance with Section 287.055, Florida Statutes, known as the "Consultants' Competitive Negotiation Act", the • City may enter into a "continuing contract" for professional architectural and engineering services for projects in which construction costs do not exceed$2 Million or for study activities for which the fee does not exceed$200,000. The City may request, accept, and consider proposals for the compensation to be paid under the contract only during competitive negotiations, which will take place after the selection of the firms deemed to be the most qualified to perform the required services. If the City is not able to negotiate a mutually satisfactory compensation schedule with the top-ranked firms which is determined to be fair, competitive and reasonable, additional firms in the order of their competence and qualifications may be selected, and negotiations may continue until an agreement is reached. The RFQ seeks proposals from firms with strong qualifications in the following specialized areas: GROUP A—ARCHITECTURE GROUP B—ENGINEERING General Environmental Interior Design/Space Planning Civil Landscape Geotechnical Planning and Urban Design Mechanical, Electrical, and Plumbing Town Planning Structural Historical Preservation Land Surveying Services RFQ 2014-346-YG 3 MIAMI BEACH The price and terms for the contracts will be negotiated after City Commission approves authorization to negotiate. Under these Agreements, study activities are quoted as a lump sum based on the estimated hours to complete the project. Detailed hourly rates will be negotiated for all personnel classifications for the firms. It is the intent of this RFQ to evaluate and recommend award for each specialized category based on specific category qualifications. Firm's proposal shall clearly indicate if qualifications are being sought under Group A — Architecture and/or Group B — Engineering. Furthermore, firms are required to submit separate proposals for each specialized category under the respective group for which they seek qualifications. Example: a firm which provides landscape architecture and interior design/space planning, shall respond under Group A — Architecture and shall submit two (2) proposals under said group; a proposal seeking qualifications under landscape architecture and a proposal seeking qualifications under interior design/space planning. This RFQ is issued pursuant to Chapter 287.055, Florida Statutes,Consultants Competitive Negotiations Act (CCNA). 3.SOLICITATION TIMETABLE.The tentative schedule for this solicitation is as follows: Solicitation Issued September 19,2014 Pre-Submittal Meeting October 1, 2014 @ 10:00 AM Deadline for Receipt of Questions October 14, 2014 @ 5:00 PM Responses Due October 23, 2014 @ 3:00 PM Evaluation Committee Review TBD Proposer Presentations TBD Tentative Commission Approval Authorizing TBD Negotiations Contract Negotiations Following Commission Approval 4. PROCUREMENT CONTACT.Any questions or clarifications concerning this solicitation shall be submitted to the Procurement Contact named herein, in writing, with a copy to the City Clerk's Office, Rafael E. Granado via e-mail: RafaelGranado a(�miamibeachfl.gov ; or facsimile: 786-394-4188. The Bid title/number shall be referenced on all correspondence. All questions or requests for clarification must be received no later than seven (7) calendar days prior to the date Statement of Qualifications are due as scheduled in Section 0200-3. All responses to questions/clarifications will be sent to all prospective Proposer in the form of an addendum. Procurement Contact: Telephone: Email: Yusbel Gonzalez,CPPB 305.673.7000 Ext.6230 yusbelgonzalez @miamibeachfl.gov RFQ 2014-346-SR 4 lv1IAAiBEACH 5. PRE-STATEMENTS OF QUALIFICATIONS MEETING OR SITE VISIT(S).Only if deemed necessary by the City, a pre-proposal meeting or site visit(s)may be scheduled. A Pre-PROPOSAL conference will be held as scheduled in Solicitation Timeline above at the following address: City of Miami Beach City Hall-4th Floor City Manager's Large Conference Room 1700 Convention Center Drive Miami Beach, Florida 33139 Attendance (in person or via telephone) is encouraged and recommended as a source of information, but is not mandatory. Proposers interested in participating in the Pre-Proposal Submission Meeting via telephone must follow these steps: (1) Dial the TELEPHONE NUMBER: 1-888-270-9936(Toll-free North America) (2) Enter the MEETING NUMBER: 1142644 Proposers who are interested in participating via telephone should send an e-mail to the contact person listed in this RFQ expressing their intent to participate via telephone. 6. PRE-STATEMENTS OF QUALIFICATIONS INTERPRETATIONS. Oral information or responses to questions received by prospective Proposers are not binding on the City and will be without legal effect, including any information received at pre-submittal meeting or site visit(s). Only questions answered by written addenda will be binding and may supersede terms noted in this solicitation. Addendum will be released through PublicPurchase. 7. CONE OF SILENCE. Pursuant to Section 2-486 of the City Code, all procurement solicitations once advertised and until an award recommendation has been forwarded to the City Commission by the City Manager are under the "Cone of Silence."The Cone of Silence ordinance is available at: http://library.municode.com/index.asox?clientlD=13097&statelD=9&statename=Florida Any communication or inquiry in reference to this solicitation with any City employee or City official is strictly prohibited with the of exception communications with the Procurement Director, or his/her administrative staff responsible for administering the procurement process for this solicitation providing said communication is limited to matters of process or procedure regarding the solicitation. Communications regarding this solicitation are to be submitted in writing to the Procurement Contact named herein with a copy to the City Clerk at rafaelgranado @miamibeachfl.gov. 8. SPECIAL NOTICES. You are hereby advised that this solicitation is subject to the following ordinances/resolutions, which may be found on the City Of Miami Beach website: http://web.miamibeachfl.govlprocurement/scroll.aspx?id=23510 • CONE OF SILENCE CITY CODE SECTION 2-486 • PROTEST PROCEDURES CITY CODE SECTION 2-371 • DEBARMENT PROCEEDINGS CITY CODE SECTIONS 2-397 THROUGH 2-485.3 • LOBBYIST REGISTRATION AND DISCLOSURE OF FEES CITY CODE SECTIONS 2-481 THROUGH 2-406 • CAMPAIGN CONTRIBUTIONS BY VENDORS CITY CODE SECTION 2-487 • CAMPAIGN CONTRIBUTIONS BY LOBBYISTS ON PROCUREMENT ISSUES CITY CODE SECTION 2-488 RFQ 2014-346-SR 5 MIAMI BEACH • REQUIREMENT FOR CITY CONTRACTORS TO PROVIDE EQUAL BENEFITS FOR DOMESTIC PARTNERS CITY CODE SECTION 2-373 • LIVING WAGE REQUIREMENT CITY CODE SECTIONS 2-407 THROUGH 2-410 • LOCAL PREFERENCE FOR MIAMI BEACH-BASED VENDORS CITY CODE SECTION 2-372 • PREFERENCE FOR FLORIDA SMALL BUSINESSES OWNED AND CONTROLLED BY VETERANS AND TO STATE-CERTIFIED SERVICE- DISABLED VETERAN BUSINESS ENTERPRISES CITY CODE SECTION 2-374 • FALSE CLAIMS ORDINANCE CITY CODE SECTION 70-300 • ACCEPTANCE OF GIFTS,FAVORS&SERVICES CITY CODE SECTION 2-449 9. POSTPONEMENT OF DUE DATE FOR RECEIPT OF QUALIFICATIONS. The City reserves the right to postpone the deadline for submittal of Statement of Qualifications and will make a reasonable effort to give at least three (3) calendar days written notice of any such postponement to all prospective Proposers through PublicPurchase. 10. PROTESTS. Protests concerning the specifications, requirements, and/or terms; or protests after the proposal due date in accordance with City Code Section 2-371, which establishes procedures for protested proposals and proposed awards. Protests not submitted in a timely manner pursuant to the requirements of City Code Section 2- 371 shall be barred. 11. MIAMI BEACH-BASED VENDORS PREFERENCE. Pursuant to City of Miami Beach Ordinance No.2011-3747, a five(5)point preference will be given to a responsive and responsible Miami Beach-based proposer. 12. VETERAN BUSINESS ENTERPRISES PREFERENCE. Pursuant to City of Miami Beach Ordinance No. 2011- 3748, the City shall give a five (5) point preference to a responsive and responsible proposer which is a small business concern owned and controlled by a veteran(s)or which is a service-disabled veteran business enterprise. 13. DETERMINATION OF AWARD. The final ranking results of Step 1 & 2 outlined in Section 0400, Evaluation of Statement of Qualifications, will be considered by the City Manager who may recommend to the City Commission the proposer(s) s/he deems to be in the best interest of the City or may recommend rejection of all Statement of Qualifications. The City Manager's recommendation need not be consistent with the scoring results identified herein and takes into consideration Miami Beach City Code Section 2-369,including the following considerations: (1)The ability,capacity and skill of the proposer to perform the contract. (2)Whether the proposer can perform the contract within the time specified, without delay or interference. (3)The character, integrity, reputation,judgment,experience and efficiency of the proposer. (4)The quality of performance of previous contracts. (5)The previous and existing compliance by the proposer with laws and ordinances relating to the contract. The City Commission shall consider the City Manager's recommendation and may approve such recommendation. The City Commission may also, at its option, reject the City Manager's recommendation and select another Proposer (s) which it deems to be in the best interest of the City, or it may also reject all Statement of Qualifications. Upon approval of selection by the City Commission, negotiations between the City and the selected Proposer(s) will take place to arrive at a mutually acceptable Agreement, including cost of services. 14.ACCEPTANCE OR REJECTION OF RESPONSES. The City reserves the right to reject any or all Statement of Qualifications prior to award. Reasonable efforts will be made to either award the Contract or reject all Statement of Qualifications within one-hundred twenty (120) calendar days after Statement of Qualifications opening date. A proposer may not withdraw its Statement of Qualifications unilaterally before the expiration of one hundred and RFQ 014- 46- R 6 MIAMI BEACH twenty(120)calendar days from the date of Statement of Qualifications opening. 15. PROPOSER'S RESPONSIBILITY. Before submitting a Statement of Qualifications, each Proposer shall be solely responsible for making any and all investigations, evaluations, and examinations, as it deems necessary, to ascertain all conditions and requirements affecting the full performance of the contract. Ignorance of such conditions and requirements, and/or failure to make such evaluations, investigations, and examinations, will not relieve the Proposer from any obligation to comply with every detail and with all provisions and requirements of the contract, and will not be accepted as a basis for any subsequent claim whatsoever for any monetary consideration on the part of the Proposer. 16. COSTS INCURRED BY RESPONDENTS. All expenses involved with the preparation and submission of Statement of Qualifications,or any work performed in connection therewith, shall be the sole responsibility(and shall be at the sole cost and expense)of the Proposer, and shall not be reimbursed by the City. 17. RELATIONSHIP TO THE CITY. It is the intent of the City, and Proposals hereby acknowledge and agree, that the successful Proposer is considered to be an independent contractor, and that neither the Proposer , nor the Proposer 's employees, agents, and/or contractors, shall, under any circumstances, be considered employees or agents of the City. 18.TAXES.The City of Miami Beach is exempt from all Federal Excise and State taxes. 19. MISTAKES. Proposals are expected to examine the terms, conditions, specifications, delivery schedules, proposed pricing, and all instructions pertaining to the goods and services relative to this RFQ. Failure to do so will be at the Proposer's risk and may result in the Statement of Qualifications being non-responsive. 20. PAYMENT. Payment will be made by the City after the goods or services have been received, inspected, and found to comply with contract, specifications, free of damage or defect, and are properly invoiced. Invoices must be consistent with Purchase Order format. 21. PATENTS & ROYALTIES. Proposer shall indemnify and save harmless the City of Miami Beach, Florida, and its officers, employees, contractors, and/or agents, from liability of any nature or kind, including cost and expenses for, or on account of, any copyrighted, patented, or unpatented invention, process, or article manufactured or used in the performance of the contract, including its use by the City of Miami Beach, Florida. If the proposer uses any design, device or materials covered by letters, patent, or copyright, it is mutually understood and agreed, without exception, that the proposal prices shall include all royalties or cost arising from the use of such design, device, or materials in any way involved in the work. 22. MANNER OF PERFORMANCE. Proposer agrees to perform its duties and obligations in a professional manner and in accordance with all applicable Local, State, County, and Federal laws, rules, regulations and codes. Lack of knowledge or ignorance by the proposer with/of applicable laws will in no way be a cause for relief from responsibility. Proposer agrees that the services provided shall be provided by employees that are educated, trained, experienced, certified, and licensed in all areas encompassed within their designated duties. Proposer agrees to furnish to the City any and all documentation, certification, authorization, license, permit, or registration currently required by applicable laws, rules, and regulations. Proposer further certifies that it and its employees will keep all licenses, permits, registrations, authorizations, or certifications required by applicable laws or regulations in full force and effect during the term of this contract. Failure of proposer to comply with this paragraph shall constitute a material breach of this contract. Where contractor is required to enter or go on to City of Miami Beach property to deliver materials or perform work or RFQ 2014-346-SCR 7 Ai\I AM I BEACH services as a result of any contract resulting from this solicitation, the contractor will assume the full duty, obligation and expense of obtaining all necessary licenses, permits, and insurance, and assure all work complies with all applicable laws. The contractor shall be liable for any damages or loss to the City occasioned by negligence of the proposer,or its officers, employees, contractors, and/or agents,for failure to comply with applicable laws. 23. SPECIAL CONDITIONS. Any and all Special Conditions that may vary from these General Terms and Conditions shall have precedence. 24. ANTI-DISCRIMINATION. The proposer certifies that he/she is in compliance with the non-discrimination clause contained in Section 202, Executive Order 11246, as amended by Executive Order 11375, relative to equal employment opportunity for all persons without regard to race,color, religion,sex or national origin. 25. DEMONSTRATION OF COMPETENCY. A. Pre-award inspection of the Proposer's facility may be made prior to the award of contract. B. Statement of Qualifications will only be considered from firms which are regularly engaged in the business of providing the goods and/or services as described in this solicitation. C. Proposals must be able to demonstrate a good record of performance for a reasonable period of time, and have sufficient financial capacity, equipment, and organization to ensure that they can satisfactorily perform the services if awarded a contract under the terms and conditions of this solicitation. D. The terms "equipment and organization", as used herein shall, be construed to mean a fully equipped and well established company in line with the best business practices in the industry, and as determined by the City of Miami Beach. E. The City may consider any evidence available regarding the financial, technical, and other qualifications and abilities of a proposer, including past performance (experience), in making an award that is in the best interest of the City. F.The City may require proposer s to show proof that they have been designated as authorized representatives of a manufacturer or supplier,which is the actual source of supply. In these instances,the City may also require material information from the source of supply regarding the quality, packaging, and characteristics of the products to be supply to the City. 26. ASSIGNMENT. The successful proposer shall not assign, transfer, convey, sublet or otherwise dispose of the contract, including any or all of its right, title or interest therein, or his/her or its power to execute such contract, to any person,company or corporation,without the prior written consent of the City. 27. LAWS, PERMITS AND REGULATIONS. The proposer shall obtain and pay for all licenses, permits, and inspection fees required to complete the work and shall comply with all applicable laws. 28. OPTIONAL CONTRACT USAGE.When the successful proposer(s) is in agreement, other units of government or non-profit agencies may participate in purchases pursuant to the award of this contract at the option of the unit of government or non-profit agency. 29. VOLUME OF WORK TO BE RECEIVED BY CONTRACTOR. It is the intent of the City to purchase the goods and services specifically listed in this solicitation from the contractor. However, the City reserves the right to purchase any goods or services awarded from state or other governmental contract, or on an as-needed basis through the City's spot market purchase provisions. 30. DISPUTES. In the event of a conflict between the documents, the order of priority of the documents shall be as follows: A. Any contract or agreement resulting from the award of this solicitation; then RFQ 4-S;6=8R 6-SR g MIAMI B. Addendum issued for this solicitation, with the latest Addendum taking precedence;then C. The solicitation;then D. The proposer's proposal in response to the solicitation. 31. INDEMNIFICATION. The contractor shall indemnify and hold harmless the City and its officers, employees, agents and instrumentalities from any and all liability, losses or damages, including attorney's fees and costs of defense, which the City or its officers, employees, agents or instrumentalities may incur as a result of claims, demands, suits, causes of actions or proceedings of any kind or nature arising out of, relating to or resulting from the performance of the agreement by the contractor or its employees, agents, servants, partners, principals or subcontractors. The contractor shall pay all claims and losses in connection therewith, and shall investigate and defend all claims, suits or actions of any kind or nature in the name of the City,where applicable, including appellate proceedings, and shall pay all costs,judgments, and attorney's fees which may be incurred thereon. The contractor expressly understands and agrees that any insurance protection required by this Agreement or otherwise provided by the contractor shall in no way limit the responsibility to indemnify, keep and save harmless and defend the City or its officers, employees, agents and instrumentalities as herein provided. The above indemnification provisions shall survive the expiration or termination of this Agreement. 32. CONTRACT EXTENSION., The City reserves the right to require the Contractor to extend contract past the stated termination date for a period of up to 120 days in the event that a subsequent contract has not yet been awarded. Additional extensions past the 120 days may occur as needed by the City and as mutually agreed upon by the City and the contractor. 33. FLORIDA PUBLIC RECORDS LAW. Proposals are hereby notified that all Bid including, without limitation, any and all information and documentation submitted therewith, are exempt from public records requirements under Section 119.07(1), Florida Statutes, and s. 24(a), Art. 1 of the State Constitution until such time as the City provides notice of an intended decision or until thirty (30) days after opening of the proposals, whichever is earlier. Additionally, Contractor agrees to be in full compliance with Florida Statute 119.0701 including, but not limited to, agreement to(a) Keep and maintain public records that ordinarily and necessarily would be required by the public agency in order to perform the services; (b) provide the public with access to public records on the same terms and conditions that the public agency would provide the records and at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law; (c) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law; (d) Meet all requirements for retaining public records and transfer, at no cost, to the public agency all public records in possession of the contractor upon termination of the contract and destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. All records stored electronically must be provided to the public agency in a format that is compatible with the information technology systems of the public agency. 34. MODIFICATIONNVITHDRAWALS OF QUALIFICATIONS. A Proposer may submit a modified Statement of Qualifications to replace all or any portion of a previously submitted Statement of Qualifications up until the Statement of Qualifications due date and time. Modifications received after the Statement of Qualifications due date and time will not be considered. Statement of Qualifications shall be irrevocable until contract award unless withdrawn in writing prior to the Statement of Qualifications due date, or after expiration of 120 calendar days from the opening of Statement of Qualifications without a contract award. Letters of withdrawal received after the Statement of Qualifications due date and before said expiration date, and letters of withdrawal received after contract award will not be considered. RFQ Ol4- 46-SR 9 MIAMI BEACH 35. EXCEPTIONS TO RFQ. Proposals must clearly indicate any exceptions they wish to take to any of the terms in this RFQ, and outline what, if any, alternative is being offered. All exceptions and alternatives shall be included and clearly delineated, in writing, in the Statement of Qualifications. The City, at its sole and absolute discretion,may accept or reject any or all exceptions and alternatives. In cases in which exceptions and alternatives are rejected, the City shall require the Proposer to comply with the particular term and/or condition of the RFQ to which Proposer took exception to (as said term and/or condition was originally set forth on the RFQ). 36.ACCEPTANCE OF GIFTS, FAVORS, SERVICES. Proposals shall not offer any gratuities, favors, or anything of monetary value to any official, employee, or agent of the City, for the purpose of influencing consideration of this Statement of Qualifications. Pursuant to Sec. 2-449 of the City Code, no officer or employee of the City shall accept any gift, favor or service that might reasonably tend improperly to influence him in the discharge of his official duties. RFQ 2014-346-SR 10 M!rA, ! BEACH SECTION 0300 SUBMITTAL INSTRUCTIONS AND FORMAT 1. SEALED RESPONSES. One original Statement of Qualifications (preferably in 3-ring binder) must be submitted in an opaque, sealed envelope or container on or before the due date established for the receipt of proposals. Additionally, ten (10) bound copies and one (1) electronic format (CD or USB format) are to be submitted. The following information should be clearly marked on the face of the envelope or container in which the proposal is submitted: solicitation number, solicitation title, proposer name, proposer return address. Statement of Qualifications received electronically,either through email or facsimile, are not acceptable and will be rejected. 2. LATE PROPOSALS. Statements of Qualifications are to be received on or before the due date established herein for the receipt of proposals. Any proposal received after the deadline established for receipt of Statement of Qualifications will be considered late and not be accepted or will be returned to proposer unopened.The City does not accept responsibility for any delays,natural or otherwise. 3. STATEMENTS OF QUALIFICATIONS FORMAT. In order to maintain comparability,facilitate the review process and assist the Evaluation Committee in review of Statement of Qualifications, it is strongly recommended that Statement of Qualifications be organized and tabbed in accordance with the sections and manner specified below. Hard copy submittal should be tabbed as enumerated below and contain a table of contents with page references. Electronic copies should also be tabbed and contain a table of contents with page references. Statement of Qualifications that do not include the required information will be deemed non-responsive and will not be considered. Proposals shall clearly indicate if qualifications are being sought under Group A — Architecture andlor Group B— Engineering. Furthermore, firms are required to submit separate proposals for each specialized category under the respective group for which they seek qualifications. Example: a firm which provides landscape architecture and interior design/space planning, shall respond under Group A — Architecture and shall submit two (2) proposals under said group; a proposal seeking qualifications under landscape architecture and a proposal seeking qualifications under interior design/space planning. TAB 1 Cover Letter&Minimum Qualifications Requirements 1.1 Cover Letter and Table of Contents. The cover letter must indicate Proposer, Proposer Primary Contact, Qualification Group (A and/or B), area of specialization, a summary of the Proposer's qualifications, experience, and services to be provided. 1.2 Response Certification, Questionnaire & Requirements Affidavit (Appendix A). Attach Appendix A fully completed and executed. 1.3 Minimum Qualifications Requirements. Submit verifiable information documenting compliance with the minimum qualifications requirements established in Appendix C Minimum Requirements and Specifications. a) For each architect and engineer, provide copies of all applicable licenses and certifications. Architects and engineers must be licensed by the Florida Department of Business and Professional Regulation. b) For Landscape Architects,provide copies of the following certifications: a. International Society of Arboriculture Certification, Landscape Inspectors Association of Florida Certification, FNGLA Certification c) For Planning, Urban,and Historical Preservation Architects, provide copies of the following certifications or memberships: a. LEED, ULI,AICP,APA. RFQ 2014-346-YG 11 MIA;\A BEACH d) Environmental Engineering firms providing General Environmental Services, Environmental and Coastal Permitting,and Contamination Assessment,provide copies of the following: a. Staffs accredited college diploma or Bachelor's degree in Environmental Sciences or related field. TAB 2 Experience&Qualifications PROPOSERS MAY SUBMIT THE BELOW REQUESTED INFORMATION UTILIZING THE ENCLOSED STANDARD FORM 330—ARCHITECT-ENGINEER QUALIFICATIONS(ATTACHED). 2.1 Qualifications of Proposing Firm. Submit detailed information regarding the firm's history and relevant experience and proven track record of providing the scope of services as identified in this solicitation, including experience in providing scope of services to public sector agencies. Proposer must submit five (5) relevant projects, performed in the last five (5) years as evidence of experience; the following is required: project description, agency name, agency contact,contact telephone&email, and year(s)and term of engagement. 2.2 Qualifications of Proposer Team (Architects and Engineers). Provide an organizational chart of all personnel and consultants to be used for this project if awarded,the role that each team member will play in providing the services detailed herein and each team members' qualifications. A resume of each individual, including education, experience, and any other pertinent information, shall be included for each respondent team member to be assigned to this contract. For each architect and engineer, include information for five (5) relevant projects, performed in the last five(5)years for public sector clients. Relevant projects shall include those projects similar in scope to those services listed in this RFQ. 2.3 Financial Capacity. Each proposer shall arrange for Dun & Bradstreet to submit a Supplier Qualification Report (SQR)directly to the Procurement Contact named herein. No proposal will be considered without receipt, by the City, of the SQR directly from Dun & Bradstreet. The cost of the preparation of the SQR shall be the responsibility of the Proposer.The Proposer shall request the SQR report from D&B at: https://supplierportal.dnb.com/webapp/wcs/stores/servlet/SupplierPortal?storeld=11696 Proposals are responsible for the accuracy of the information contained in its SQR. It is highly recommended that each proposer review the information contained in its SQR for accuracy prior to submittal to the City and as early as possible in the solicitation process. For assistance with any portion of the SQR submittal process, contact Dun & Bradstreet at 800-424-2495. RFQ 2014-346-SR 12 MIAMI B EAC H TAB 3 Approach and Methodology For the scope of services outlined in Tab 3, Scope of Services, submit detailed information on the approach and methodology, how Proposer plans to accomplish the proposed scope of services, including detailed information, as applicable, which addresses, but need not be limited to: implementation plan, project timeline, phasing options, testing and risk mitigation options for assuring project is implemented on time and within budget. It is the objective of the City that the majority of the services defined herein be performed directly by the Proposer (rather than through sub-consultants). To evaluate compliance with this objective, proposers shall explain how they plan to accomplish this, denoting which sections of the scope shall be performed directly by the Firm (with its own forces) and which sections are intended to be subcontracted. Also, provide information on Proposer's current workload and how the potential project(s) will fit into Proposer's workload. Describe available facilities, technological capabilities and other available resources you offer for the potential project(s). Lastly, submit verifiable evidence of Proposer's intent to utilize Disadvantaged Business Enterprise (DBE) Firms. Accepted DBE certifications include the Small Business Administration (SBA), State of Florida, or Miami-Dade County. Note: After proposal submittal, the City reserves the right to require additional information from Proposer (or proposer team members or sub-consultants) to determine: qualifications (including, but not limited to, litigation history, regulatory action, or additional references); and financial capability (including, but not limited to, annual reviewed/audited financial statements with the auditors notes for each of their last two complete fiscal years). RFC 2014-346-SR 13 MIAMI BEACH SECTION 0400 STATEMENTS OF QUALIFICATIONS EVALUATION 1. Evaluation Committee. An Evaluation Committee, appointed by the City Manager, shall meet to evaluate each Statement of Qualifications in accordance with the requirements set forth in the solicitation. If further information is desired, Proposals may be requested to make additional written submissions of a clarifying nature or oral presentations to the Evaluation Committee. The evaluation of Statement of Qualifications will proceed in a two-step process as noted below. It is important to note that the Evaluation Committee will score the qualitative portions of the Statement of Qualifications only. The Evaluation Committee does not make an award recommendation to the City Manager. The results of Step 1 &Step 2 Evaluations will be forwarded to the City Manager who will utilize the results to make a recommendation to the City Commission. 2. Step 1 Evaluation. Proposals will be categorized into the discipline areas noted in section 0200-2(Groups A & B) prior to evaluation by the committee in order that proposals may be evaluated by category against other proposers in that category. The first step will consist of the qualitative criteria listed below to be considered by the Evaluation Committee. The second step will consist of quantitative criteria established below to be added to the Evaluation Committee results by the Department of Procurement. An Evaluation Committee, appointed by the City Manager, shall meet to evaluate each Statement of Qualifications in accordance with the qualifications criteria established below for Step 1, Qualitative Criteria. In doing so, the Evaluation Committee may: • review and score all Statement of Qualifications received, with or without conducting interview sessions;or • review all Statement of Qualifications received and short-list one or more Proposer to be further considered during subsequent interview session(s)(using the same criteria). Step 1 -Qualitative Criteria Maximum Points Proposing Firm — Experience and Qualifications, including Financial 40 Capability Proposing Team (Architects and Engineers) — Experience and 40 Qualifications Approach and Methodology, including Self-Performance of Work and 15 utilization of Disadvantased Business Ente 'rise DBE firms. TOTAL AVAILABLE STEP 1 POINTS 95 3. Step 2 Evaluation. Following the results of Step 1 Evaluation of qualitative criteria, the Proposer may receive additional quantitative criteria points to be added by the Department of Procurement to those points earned in Step 1, as follows. Step 2-Quantitative Criteria Veterans Preference 5 The volume of work previously awarded to each firm by the City 5 within the last three 3)years.See Section 4 below. TOTAL AVAILABLE STEP 2 POINTS 10 4. Volume of Work Points: Points awarded to the proposer for volume of work awarded by the City in the last three(3)years in accordance with the following table: Less than$250,000 5 $250,000.01 $2,000,000 3 - Greater than$2,000,000 0 RFQ 2014-346-YG 14 AIAMI BEACH 5. Determination of Final Ranking. At the conclusion of the Evaluation Committee Step 1 scoring, Step 2 Points will be added to each evaluation committee member's scores by the Department of Procurement. Step 1 and 2 scores will be converted to rankings in accordance with the example below: Proposer Proposer Proposer A B C Step 1 Points 82 76 80 Step 2 Points 22 15 12 Committee._. Total 104 91 92 Member 1 Rank. . 1 3 .. 2 Step 1 Points 79 85 72 Step 2 Points 22 15 12 Committee Total 101 100 84 Member2 Rank: - 1 2 : 3 Step 1 Points 80 74 66 Step 2 Points 22 15 12 Committee Total 102 89 78 ..Member 2• ; . Rank -.1 . 2 .. • .3 Low Aggregate Score 3 7 8 Final Ranking* 1 2 3 *Final Ranking is presented to the City Manager for further due diligence and recommendation to the City Commission. Final Ranking does not constitute an award recommendation until such time as the City Manager has made his recommendation to the City Commission, which may be different than final ranking results. RF Q 0l -346-SR 1 5 APPENDIX A MIAMI 1IEAEIT ;H:44\ Response Certification , Questionnaire & Requirements Affidavit RFQ No. 201 4-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS " DEPARTMENT OF PROCUREMENT 700 Convention Center Drive Miami Beach, Florida 33139 Solicitation No: Solicitation Title: RFQ 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN"AS-NEEDED-BASIS" Procurement Contact Tel: Email: Yusbel Gonzalez 305.673.7000,Ext.6230 yusbelgonzalez a(�,miamibeachfl:gov STATEMENTS OF QUALIFICATIONS CERTIFICATION, QUESTIONNAIRE &REQUIREMENTS AFFIDAVIT Purpose: The purpose of this Response Certification, Questionnaire and Requirements Affidavit Form is to inform prospective Proposals of certain solicitation and contractual requirements, and to collect necessary information from Proposals in order that certain portions of responsiveness, responsibility and other determining factors and compliance with requirements may be evaluated. This Statement of Qualifications Certification, Questionnaire and Requirements Affidavit Form is a REQUIRED FORM that must be submitted fully completed and executed. 1.. General Proposer Information. FIRM NAME: No of Years in Business: No of Years in Business Locally: No of Employees: OTHER NAME(S)PROPOSER HAS OPERATED UNDER IN THE LAST 10 YEARS: FIRM PRIMARY ADDRESS(HEADQUARTERS): CITY: STATE: ZIP CODE: TELEPHONE NO.: TOLL FREE NO.: FAX NO.: FIRM LOCAL ADDRESS: CITY: STATE: ZIP CODE: PRIMARY ACCOUNT REPRESENTATIVE FOR THIS ENGAGEMENT: ACCOUNT REP TELEPHONE NO.: ACCOUNT REP TOLL FREE NO.: ACCOUNT REP EMAIL: FEDERAL TAX IDENTIFICATION NO.: The City reserves the right to seek additional information from proposer or other source(s), including but not limited to: any firm or principal information,applicable licensure,resumes of relevant individuals,client information,financial information,or any information the City deems necessary to evaluate the capacity of the proposer to perform in accordance with contract requirements. -�.'� .�.'ai�3sTne".s-.o�,c*..y f"%moist-,'f .�s:'�/if�i.w�:: :?A-tHf.�Z'=>s.'.KI.S=.-f.,•.ix�'SSY��M'.-.��bY': ���1X.d;�:.��.-.a�la-�:":�.a,.,.�+.�r7u fiY..:.r.��'...ss:,m.c.Nakzan-:ism'�...aissrer=N.5t6'rs:..:'t-'-r�as'H�..`�z,,.,.-:._s� :sse RFQ 2014 346-YG Appendix A— Page 1 1. Veteran Owned Business.Is ro oser claiming a veteran owned business status? YES J NO SUBMITTAL REQUIREMENT: Proposals claiming veteran owned business status shall submit a documentation proving that firm is certified as a veteran-owned business or a service-disabled veteran owned business by the State of Florida or United States federal government,as required pursuant to ordinance 2011-3748. 2. Conflict Of Interest.All Proposals must disclose,in their Statement of Qualifications,the name(s)of any officer,director,agent,or immediate family member(spouse, parent,sibling, and child)who is also an employee of the City of Miami Beach. Further, all Proposals must disclose the name of any City employee who owns,either directly or indirectly,an interest of ten(10%)percent or more in the Proposer entity or any of its affiliates. SUBMITTAL REQUIREMENT: Proposals must disclose the name(s)of any officer, director, agent, or immediate family member (spouse,parent,sibling,and child)who is also an employee of the City of Miami Beach. Proposals must also disclose the name of any City employee who owns,either directly or indirectly,an interest of ten(10%)percent or more in the Proposer entity or any of its affiliates 3. Suspension,Debarment or Contract Cancellation.Has proposer ever been debarred,suspended or other legal violation,or had a contract cancelled due to non- erformance by an ublic sector agency? YES NO SUBMITTAL REQUIREMENT: If answer to above is"YES,"Proposer shall submit a statement detailing the reasons that led to action(s). 4. Vendor Campaign Contributions. Proposals are expected to be or become familiar with, the City's Campaign Finance Reform laws, as codified in Sections 2-487 through 2-490 of the City Code. Proposals shall be solely responsible for ensuring that all applicable provisions of the City's Campaign Finance Reform laws are complied with,and shall be subject to any and all sanctions, as prescribed therein,including disqualification of their Statement of Qualifications,in the event of such non-compliance. SUBMITTAL REQUIREMENT: Submit the names of all individuals or entities (including your sub-consultants) with a controlling financial interest as defined in solicitation. For each individual or entity with a controlling financial interest indicate whether or not each individual or entity has contributed to the campaign either directly or indirectly,of a candidate who has been elected to the office of Mayor or City Commissioner for the City of Miami Beach. 5. Code of Business Ethics.Pursuant to City Resolution No.2000-23879,each person or entity that seeks to do business with the City shall adopt a Code of Business Ethics("Code")and submit that Code to the Procurement Division with its proposal/response or within five(5)days upon receipt of request.The Code shall,at a minimum,require the Proposer,to comply with all applicable governmental rules and regulations including, among others, the conflict of interest, lobbying and ethics provision of the City of Miami Beach and Miami Dade County. SUBMITTAL REQUIREMENT: Proposer shall submit firm's Code of Business Ethics. In lieu of submitting Code of Business Ethics,proposer may submit a statement indicating that it will adopt,as required in the ordinance,the City of Miami Beach Code of Ethics,available at www•miamibeachfl.gov/procurement/. 6. - - - - '! - _-- - • -- - - • • • •- - - RFQ 2014-346 YG Appendix A- Page 2 • 7. Equal Benefits for Employees with Spouses and Employees with Domestic Partners.When awarding competitively solicited contracts valued at over$100,000 whose contractors maintain 51 or more full time employees on their payrolls during 20 or more calendar work weeks,the Equal Benefits for Domestic Partners Ordinance 2005-3494 requires certain contractors doing business with the City of Miami Beach,who are awarded a contract pursuant to competitive proposals,to provide'Equal Benefits"to their employees with domestic partners, as they provide to employees with spouses. The Ordinance applies to all employees of a Contractor who work within the City limits of the City of Miami Beach,Florida;and the Contractor's employees located in the United States, but outside of the City of Miami Beach limits, who are directly performing work on the contract within the City of Miami Beach. A. Does your company provide or offer access to any benefits to employees with spouses or to spouses of employees? YES NO B. Does your company provide or offer access to any benefits to employees with(same or opposite sex)domestic partners"or to domestic partners of employees? YES NO C. Please check all benefits that apply to your answers above and list in the "other" section any additional benefits not already specified. Note:some benefits are provided to employees because they have a spouse or domestic partner,such as bereavement leave;other benefits are provided directly to the spouse or domestic partner,such as medical insurance. BENEFIT Firm Provides for Firm Provides for Firm does not Employees with Employees with Provide Benefit Spouses Domestic Partners Health Sick Leave Family Medical Leave Bereavement Leave If Proposer cannot offer a benefit to domestic partners because of reasons outside your control, (e.g., there are no insurance providers in your area willing to offer domestic partner coverage)you may be eligible for Reasonable Measures compliance.To comply on this basis, you must agree to pay a cash equivalent and submit a completed Reasonable Measures Application (attached)with all necessary documentation.Your Reasonable Measures Application will be reviewed for consideration by the City Manager, or his designee.Approval is not guaranteed and the City Manager's decision is final. Further information on the Equal Benefits requirement is available at www.miamibeachfl.gov/procurement/. 8. Public Entity Crimes.Section 287.133(2)(a),Florida Statutes,as currently enacted or as amended from time to time,states that a person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a proposal, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a proposal, proposal,or reply on a contract with a public entity for the construction or repair of a public building or public work;may not submit proposals, Statement of Qualifications,or replies on leases of real property to a public entity;may not be awarded or perform work as a contractor,supplier, subcontractor,or consultant under a contract with any public entity;and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list. SUBMITTAL REQUIREMENT:No additional submittal is required. By virtue of executing this affidavit document,proposer agrees with the requirements of Section 287.133,Florida Statutes,and certifies it has not been placed on convicted vendor list. RFQ 2014-346-YG Appendix A— Page 3 9. Acknowledgement of Addendum. After issuance of solicitation,the City may release one or more addendum to the solicitation which may provide additional information to Proposer or alter solicitation requirements.The City will strive to reach every Proposer having received solicitation through the City's e-procurement system, PublicPurchase.com. However, Proposals are solely responsible for assuring they have received any and all addendum issued pursuant to solicitation. This Acknowledgement of Addendum section certifies that the Proposer has received all addendum released by the City pursuant to this solicitation.Failure to obtain and acknowledge receipt of all addendum may result in proposal disqualification. Initial to Confirm Initial to Confirm Initial to Confirm Receipt _ Receipt Receipt Addendum 1 Addendum 6 Addendum 11 Addendum 2 Addendum 7 Addendum 12 Addendum 3 Addendum 8 Addendum 13 Addendum 4 Addendum 9 Addendum 14 Addendum 5 _ Addendum 10 Addendum 15 if additional confirmation of addendum is required,submit under separate cover. RFQ 2014-346-YG Appendix A- Page 4 DISCLOSURE AND DISCLAIMER-SECTION The solicitation referenced herein is being furnished to the recipient by the City of Miami Beach(the"City")for the recipient's convenience. Any action taken by the City in response to Statement of Qualifications made pursuant to this solicitation,or in making any award,or in failing or refusing to make any award pursuant to such Statement of Qualifications, or in cancelling awards, or in withdrawing or cancelling this solicitation,either before or after issuance of an award,shall be without any liability or obligation on the part of the City. In its sole discretion,the City ty ma withdraw th e solicitation tation either before or after receiving Statement of Qualifications,may accept or reject Statement of Qualifications,and may accept Statement of Qualifications which deviate from the solicitation,as it deems appropriate and in its best interest.In its sole discretion,the City may determine the qualifications and acceptability of any party or parties submitting Statement of Qualifications in response to this solicitation. Following submission of Statement of Qualifications, the applicant agrees to deliver such further details, information and assurances, including financial and disclosure data, relating to the Statement of Qualifications and the applicant including, without limitation, the applicant's affiliates,officers,directors,shareholders,partners and employees,as requested by the City in its discretion. The information contained herein is provided solely for the convenience of prospective Proposals. It is the responsibility of the recipient to assure itself that information contained herein is accurate and complete.The City does not provide any assurances as to the accuracy of any information in this solicitation. Any reliance on these contents,or on any permitted communications with City officials,shall be at the recipient's own risk.Proposals should rely exclusively on their own investigations,interpretations,and analyses.The solicitation is being provided by the City without any warranty or representation,express or implied,as to its content,its accuracy,or its completeness. No warranty or representation is made by the City or its agents that any Statement of Qualifications conforming to these requirements will be selected for consideration, negotiation, or approval. The City shall have no obligation or liability with respect to this solicitation,the selection and the award process,or whether any award will be made.Any recipient of this solicitation who responds hereto fully acknowledges all the provisions of this Disclosure and Disclaimer,is totally relying on this Disclosure and Disclaimer,and agrees to be bound by the terms hereof.Any Statement of Qualifications submitted to the City pursuant to this solicitation are submitted at the sole risk and responsibility of the party submitting such Statement of Qualifications. This solicitation is made subject to correction of errors,omissions,or withdrawal from the market without notice.Information is for guidance only,and does not constitute all or any part of an agreement. The City and all Proposals will be bound only as,if and when a Statement of Qualifications,as same may be modified, and the applicable definitive agreements pertaining thereto, are approved and executed by the parties, and then only pursuant to the terms of the definitive agreements executed among the parties.Any response to this solicitation may be accepted or rejected by the City for any reason,or for no reason,without any resultant liability to the City. The City is governed by the Government-in-the-Sunshine Law, and all Statement of Qualifications and supporting documents shall be subject to disclosure as required such subject q d by suc law.All Statement of Qualifications shall be submitted in sealed proposal form and shall remain confidential to the extent permitted by Florida Statutes, until the date and time selected for opening the responses. At that time, all documents received by the City shall become public records. Proposals are expected to make all disclosures and declarations as requested in this solicitation. By submission of a Statement of Qualifications,the Proposer acknowledges and agrees that the City has the right to make any inquiry or investigation it deems appropriate to substantiate or supplement information contained in the Statement of Qualifications, and authorizes the release to the City of any and all information sought in such inquiry or investigation. Each Proposer certifies that the information contained in the Statement of Qualifications is true,accurate and complete,to the best of its knowledge,information,and belief. Notwithstanding the foregoing or anything contained in the solicitation,all Proposals agree that in the event of a final unappealable judgment by a court of competent jurisdiction which imposes on the City any liability arising out of this solicitation, or any response thereto, or any action or inaction by the City with respect thereto,such liability shall be limited to$10,000.00 as agreed-upon and liquidated damages.The previous sentence, however, shall not be construed to circumvent any of the other provisions of this Disclosure and Disclaimer which imposes no liability on the City. In the event of any differences in language between this Disclosure and Disclaimer and the balance of the solicitation, it is understood that the provisions of this Disclosure and Disclaimer shall always govern.The solicitation and any disputes arising from the solicitation shall be governed by and construed in accordance with the laws of the State of Florida. RFQ 2014 346-YG Appendix A — Page 5 PROPOSER CERTIFICATION I hereby certify that: I,as an authorized agent of the Proposer,am submitting the following information as my firm's proposal; Proposer agrees to complete and unconditional acceptance of the terms and conditions of this document, inclusive of this solicitation, all attachments, exhibits and appendices and the contents of any Addenda released hereto, and the Disclosure and Disclaimer Statement; proposer agrees to be bound to any and all specifications, terms and conditions contained in the solicitation, and any released Addenda and understand that the following are requirements of this solicitation and failure to comply will result in disqualification of proposal submitted; Proposer has not divulged,discussed, or compared the proposal with other Proposals and has not colluded with any other proposer or party to any other proposal; proposer acknowledges that all information contained herein is part of the public domain as defined by the State of Florida Sunshine and Public Records Laws; all responses, data and information contained in this proposal, inclusive of the Statement of Qualifications Certification,Questionnaire and Requirements Affidavit are true and accurate. Name of Proposer's Authorized Representative: Title of Proposer's Authorized Representative: Signature of Proposer's Authorized Representative: Date: State of FLORIDA ) On this day of ,20_,personally appeared before me who County of ) stated that (s)he is the of_ , a corporation, and that the instrument was signed in behalf of the said corporation by authority of its board of directors and acknowledged said instrument to be its voluntary act and deed. Before me: Notary Public for the State of Florida My Commission Expires: RFQ 2014 346-YG Appendix A— Page 6 APPENDIX B J\/\ I 4 bb o Bid " RFQ No. 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" DEPARTMENT OF PROCUREMENT 1700 Convention Center Drive Miami Beach, Florida 33139 Note: It is intent for those vendors who have received notification of this solicitation but have decided not to respond to complete and submit the attached "Statement of No Bid." The "Statement of No Bid" provides the City with information on how to improve the solicitation process. Faffure to submit a "Statement of Na Bid" may result in not being notified of future solicitations WilicitOttPhs.by the Statement of No Bid WE HAVE ELECTED NOT TO SUBMIT A STATEMENTS OF QUALIFICATIONS AT THIS TIME FOR REASON(S) CHECKED AND/OR INDICATED BELOW: Workload does not allow us to proposal Insufficient time to respond —Specifications unclear or too restrictive Unable to meet specifications Unable to meet service requirements Unable to meet insurance requirements Do not offer this product/service _OTHER. (Please specify) We do—do not`want to be retained on your mailing list for future proposals of this type product and/or service. Signature: Title: Legal Company Name: Note: Failure to respond, either by submitting a proposal or this completed form, may result in your company being removed from our vendors list. PLEASE RETURN TO: CITY OF MIAMI BEACH PROCUREMENT DEPARTMENT ATTN: Yusbel Gonzalez STATEMENTS OF QUALIFICATIONS #2014-346-YG 1700 Convention Center Drive MIAMI BEACH, FL 33139 2.._•"Y.a.•Y�w.4':.:�.:._'. l..�.-{!-.T.b,i\i ^.:. -'t!..�+1�..:.�?...E��.l�..�"•_ .7....ia._i-i ::aC...:2-�'ti>:.C.:....:-et_.ls.u. •i...+. - .., ...m.-,-... tt 4 W'..:s..:ids..^,r_n .t'.<i.:-,r::.i:4 RFQ 2014-346—YG Appendix B - Page 1 APPENDIX C M1Af\/\ IJ: E4CL Minimum Requirements & Specifications RFQ No . 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" DEPARTMENT OF PROCUREMENT 1700 Convention Center Drive Miami Beach, Florida 33139 Cl.MINIMUM REQUIREMENTS: The Minimum Eligibility Requirements for this solicitation are listed below. Proposer shall clearly indicate if qualifications are being sought under Group A—Architecture and/or Group B— Engineering. Proposer shall submit detailed verifiable information affirmatively documenting compliance with each minimum requirement. Proposals that fail to comply with minimum requirements will be deemed non-responsive and will not be considered. • Proposer must have a minimum of five (5) years' experience and successfully completed at least five(5)projects for public sector agencies. • Architects and Engineers must have a minimum of five (5) years' experience and successfully completed at least five (5) projects in their designated professional specialization for public sector agencies. • Architects and engineers must be licensed by the Florida Department of Business and Professional Regulation. o Landscape Architects must be certified by International Society of Arboriculture Certification, Landscape Inspectors Association of Florida Certification, FNGLA Certification. o Planning, Urban,and Historical Preservation Architects certified or members of LEED, ULI,AICP,APA is preferred. o Environmental Engineering firms providing General Environmental Services, Environmental and Coastal Permitting, and Contamination Assessment, must have staffs with accredited college diploma or Bachelor's degree in Environmental Sciences or related field. This RFQ is issued pursuant to Chapter 287.055, Florida Statutes, the Consultants Competitive Negotiations Act(CCNA). C2. SCOPE OF WORK REQUIRED. It is the intent of the City of Miami Beach to select several firms which will be contacted on an "as- needed basis" during the term of the contract. This contract will include, but not be limited to the following architectural or engineering services: Description • Acoustics, Noise Abatement • Air Pollution Control • Auditoriums and Theaters • Automation; Controls; Instrumentation • Boundary Survey • Bridges • Codes;Standards; Ordinances • Coastal Engineering(Seawall Design and Repair) • Coastal Surveys • Communications Systems;TV; Microwave RFQ 2014-346-YG Appendix C • Construction Management • Cost Estimating • Dune Planting and Management • Energy Conservation; New Energy Sources • General Environmental Services: o Environmental Assessments o Air and Water quality testing and monitoring o Environmental sustainability planning services o Environmental support services to achieve and maintain regulatory compliance • Environmental and Coastal Permitting: o Prepare and submit applications for and lead agency coordination in obtaining environmental and coastal permits; and, o Prepare supporting documentation required for environmental and coastal permits including but not limited to biological reports, flora and fauna surveys, and other environmental assessments. o Work with Federal, State, County, and other local environmental permitting agencies, including but not limited to the U.S. Army Corps of Engineers, the South Florida Water Management District, the Florida Department of Environmental Protection, and Miami-Dade County's Division of Environmental Resources Management. • Contamination Assessment: o Environmental Site Assessments o Oversee and coordinate remediation project o Preparation of sampling and remediation plans and other related documents o Other associated tasks related to regulatory compliance o Work on contamination projects in South Florida • Fire Protection • Garages;Vehicle Maintenance Facilities; Parking Decks • Heating; Ventilating; Air Conditioning • Highways; Streets;Airfield Paving; Parking Lots • Interior Design;Space Planning • Irrigation; Drainage • Lab Testing Services • Landscape Architecture • Lighting (Interior, Display, Theater, etc.) • Lighting(Exterior, Streets, Memorials,Athletic Fields, etc.) • Planning (Community, Regional,Area-wide and State) • Plumbing and Piping Design • Recreation Facilities(Parks, Marinas,etc.) • Rehabilitation(Buildings, Structures, Facilities,etc.) • Right-of-Way Survey • Safety Engineering;Accident Studies; OSHA Studies • Security Systems; Intruder&Smoke Detection • Sewage Collection, Treatment and Disposal • Soils&Geologic Studies; Foundations • Storage Tank Repair and Monitoring • Structural Design; Special Structures RFQ 2014-346-YG Appendix C • Surveying, Mapping, GIS, and other services: o High Definition Services(HDS) o Light Detection and Ranging (LiDAR) o Global Navigation Satellite Systems(GLASS) o Ground Penetration Radar(GPR) o Subsurface Utility Engineering(SUE)and Underground Utility Services o These specialized services may be utilized for surveys to include but not limited to Specific or Special Purpose, Topographic (surveys for engineering design), As- Built/Record, Boundary, Condominium, Construction Layout, Control, Hydrographic, Mean High Water, Quantity, Submerged/Filled Lands as well as GIS feature creation • Control and Data Services: o Establishing vertical and horizontal control o Researching and utilizing record documents for right-of-ways etc. Locations of all • improvements, features as required in the City of Miami Beach Public Works Department Manual and/or as designated for a specific project. All field data is to be collected in digital form Point Clouds (Text XYZ Coordinate files, etc.)with horizontal and vertical control points identified and recorded in field books. The digital data shall be post processed and delivered to the City as specified herein. Survey control for Vertical Control shall be referenced to the North American Vertical Datum of 1988 (NAVD1988) and the Horizontal Control shall be referenced to Florida State Plane Coordinates, East Zone, North American Datum of 1983/1990 (NAD83190) supplemented with digital data files including but not limited to processed HDS and LiDAR Point Clouds with Photographics, ESRI File Geodatabases, ESRI Shapefiles (.SHP), and .DWG format drawings of the Surveys, Maps, GIS Data Sets etc. • Platting; Mapping;Flood Plain Studies • Swimming Pools • Storm Water Handling&Facilities • Testing &Inspection Services • Topa Survey • Urban Renewals; Community Development • Value Analysis; Life-Cycling Costing • Water Supply,Treatment and Distribution • Zoning;Land Use Studies • Any other professional service pursuant to Section 287.055, Florida Statutes, commonly known as the Consultants'Competitive Negotiation Act(CCNA). The selected architectural and/or engineering firms will be responsible for reviewing all existing City of Miami Beach Zoning Ordinances and Building Codes. The teams will be responsible for incorporating all the above data into complete construction documents, including final working drawings, specifications, and bid documents necessary for the bidding and construction of the project, and in some instances, for construction management. The construction documents and drawings must comply with the City of Miami Beach DSM and Florida Status(particularly surveys). The selected firms will be responsible for obtaining all State, Federal and local permits and approvals necessary for the construction of all projects, and may be required to provide consulting services to the City on various matters which do not result in drawings or specifications. RFQ 2014-346-YG Appendix C APPENDIX D A Li, AlorAfr-41 .4 \/ o rrAk, g Special Conditions RFQ No. 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" DEPARTMENT OF PROCUREMENT 1700 Convention Center Drive Miami Beach, Florida 33139 RFolO14-346-iG — — Appendix C 1. TERM OF CONTRACT. Three(3)years. 2. OPTIONS TO RENEW. Two (2) additional one(1)year options 3. PRICES. Not Applicable. 4. EXAMINATION OF FACILITIES. Not Applicable. 5. INDEMNIFICATION. Not Applicable. 6. PERFORMANCE BOND. Not Applicable. 7. REQUIRED CERTIFICATIONS. Not Applicable. 8. SHIPPING TERMS. Not Applicable. 9. DELIVERY REQUIREMENTS. Not Applicable. 10.WARRANTY REQUIREMENTS. Not Applicable. 11. BACKGROUND CHECKS. Not Applicable. 12. ADDITIONAL TERMS OR CONDITIONS. This RFQ, including the attached Sample Contract, contains all the terms and conditions applicable to any service being provided to the City resulting from award of contract. By virtue of submitting a proposal, consultant agrees not to require additional terms and conditions at the time services are requested, either through a separate agreement, work order, letter of engagement or purchase order. RFQ 2014-346-YG Appendix D— Page 1 APPENDIX E M L.. A\ Insurance Requirements RFQ No. 201 4-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" DEPARTMENT OF PROCUREMENT 1700 Convention Center Drive Miami Beach, Florida 33139 I\ A I At f I D: L, A t .;,' i V \ 1 1 i 1/4.,, INSURANCE REQUIREMENTS This document sets forth the minimum levels of insurance that the contractor is required to i maintain throughout the term of the contract and any renewal periods. XXX 1. Workers' Compensation and Employer's Liability per the Statutory limits of the state of Florida. , XXX 2. Commercial General Liability on a comprehensive basis in an amount not less than $1,000,000 combined single limit per occurrence for bodily injury and property damage. City of Miami Beach must be shown as an additional insured with respect to this coverage. XXX 3. Automobile Liability Insurance covering all owned, non-owned and hired vehicles used in connection with the work, in an amount not less than $500,000 combined single limit per occurrence for bodily injury and property damage. XXX 4. Professional Liability Insurance in an amount not less than $1,000,000 with the deductible per claim, if any, not to exceed 10%of the limit of liability. XXX 5. The City must be named as and additional insured on the liability policies; and it must be stated on the certificate. 6. Other Insurance as indicated: Builders Risk completed value $ .00 Liquor Liability $ .00 Fire Legal Liability $ .00 9 Y Protection and Indemnity $ .00 — Employee Dishonesty Bond $ .00 —Other $ .00 XXX 7. Thirty(30)days written cancellation notice required. XXX 8. Best's guide rating"A"as to management and"Class V"as to financial strength or better, latest edition. XXX 9. The certificate must state the proposal number and title. The City of Miami Beach is self-insured. Any and all claim payments made from self-insurance are subject to the limits and provisions of Florida Statute 768.28, the Florida Constitution, and any other applicable Statutes. A waiver of subrogation in favor of the City must be included for the policies required above. The insurance coverage required shall include those classifications, as listed in standard liability insurance manuals, which most nearly reflect the operations of the vendor. CERTIFICATE HOLDER MUST READ: CITY OF MIAMI BEACH 1700 CONVENTION CENTER DRIVE 3rd FLOOR MIAMI BEACH, FL 33139 RFQ 2014-346-YG Appendix E — Page 1 APPENDIX F MIAMI "= AC - Sample Contract RFQ No. 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS " DEPARTMENT OF PROCUREMENT 1700 Convention Center Drive Miami Beach, Florida 33139 AGREEMENT BETWEEN CITY OF MIAMI BEACH AND XX)OOOOtXXX FOR PROFESSIONAL ARCHITECTURE AND ENGINEERING SERVICES FOR THE XXXX)ODUUCXXXXXXXX)OOOO O XXXXX CX Resolution No. TABLE OF CONTENTS DESCRIPTION PAGE ARTICLE 1 DEFINITIONS 2 ARTICLE 2. BASIC SERVICES 7 ARTICLE 3. THE CITY'S RESPONSIBILITIES 13 ARTICLE 4. RESPONSIBILITY FOR CONSTRUCTION COST 16 ARTICLE 5. ADDITIONAL SERVICES 17 ARTICLE 6. REIMBURSABLE EXPENSES 18 ARTICLE 7. COMPENSATION FOR SERVICES 19 ARTICLE 8. CONSULTANT'S ACCOUNTING AND OTHER RECORDS 20 ARTICLE 9. OWNERSHIP OF PROJECT DOCUMENTS 21 • ARTICLE 10. TERMINATION OF AGREEMENT 22 ARTICLE 11. INSURANCE 23 ARTICLE 12. INDEMNIFICATION AND HOLD HARMLESS 24 ARTICLE 13. ERRORS AND OMISSIONS 25 ARTICLE 14. LIMITATION OF LIABILITY 26 ARTICLE 15. NOTICE 26 ARTICLE 16. MISCELLANEOUS PROVISIONS 27 SCHEDULES: • SCHEDULE A SCOPE OF SERVICES 33 SCHEDULE B CONSULTANT COMPENSATION 34 SCHEDULE C HOURLY BILLING RATE 35 SCHEDULE D CONSTRUCTION COST BUDGET 36 SCHEDULE E PROJECT SCHEDULE 37 SCHEDULE F GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT 38 SCHEDULE G INSURANCE AND SWORN AFFIDAVITS 39 SCHEDULE H BEST VALUE AMENDMENT 40 TERMS AND CONDITIONS OF AGREEMENT BETWEEN THE CITY OF MIAMI BEACH AND X FOR PROFESSIONAL ARCHITECTURE AND ENGINEERING (NE) SERVICES FOR THE XXXXXXXXXXXX)OOOO( X)OOOOO (XX This Agreement made and entered into this day of , 20XX, by and between the CITY OF MIAMI BEACH, a municipal corporation existing under the laws of the State of Florida, having its principal offices at 1700 Convention Center Drive, Miami Beach, Florida, 33139, (hereinafter referred to as City), and XXXXXXXXXXXXXXXXXXXXXXXXXXXX, a Florida XXXXXXX)UUUC having its principal office at XX)UUU< XXXXXXX(hereinafter referred to as Consultant). • WITNESSETH: WHEREAS, the City intends to undertake a project within the City of Miami Beach, which is more particularly described in the Scope of Services attached as Schedule "A" hereto, and wishes to engage the Consultant to provide specific professional services including, without limitation, NE services, for the Project, at the agreed fees set forth in this Agreement; and WHEREAS, the Consultant desires to contract with the City for performance of the aforestated professional services relative to the Project, as hereinafter set forth; and NOW THEREFORE, City and Consultant, in consideration of the mutual covenants and agreement herein contained, agree as follows: ARTICLE 1. DEFINITIONS 1.1 CITY(OR OWNER): The "City" shall mean the City of Miami Beach, a Florida municipal corporation having its principal offices at 1700 Convention Center Drive, Miami Beach, Florida, 33139. 1.2 CITY COMMISSION: "City Commission" shall mean the governing and legislative body of the City. 1.3 CITY MANAGER: The "City Manager" shall mean the chief administrative officer of the City. The City Manager shall be construed to include any duly authorized representatives designated in writing (including the Project Coordinator) with respect to any specific matter(s) concerning the Services and/or this Agreement(exclusive of those authorizations reserved to the City Commission or regulatory or administrative bodies having jurisdiction over any matter(s) related to the Project, the Services, and/or this Agreement). 1.4 PROPOSAL DOCUMENTS: "Proposal Documents" shall mean Request for XXXXX)UUUU(XXX No. XXX)UXXX)XX, entitled "XXX)U(XXXXXX)(X XXXXXXXXXXXXXXXX" issued by the City in contemplation of this Agreement, together with all amendments thereto (if any), and the Consultant's proposal in response thereto (Proposal), which is incorporated by reference to this Agreement and made a part hereof; provided, however, that in the event of an express conflict between the Proposal Documents and this Agreement, the Agreement shall prevail. 1.5 CONSULTANT: The named entity on page 1 of this Agreement, the "Consultant" shall mean the architect/engineer who has entered into a contract with the City to provide the Services described under this Agreement. When the term "Consultant" is used in this Agreement it shall also be deemed to include any officers, employees, sub-consultants, agents, and any other person or entity acting under the supervision, direction, or control of Consultant. Any sub- consultants retained by Consultant for the Project shall be subject to the prior written approval of the City Manager. Consultant shall provide the Project Coordinator with copies of the contract between Consultant and any sub-consultant's. Any such contracts shall contain provisions that preserve and protect the rights of the City under this Agreement. Nothing contained in this Agreement shall create any contractual relationship between the City and sub-consultants. Any approval of a sub-consultant by the City shall not, in any way, shift the responsibility for the quality and acceptability by the City of the services performed by the sub-consultant, from the Consultant to City. Payment of sub-consultants shall be the responsibility of the Consultant, and shall not be cause for any increase in compensation to the Consultant for payment of the Basic Services. The quality of services and acceptability to the City of the services performed by such sub-consultants shall be the sole responsibility of Consultant. The following sub-consultants are hereby approved by the City Manager for the Project: XXXXXXXXXX ; XXXX)WCXXX 1.6 PROJECT COORDINATOR:The "Project Coordinator" shall mean the individual designated in writing by the City Manager who shall be the City's authorized representative to coordinate, direct, and review (on behalf of the City) all matters related to the Project during the design and construction of the Project (unless expressly provided otherwise in this Agreement or the Contract Documents). 1.7 [Intentionally Omitted] 1.8 BASIC SERVICES: "Basic Services" shall include those services which Consultant shall perform in accordance with the terms of the Agreement (and as required to complete the Project), as further described in Article 2 and Schedule "A" hereto. In addition any Services not specifically addressed as Additional Services (as defined herein) shall be considered Basic Services. 1.9 PROJECT: The "Project" shall mean that certain City capital project that has been approved by the City Commission and is described in Schedule "A" hereto. 1.9.1 Project Cost:The "Project Cost", shall mean the estimated total cost of the Project, as prepared and established by the City, including the estimated Construction Cost and Soft Costs. The Project Cost may, from time to time, be revised or adjusted by the City, in its sole discretion, to accommodate approved modifications or changes to the Project or scope of work. 1.9.2 Project Scope: The "Project Scope" shall mean the description of the Project in Schedule"A"hereto. 1.10 CONSTRUCTION COST: The "Construction Cost" shall mean the sum which is the actual total cost to the City of the Work(as established in the Contract Documents, as they may be amended from time to time), including a contingency allowance for unforeseen conditions, not to exceed ten percent(10%) of the construction cost for new construction, or twenty percent(20%) of the construction cost for rehabilitation of historic buildings. For Work not constructed, the Construction Cost shall be the same as the lowest bona fide bid or competitive bid received and accepted from a responsive and responsible bidder or proposer for such Work. 1.10.1 Construction Cost Budget: The "Construction Cost Budget" shall mean the amount budgeted by the City for the Construction Cost, as set forth in Schedule "A"hereto. 1.10.2 Statement Of Probable Construction Cost: The "Statement of Probable Construction Cost" shall mean the latest approved written estimate of Construction Cost submitted by Consultant to the City, in a format approved by the Project Coordinator. For Work which bids or proposals have not been let, the Statement of Probable Construction Cost shall be the same as the Construction Cost. 1.11 FORCE MAJEURE: "Force Majeure" shall mean any delay occasioned by superior or irresistible force occasioned by violence in nature without the interference of human agency such as hurricanes, tornadoes, floods, loss caused by fire and other similar unavoidable casualties; or by changes in Federal, State or local laws, ordinances, codes or regulations enacted after the date of this Agreement ; or other causes beyond the parties' control which have, or may be reasonably expected to have, a material adverse effect on the Project, or on the rights and obligations of the parties under this Agreement and which, by the exercise of due diligence, such parties shall not have been able to avoid; provided, however, that inclement weather (except as noted above), the acts or omissions of sub-consultants/sub-contractors, market conditions, labor conditions, construction industry price trends, and similar matters which normally impact on the construction process SHALL NOT be considered a Force Majeure. If the Consultant is delayed in performing any obligation under this Agreement due to a force majeure, the Consultant shall request a time extension from the Project Coordinator within five (5) business days of said force majeure. Any time extension shall be subject to mutual agreement and shall not be cause for any claim by the Consultant for extra compensation, unless additional services are required, and approved pursuant to Article 5 hereof. 1.12 CONTRACTOR: "Contractor" shall mean the individual or individuals, firm, company, corporation,joint venture, or other entity contracting with City for performance of the Work covered in the Contract Documents. 1.13 CONTRACT DOCUMENTS: "Contract Documents" shall mean this Agreement (together with all exhibits, addenda, and written amendments issued thereto), and the documents prepared by Consultant in accordance with the requirements of the Scope of Services in Schedule "A" hereto (that form the basis for which the City can receive bids for the Work included in the documents). The Contract Documents shall also include, without limitation (together with all exhibits, addenda, and written amendments issued thereto), the invitation to bid (ITB), instructions to bidders, bid form, bid bond, the Contract for Construction, surety payment and performance bonds, Conditions of the Contract for Construction [General, Supplementary, and other Conditions], Divisions 0-17, Construction Documents, an approved Change Order(s), approved Construction Change Directive(s), and/or approved written order(s)for a minor change in the Work. 1.14 CONTRACT FOR CONSTRUCTION: "Contract for Construction" shall mean the legally binding agreement between City and with Contractor for performance of the Work covered in the Contract Documents. 1.15 CONSTRUCTION DOCUMENTS: "Construction Documents" shall mean the final plans, technical specifications, drawings, documents, and diagrams prepared by the Consultant pursuant to this Agreement, which show the locations, characters, dimensions and details of the Work to be done, and which are part of the Contract Documents. 1.16 CONTRACT AMENDMENT: "Contract Amendment" shall mean a written modification to the Agreement approved by the City (as specified below) and executed between City and Consultant, covering changes, additions, or reductions in the terms of this Agreement including, without limitation, authorizing a change in the Project, or the method and manner of performance thereof, or an adjustment in the fee and/or completion dates. Contract Amendments shall be approved by the City Commission if they exceed twenty-five thousand dollars ($25,000.00) or the City Manager if they are twenty-five thousand dollars ($25,000.00) or less (or other such amount as may be specified by the City of Miami Beach Procurement Ordinance, as amended). Even for Contract Amendments for less than twenty-five thousand ($25,000.00), the City Manager reserves the right to seek and obtain concurrence of the City Commission for approval of any such Contract Amendment. 1.17 ADDITIONAL SERVICES: "Additional Services" shall mean those services, in addition to the Basic Services in this Agreement, which the Consultant shall perform, at the City's option, and which have been duly authorized, in writing, by the City Manager or his authorized designee, prior to commencement of same. 1.18 WORK: "Work" shall mean all labor, materials, tools, equipment, services, methods, procedures, etc. necessary or convenient to performance by Contractor of all duties and obligations proposed by the Contract Documents. 1.19 SERVICES: "Services" shall mean all services, work, and actions by the Consultant performed pursuant to or undertaken under this Agreement. 1.20 SOFT COSTS: "Soft Costs" shall mean costs related to the Project other than Construction Cost including, without limitation, Consultant's Basic Services, Additional Services, surveys, testing, general consultant, financing, and permitting fees, etc. 1.21 BASE BID: "Base Bid" shall mean the elements contained in the Construction Documents recommended by the Consultant (and approved by the City) as being within the Construction Cost Budget. "Base Bid" shall not include Additive Alternates or Deductive Alternates. 1.22 SCOPE OF SERVICES: "Scope of Services" shall include the Project Scope, Basic Services, and any Additional Services (as approved by the City), all as described in Schedule"A" hereto. 1.23 SCHEDULES: "Schedules" shall mean the various schedules attached to this Agreement and referred to as follows: Schedule A— Scope of Services. Schedule B— Consultant Compensation. Schedule C— Consultant Hourly Billing Rate Schedule. Schedule D— Construction Cost Budget. Schedule E— Project Schedule. Schedule F— General Conditions of the Contract for Construction Schedule G— Insurance Requirements and Sworn Affidavits Schedule H— Best Value Amendment ARTICLE 2. BASIC SERVICES 2.1 The Consultant shall provide Basic Services for the Project, as required by the Contract Documents and as set forth in Schedule "A" hereto. 2.2 The Services will be commenced upon issuance of the first Notice to Proceed which shall be issued by the Project Coordinator and counter-signed by Consultant. Subsequent Notices to Proceed shall also be issued by the Project Coordinator. A separate Notice to Proceed shall be required prior to commencement of each Task (as same are set forth in Schedule "A" hereto). 2.3 As it relates to the Services and the Project, Consultant warrants and represents to City that it is knowledgeable of Federal, State, and local laws codes, rules and regulations applicable in the jurisdiction(s) in which the Project is located, including, without limitation, applicable Florida Statutes, and State of Florida codes, rules and regulations, and local (City of Miami Beach and Miami-Dade County) ordinances, codes, and rules and regulations (collectively, "Applicable Laws"). As they relate to the Services and to the Project, the Consultant agrees to comply with all such Applicable Laws, whether now in effect or as may be amended or adopted from time to time, and shall further take into account all known pending changes to the foregoing of which it should reasonably be aware. Recognizing that the construction of other projects within the City may affect scheduling of the construction for the Project, the Consultant shall diligently coordinate performance of the Services with the City (through the Project Coordinator) in order to provide for the safe, expeditious, economical and efficient completion of the Project, without negatively impacting concurrent work by others. The Consultant shall coordinate the Services with all of its sub-consultants, as well as other consultants, including, without limitation, City provided consultants(if any). 2.4 The Consultant warrants and represents to City that all of the Services required under this Agreement shall be performed in accordance with the standard of care normally exercised in the design of comparable projects in South Florida. Consultant warrants and represents to the City that it is experienced, fully qualified, and properly licensed (pursuant to Applicable Laws) to perform the Services. Consultant warrants and represents to City that it is responsible for the technical accuracy of the Services (including, without limitation, the Design Documents contemplated in Schedule"A"hereto). 2.5 The Consultant's Basic Services shall consist of five (5) Tasks (inclusive of planning, design, bidding/award, construction administration, and Additional Services [as may be approved]), all as further described in Schedule "A" hereto; and shall also include any and all of Consultant's responsibilities and obligations with respect to the Project, as set forth in the General Conditions of the Contract for Construction (attached as Schedule"F" hereto). 2.5.1 Planning Services: Consultant shall provide planning services for the Project, as required by the Contract Documents and as set forth in Task 1 of Schedule "A" hereto (entitled "Planning Services"). 2.5.2 Design Services: Consultant shall prepare Design Documents for the Project, as required by the Contract Documents and as set forth in Task 2 of Schedule "A" hereto (entitled "Design Services") 2.5.3 Bidding And Award Services: Consultant shall provide bidding and award services for the Project, as required by the Contract Documents and as set forth in Task 3 of Schedule "A" hereto (entitled "Bidding and Award . Services"). 2.5.4 Construction Administration Services: Consultant shall provide construction administration services for the Project, as required by the Contract Documents and as set forth in Task 4 of Schedule "A" hereto (entitled "Construction Administration Services"). 2.5.5 Additional Services: If required (and so approved) by the City, Consultant shall provide Additional Services, as set forth in Task 5 of Schedule "A" hereto. 2.6 RESPONSIBILITY FOR CLAIMS AND LIABILITIES: Written decisions and/or approvals issued by the City shall not constitute nor be deemed a release of the responsibility and liability of the Consultant(or of any of its officers, employees, sub-consultants, agents, and/or servants), for the accuracy and competency of its/their designs, working drawings, plans, technical specifications, or other technical documents, nor shall such approval and/or decisions be deemed to be an assumption of such responsibility by the City for a defect, error or omission in designs, working drawings, plans, technical specifications, or other technical documents; provided, however, that the Consultant shall be entitled to reasonably rely upon the accuracy and validity of written decisions and approvals furnished by the City pursuant to this Agreement. 2.7 TIME: It is understood that time is of the essence in the completion of the Project and, in this respect, the parties agree as follows: 2.7.1 Term: The term of this Agreement shall commence upon execution by the parties (subject to approval of the Agreement by the Mayor and City Commission) (the Effective Date), and shall be in effect until all Services are completed or until the work and/or services under the Notices to Proceed in force at the end of the stated period of time have been completed and the Services accepted, whichever may be later. 2.7.2 The Consultant shall perform the Services as expeditiously as is consistent with the standard of professional skill and care required by this Agreement, and the orderly progress of the Work. 2.7.3 The Services shall be performed in a manner that shall conform with the approved Project Schedule, attached to as Schedule "E" hereto. The Consultant may submit requests for an adjustment to the Project Schedule, if made necessary because of undue delays resulting from untimely review taken by the City (or other governmental authorities having jurisdiction over the Project) to approve the Consultant's submissions, or any other portion of the Services requiring approval by the City (or other governmental authorities having jurisdiction over the Project). Consultant shall immediately provide the Project Coordinator with written notice stating the reason for the particular delay; the requested adjustment (i.e. extension) to the Project Schedule; and a revised anticipated schedule of completion. Upon receipt and review of Consultant's request (and such other documentation as the Project Coordinator may require), the Project Coordinator may grant a reasonable extension of time for completion of the particular work involved, and authorize that the appropriate adjustment be made to the Project Schedule. The Project Coordinator's approval(if granted)shall be in writing. 2.7.4 Nothing in this Section 2.7 shall prevent the City from exercising its rights to terminate the Agreement, as provided elsewhere herein. 2.8 Consultant shall use its best efforts to maintain a constructive, professional, cooperative working relationship with the Project Coordinator, Contractor, and any and all other individuals and/or firms that have been contracted, or otherwise retained, to perform work on the Project. 2.9 The Consultant shall perform its duties under this Agreement in a competent, timely and professional manner, and shall be responsible to the City for any failure in its performance, except to the extent that acts or omissions by the City make such performance impossible. The Consultant is responsible for the professional quality, technical accuracy, completeness, performance and coordination of all work required under the Agreement (including the work performed by sub-consultants), within the specified time period and specified cost. The Consultant shall perform the work utilizing the skill, knowledge, and judgment ordinarily possessed and used by a proficient consulting with respect to the disciplines required for the performance of the work in the State of Florida. The Consultant is responsible for, and shall represent to City that the work conforms to City's requirements, as set forth in the Agreement. The Consultant shall be and remain liable to the City for all damages to the City caused by the Consultant's negligent acts or errors or omissions in the performance of the work. In addition to all other rights and remedies, which the City may have, the Consultant shall, at its expense, re- perform all or any portion of the Services to correct any deficiencies which result from the Consultant's failure to perform in accordance with the above standards. The Consultant shall also be liable for the replacement or repair of any defective materials and equipment and re- performance of any non-conforming construction services resulting from such deficient Consultant services for a period from the Effective Date of this Agreement, until twelve (12) months following final acceptance of the Work, and for the period of design liability required by applicable law. The Project Coordinator shall notify the Consultant, in writing, of any deficiencies and shall approve the method and timing of the corrections. Neither the City's inspection, review, approval or acceptance of, nor payment for, any of the work required under the Agreement shall be construed to relieve the Consultant (or any sub-consultant) of its obligations and responsibilities under the Agreement, nor constitute a waiver of any of the City's rights under the Agreement, or of any cause of action arising out of the performance of the Agreement. The Consultant and its sub- consultants shall be and remain liable to the City in accordance with Applicable Laws for all damages to City caused by any failure of the Consultant or its sub-consultants to comply with the terms and conditions of the Agreement or by the Consultant or any sub-consultants' misconduct, unlawful acts, negligent acts, errors or omissions in the performance of the Agreement. With respect to the performance of work by sub-consultants, the Consultant shall, in approving and accepting such work, ensure the professional quality, completeness, and coordination of the sub- consultant's work. 2.9.1 The Consultant shall be responsible for deficient, defective services and any resulting deficient, defective construction services re-performed within twelve (12) months following final acceptance and shall be subject to further re-performance, repair and replacement for twelve (12) months from the date of initial re-performance, not to exceed twenty-four months (24)from final acceptance. 2.9.2 Consultant Performance Evaluation: The Consultant is advised that a performance evaluation of the work rendered throughout this Agreement will be completed by the City and kept in the City's files for evaluation of future solicitations. 2.10 The City shall have the right, at any time, in its sole and absolute discretion, to submit for review to other consultants (engaged by the City at its expense) any or all parts of the Services and the Consultant shall fully cooperate in such review(s). Whenever others are required to verify, review, or consider any work performed by Consultant (including, without limitation, contractors, other design professionals, and/or other consultants retained by the City), the intent of such requirement is to enable the Consultant to receive input from others' professional expertise to identify any discrepancies, errors or omissions that are inconsistent with industry standards for design or construction of comparable projects; or which are inconsistent with Applicable Laws; or which are inconsistent with standards, decisions or approvals provided by the City under this Agreement. Consultant will use reasonable care and skill, in accordance and consistent with customary professional standards, in responding to items identified by other reviewers in accordance with this subsection. Consultant shall receive comments from reviewers, in writing, including, without limitation (and where applicable), via a set of marked-up drawings and specifications. Consultant shall address comments forwarded to it in a timely manner. The term "timely" shall be defined to mean as soon as possible under the circumstances, taking into account the timelines of the Project Schedule. 2.11 [Intentionally Omitted] 2.12 Consultant agrees that when any portion of the Services relates to a professional service which, under Florida Statutes, requires a license, certificate of authorization, or other form of legal entitlement to practice and/or perform such Service(s), it shall employ and/or retain only qualified duly licensed certified personnel to provide same. 2.13 Consultant agrees to designate, in writing, within five (5) calendar days after issuance of the first Notice to Proceed, a qualified licensed professional to serve as its project manager (hereinafter referred to as the "Project Manager"). The Project Manager shall be authorized and responsible to act on behalf of Consultant with respect to directing, coordinating and administrating all aspects of the Services. Consultant's Project Manager (as well as any replacement) shall be subject to the prior written approval of the City Manager or his designee (who in this case shall be the Project Coordinator). Replacement (including reassignment) of an approved Project Manager shall not be made without the prior written approval of the City Manager or his designee(i.e. the Project Coordinator). 2.13.1 Consultant agrees, within fourteen (14) calendar days of receipt of written notice from the City Manager or his designee (which notice shall state the cause therefore), to promptly remove and replace a Project Manager, or any other personnel employed or otherwise retained by Consultant for the Project ( including, without limitation, any sub- consultants). 2.14 Consultant agrees not to divulge, furnish or make available to any third party(ies), any non-public information concerning the Services or the Project, without the prior written consent of the City Manager or his designee (who shall be the Project Coordinator), unless such disclosure is incident to the proper performance of the Services; or the disclosure is required pursuant to Florida Public Records laws; or, in the course of judicial proceedings, where such information has been properly subpoenaed. Consultant shall also require its employees and sub-consultants to comply with this subsection. 2.15 The City and Consultant acknowledge that the Services do not delineate every detail and minor work task required to be performed by Consultant to complete the Project. If, during the course of performing of the Services, Consultant determines that work should be performed to complete the Project which is, in the Consultant's reasonable opinion, outside the level of effort originally anticipated in the Scope of Services, Consultant shall promptly notify the Project Coordinator, in writing, and shall obtain the Project Coordinator's written consent before proceeding with such work. If Consultant proceeds with any such additional work without obtaining the prior written consent of the Project Coordinator, said work shall be deemed to be within the original Scope of Services, and deemed included as a Basic Service (whether or not specifically addressed in the Scope of Services). Mere notice by Consultant to the Project Coordinator shall not constitute authorization or approval by the City to perform such work. Performance of any such work by Consultant without the prior written consent of the Project Coordinator shall be undertaken at Consultant's sole risk and liability. 2.16 Consultant shall establish, maintain, and categorize any and all Project documents and records pertinent to the Services and shall provide the City, upon request, with copies of any and all such documents and/or records. In addition, Consultant shall provide electronic document files to the City upon completion of the Project. 2.17 The City's participation in the design and construction of the Project shall in no way be deemed to relieve the Consultant of its professional duties and responsibilities under the Contract Documents or under Applicable Laws. 2.18 GREEN BUILDING STANDARDS: The Consultant shall comply with the requirements of Section 255.2575, Florida Statutes, and Chapter 100 of the City Code, as both may be amended from time to time, addressing applicable Leadership in Energy and Environmental Design (LEED) compliance requirements. 2.19 SUB-CONSULTANTS: All services provided by sub-consultants shall be consistent with those commitments made by the Consultant in its Proposal and during the competitive solicitation selection process and interview. Such services shall be undertaken and performed pursuant to appropriate written agreements between the Consultant and the sub- consultants, which shall contain provisions that preserve and protect the rights of the City under this Agreement. Nothing contained in this Agreement shall create any contractual relationship between the City and the sub-consultants. The Consultant shall not retain, add, or replace any sub-consultant without the prior written approval of the City Manager, in response to a written request from the Consultant stating the reasons for any proposed substitution. Any approval of a sub-consultant by the City Manager shall not in any way shift the responsibility for the quality and acceptability by the City of the services performed by the sub-consultant from the Consultant to the City. The quality of services and acceptability to the City of the services performed by sub-consultants shall be the sole responsibility of Consultant. The Consultant shall cause the names of sub-consultants responsible for significant portions of the Services to be inserted on the plans and specifications. ARTICLE 3. THE CITY'S RESPONSIBILITIES 3.1 The City Manager shall designate a Project Coordinator, in writing, who shall be the City's authorized representative to coordinate, direct, and review all matters related to this Agreement and the Project during the design and construction of same (except unless otherwise expressly provided in this Agreement or the Contract Documents). The Project Coordinator shall be authorized (without limitation) to transmit instructions, receive information, and interpret and define City policies and decisions with respect to the Services and the Project. However, the Project Coordinator is not authorized to issue any verbal or written orders or instructions to Consultant that would have the affect (or be interpreted as having the effect) of modifying or changing, (in any way) the following: a) the Scope of Services; b) the time within which Consultant is obligated to commence and complete the Services; or c) the amount of compensation the City is obligated or committed to pay Consultant. 3.2 The City shall make available to Consultant all information that the City has in its possession pertinent to the Project. Consultant hereby agrees and acknowledges that, in making any such information available to Consultant, the City makes no express or implied certification, warranty, and/or representation as to the accuracy or completeness of such information. The Consultant understands, and hereby agrees and acknowledges, that it is obligated to verify to the extent it deems necessary all information furnished by the City, and that it is solely responsible for the accuracy and applicability of all such information used by Consultant. Such verification shall include, without limitation, visual examination of existing conditions in all locations encompassed by the Project, where such examination can be made without using destructive measures (i.e. excavation or demolition). Survey information shall be spot checked to the extent that Consultant has satisfied itself as to the reliability of the information. 3.3 [Intentionally Omitted] 3.4 At any time, in his/her sole discretion, the City Manager may furnish accounting, and insurance counseling services for the Project (including, without limitation, auditing services to verify the Consultant's applications for payment, or to ascertain that Consultant has properly remitted payment due to its sub-consultants or vendors). 3.5 If the City observes or otherwise becomes aware of any fault or defect in the Project, or non-conformance with the Contract Documents, the City, through the Project Coordinator, shall give prompt written notice thereof to the Consultant. 3.6 The City, acting in its proprietary capacity as Owner and not in its regulatory capacity, shall render any administrative approvals and decisions required under this Agreement, in writing, as reasonably expeditious for the orderly progress of the Services and of the Work. No City administrative (proprietary) approvals and/or decisions required under this Agreement shall be unreasonably conditioned, withheld, or delayed; provided, however, that the City shall at all times have the right to approve or reject any such requests for any reasonable basis. 3.7 The City Commission shall be the final authority to do or to approve the following actions or conduct, by passage of an enabling resolution or amendment to this Agreement: 3.7.1 Except where otherwise expressly noted in the Agreement or the Contract Documents, the City Commission shall be the body to consider, comment upon, or approve any amendments or modifications to this Agreement. 3.7.2 The City Commission shall be the body to consider, comment upon, or approve any assignment, sale, transfer or subletting of this Agreement. Assignment and transfer shall be defined to also include sale of the majority of the stock of a corporate consultant. 3.7.3 Upon written request from Consultant, the City Commission shall hear appeals from administrative decisions of the City Manager or the Project Coordinator. In such cases, the Commission's decision shall be final and binding upon all parties. 3.7.4 The City Commission shall approve or consider all Contract Amendments that exceed the sum of twenty five thousand dollars ($25,000.00) (or other such amount as may be specified by the City of Miami Beach Procurement Ordinance, as amended). 3.8 Except where otherwise expressly noted in this Agreement, the City Manager shall serve as the City's primary representative to whom administrative (proprietary) requests for decisions and approvals required hereunder by the City shall be made. Except where otherwise expressly noted in this Agreement or the Contract Documents, the City Manager shall issue decisions and authorizations which may include, without limitation, proprietary review, approval, or comment upon the schedules, plans, reports, estimates, contracts, and other documents submitted to the City by Consultant. 3.8.1 The City Manager shall have prior review and approval of the Project Manager (and any replacements)and of any sub-consultants(and any replacements). 3.8.2 The City Manager shall decide, and render administrative (proprietary) decisions on matters arising pursuant to this Agreement which are not otherwise expressly provided for in this Agreement. In his/her discretion, the City Manager may also consult with the City Commission on such matters. 3.8.3 At the request of Consultant, the City Manager shall be authorized, but not required, to reallocate monies already budgeted toward payment of the Consultant; provided, however, that the Consultant's compensation (or other budgets established by this Agreement) may not be increased without the prior approval of the City Commission, which approval (if granted at all) shall be in its sole and reasonable discretion. 3.8.4 [Intentionally Omitted] 3.8.5 The City Manager may approve Contract Amendments which do not exceed the sum of twenty five thousand dollars ($25,000.00) (or other such amount as may be specified by the City of Miami Beach Purchasing Ordinance, as amended); provided that no such amendments increase any of the budgets established by this Agreement. 3.8.6 The City Manager may, in his/her sole discretion, form a committee or committees, or inquire of, or consult with, persons for the purpose of receiving advice and recommendations relating to the exercise of the City's powers, duties, and responsibilities under this Agreement or the Contract Documents. 3.8.7 The City Manager shall be the City Commission's authorized representative with regard to acting on behalf of the City in the event of issuing any default notice(s) under this Agreement, and, should such default remain uncured, in terminating the Agreement (pursuant to and in accordance with Article 10 hereof). ARTICLE 4. RESPONSIBILITY FOR CONSTRUCTION COST 4.1 The City has established the Construction Cost Budget for the Project, as set forth in Schedule"D", attached hereto. 4.2 Consultant shall certify and warrant to the City all estimates of Construction Cost prepared by Consultant. 4.3 Consultant shall warrant and represent to the City that its review and evaluation of the Construction Cost Budget, Statement of Probable Construction Cost, and any other cost estimates prepared (or otherwise provided) by Consultant for the Project, represent Consultant's best judgment as an experienced design professional familiar with the construction industry; provided, however, that Consultant cannot (and does not) guarantee that bids or negotiated prices will not vary from any estimates of Construction Cost or other cost evaluation(s) prepared (or otherwise provided) by Consultant. 4.4 The Construction Cost Budget (as established in Schedule "D" hereto) shall not be exceeded without fully justifiable, extraordinary, and unforeseen circumstances (such as Force Majeure)which are beyond the control of the parties. Any expenditure above this amount shall be subject to prior City Commission approval which, if granted at all, shall be at the sole and reasonable discretion of the City Commission. The City Commission shall have no obligation to approve an increase in the Construction Cost Budget and, if such budget is exceeded, the City Commission may, at its sole and reasonable discretion, terminate this Agreement (and the remaining Services)without any further liability to the City. 4.5 If the lowest and best base bid exceeds the Construction Cost Budget by more than five percent (5%), the City Commission may, at its sole option and discretion, elect any of the following options: (1) approve an increase to the Construction Cost Budget; (2) reject all bids, and (at its option) authorize rebidding of the Project; (3) abandon the Project and terminate the remaining Services without any further liability to the City; (4) select as many Deductive Alternatives as may be necessary to bring the lowest and best bid within the Construction Cost Budget; or (5) work with the Consultant to reduce the Project Scope, construction schedule, sequence of Work, or such other action, as deemed necessary, to reduce the Construction Cost Budget. In the event the City elects to reduce the Project Scope, the Consultant shall provide any required revisions to the Contract Documents (including, without limitation, the Construction Documents), and provide re-bidding services, as many times as reasonably requested by the City, at no additional cost to the City, in order to bring any resulting, responsive and responsible bids within five percent(5%)of the Construction Cost Budget. ARTICLE 5. ADDITIONAL SERVICES 5.1 Additional Services shall only be performed by Consultant following receipt of written authorization by the Project Coordinator (which authorization must be obtained prior to commencement of any such additional work by Consultant). The written authorization shall contain a description of the Additional Services required; an hourly fee (in accordance with the rates in Schedule "C" hereto), with a "Not to Exceed" amount; Reimbursable Expenses (if any) with a "Not to Exceed" amount; the amended Construction Cost Budget (if applicable); the time required to complete the Additional Services; and an amended Project Schedule (if applicable). "Not to Exceed" shall mean the maximum cumulative hourly fees allowable (or, in the case of Reimbursable Expenses, the maximum cumulative expenses allowable), which the Consultant shall not exceed without further written authorization of the Project Coordinator. The "Not to Exceed" amount is not a guaranteed maximum cost for the additional work requested (or, in the case of Reimbursables, for the expenses), and all costs applicable to same shall be verifiable ' through time sheets(and, for Reimbursables, expense reviews). 5.2 Additional Services may include, but not be limited to, the following: 5.2.1 Providing additional work relative to the Project which arises from subsequent circumstances and causes which do not currently exist, or which are not contemplated by the parties at the time of execution of this Agreement (excluding circumstances and causes resulting from error, omission, inadvertence, or negligence of Consultant). 5.2.2 Serving as an expert witness in connection with any public hearing, arbitration proceeding, or legal proceeding, unless the subject matter at issue has arisen from the error omission, inadvertence, or negligence of Consultant. 5.2.3 [Intentionally Omitted] 5.2.4 Assistance in connection with bid protests, re-bidding, or re-negotiating contracts (except for Contract Document revisions and re-bidding services required under Section 4.5 hereof, which shall be provided at no additional cost to City). ARTICLE 6. REIMBURSABLE EXPENSES 6.1 Reimbursable Expenses are an allowance set aside by the City and shall include actual expenditures made by the Consultant in the interest of the Project. The Reimbursable Expenses allowance, as specified in Schedule "B" hereto, belongs to, and shall be controlled by, the City. Any money not directed to be used by City for Reimbursable Expenses shall remain with the City (i.e. unused portions will not be paid to Consultant). Notwithstanding the above, any Reimbursable Expenses in excess of $500 must be authorized, in advance, in writing, by the Project Coordinator. Invoices or vouchers for Reimbursable Expenses shall be submitted to the Project Coordinator (along with any supporting receipts and other back-up material requested by the Project Coordinator). Consultant shall certify as to each P 4 Y J ) fY such invoice and/or voucher that the amounts and items claimed as reimbursable are "true and correct and in accordance with the Agreement." 6.2 Reimbursable Expenses may include, but not be limited to, the following: 6.2.1 Cost of reproduction, courier, and postage and handling of drawings, plans, specifications, and other Project documents (excluding reproductions for the office use of the Consultant and its sub-consultants, and courier, postage and handling costs between the Consultant and its sub-consultants). 6.2.2 Costs for reproduction and preparation of graphics for community workshops. 6.2.3 Permit fees required by City of Miami Beach regulatory bodies having jurisdiction over the Project(i.e. City permit fees). ARTICLE 7. COMPENSATION FOR SERVICES 7.1 Consultant's "Not to Exceed"fee for provision of the Services shall be XX)000UUC, with a Reimbursable Expenses allowance of XX)UUUUUC. 7.2 Payments for Services shall be made within forty-five (45) calendar days of receipt and approval of an acceptable invoice by the Project Coordinator. Payments shall be made in proportion to the Services satisfactorily performed, so that the payments for Services never exceed the progress percentage noted in the Consultant's Progress Schedule (to be submitted with each invoice). No mark-up shall be allowed on subcontracted work. 7.3 Approved Additional Services shall be compensated in accordance with the hourly rates set forth in Schedule "C," attached hereto. Any request for payment of Additional Services shall be included with a Consultant payment request. No mark-up shall be allowed on Additional Services (whether sub-contracted or not). 7.4 Approved Reimbursable Expenses shall be paid in accordance with Article 6 hereto, up to the "Not to Exceed" Reimbursable allowance amount in Schedule "B" hereto. Any request for payment of Reimbursable Expenses shall also be included with Consultant's payment request. No mark-up shall be allowed on Reimbursable Expenses. 7.5 ESCALATION: During the Term of this Agreement, the City may, by written directive approved and executed by the City Manager, adjust the fees included in the Hourly Billing Rate Schedule in Schedule "C" hereto, to reflect the change in the Consumer Price Index (CPI) on a year to year basis. Such adjustment will be based on the cumulative change of the CPI for the Miami urban area, provided that in no event shall any the annual increase exceed three percent (3%). 7.6 No retainage shall be made from the Consultant's compensation on account of sums withheld by the City on payments to Contractor. 7.7 METHOD OF BILLING AND PAYMENT. Consultant shall invoice the Project Coordinator in a timely manner, but no more than once on a monthly basis. Invoices shall identify the nature and extent of the work performed; the total hours of work performed by employee category; and the respective hourly billing rate associated therewith. In the event sub-consultant work is used, the percentage of completion shall be identified. Invoices shall also itemize and summarize any Additional Services and/or Reimbursable Expenses. A copy of the written approval of the Project Coordinator for the requested Additional Service(s) or Reimbursable Expense(s)shall accompany the invoice. 7.7.1 If requested, Consultant shall provide back-up for past and current invoices that records hours for all work (by employee category), and cost itemizations for Reimbursable Expenses(by category). 7.7 .2 The City shall pay Consultant within forty-five (45) calendar days from receipt and approval of an acceptable invoice by the Project Coordinator. 7.7.3 Upon completion of the Services, Consultant's final payment shall require the prior written approval of the City Manager before disbursement of same. ARTICLE 8. CONSULTANT'S ACCOUNTING AND OTHER RECORDS 8.1 All books, records (whether financial or otherwise), correspondence, technical documents, and any other records or documents related to the Services and/or Project will be available for examination and audit by the City Manager, or his/her authorized representatives, at Consultant's office (at the address designated in Article 15 ["Notices"]), during customary business hours. All such records shall be kept at least for a period of three (3) years after Consultant's completion of the Services. Incomplete or incorrect entries in such records and accounts relating personnel services and expenses may be grounds for City's disallowance of any fees or expenses based upon such entries. Consultant shall also bind its sub-consultants to the requirements of this Article and ensure compliance therewith ARTICLE 9. OWNERSHIP OF PROJECT DOCUMENTS 9.1 All notes, correspondence, documents, plans and specifications, designs, drawings, renderings, calculations, specifications, models, photographs, reports, surveys, investigations, and any other documents (whether completed or partially completed) and copyrights thereto for Services performed or produced in the performance of this Agreement, or related to the Project, whether in paper or other hard copy medium or in electronic medium, except with respect to copyrighted standard details and designs owned by the Consultant or owned by a third party and licensed to the Consultant for use and reproduction, shall become the property of the City. Consultant shall deliver all such documents to the Project Coordinator within thirty (30) days of completion of the Services (or within thirty (30) days of expiration or earlier termination of this Agreement as the case may be). However, the City may grant an exclusive license of the copyright to the Consultant for reusing and reproducing copyrighted materials or portions thereof as authorized by the City Manager in advance and in writing, In addition, the Consultant shall not disclose, release, or make available any document to any third party without prior written approval from the City Manager. The Consultant shall warrant to the City that it has been granted a license to use and reproduce any standard details and designs owned by a third party and used or reproduced by the Consultant in the performance of this Agreement. Nothing contained herein shall be deemed to exclude any document from Chapter 119, Florida Statutes. g) g) 9.2 The Consultant is permitted to reproduce copyrighted material described above subject to prior written approval of the City Manager. 9) g) 9.3 At the City's option, the Consultant may be authorized, as an Additional Service, to adapt copyrighted material for additional or other work for the City; however, payment to the Consultant for such adaptations will be limited to an amount not greater than 50% of the original fee earned to adapt the original copyrighted material to a new site. g) g) 9.4 The City shall have the right to modify the Project or any components thereof without permission from the Consultant or without any additional compensation to the Consultant. The Consultant shall be released from any liability resulting from such modification. g) 9.5 The Consultant shall bind all sub-consultants to the Agreement requirements for re-use of plans and specifications. ARTICLE 10. TERMINATION OF AGREEMENT 10.1 TERMINATION FOR LACK OF FUNDS: The City is a governmental entity and is subject to the appropriation of funds by its legislative body in an amount sufficient to allow continuation of its performance in accordance with the terms and conditions of this Agreement. In the event there is a lack of adequate funding either for the Services or the Project (or both), the City may terminate this Agreement without further liability to the City. 10.2 TERMINATION FOR CAUSE: The City, through the City Manager, may terminate this Agreement for cause, upon written notice to Consultant, in the event that the Consultant (1) violates any provision of this Agreement or performs same in bad faith; (2) unreasonably delays the performance of the Services or any portion thereof; or (3) does not perform the Services or any portion thereof in a timely and satisfactory manner. In the case of termination for cause by the City, the Consultant shall first be granted a thirty (30) day cure period (commencing upon receipt of the initial written notice of default from the City). 10.2.1 In the event this Agreement is terminated for cause by the City, the City, at its sole option and discretion, may take over the remaining Services and complete them by contracting with another consultant(s), or otherwise. The Consultant shall be liable to the City for any additional cost(s) incurred by the City due to such termination. "Additional Cost" is defined as the difference between the actual cost of completion of the Services, and the cost of completion of such Services had the Agreement not been terminated. 10.2.2 In the event of termination for cause by the City, the City shall only be obligated to pay Consultant for those Services satisfactorily performed and accepted prior to the date of termination (as such date is set forth in, or can be calculated from, the City's initial written default notice). Upon payment of any amount which may be due to Consultant pursuant to this subsection 10.2.2, the City shall have no further liability to Consultant. 10.2.3 As a condition precedent to release of any payment which may be due to Consultant under subsection 10.2.2, the Consultant shall promptly assemble and deliver to the Project Coordinator any and all Project documents prepared (or caused to be prepared) by Consultant(including, without limitation, those referenced in subsection 9.1 hereof). The City shall not be responsible for any cost incurred by Consultant for assembly, copy, and/or delivery of Project documents pursuant to this subsection. 10.3 TERMINATION FOR CONVENIENCE: In addition to the City's right to terminate for cause, the City through the City Manager, may also terminate this Agreement, upon fourteen (14) days prior written notice to Consultant, for convenience, without cause, and without penalty, when (in its sole discretion) it deems such termination to be in the best interest of the City. In the event the City terminates the Agreement for convenience, Consultant shall be compensated for all Services satisfactorily performed and accepted up to the termination date (as set forth in the City's written notice), and for Consultant's costs in assembly and delivery to the Project Coordinator of the Project documents (referenced in subsection 10.2.3 above). Upon payment of any amount which may be due to Consultant pursuant this subsection 10.3, the City shall have no further liability to Consultant. 10.4 TERMINATION BY CONSULTANT: The Consultant may only terminate this Agreement for cause, upon thirty (30) days prior written notice to the City, in the event that the City willfully violates any provisions of this Agreement or unreasonably delays payment of the Services or any portion thereof. In the event of a termination for cause by Consultant, the City shall pay Consultant for any Services satisfactorily performed and accepted up to the date of termination; provided, however, that the City shall first be granted a thirty (30) day cure period (commencing upon receipt of Consultant's initial written notice). 10.4.1 The Consultant shall have no right to terminate this Agreement for convenience. 10.5 IMPLEMENTATION OF TERMINATION: In the event of termination (whether for cause or for convenience), the Consultant shall immediately, upon receipt of the City's written notice of termination: (1) stop the performance of Services; (2) place no further orders or issue any other subcontracts, except for those which may have already been approved, in writing, by the Project Coordinator; (3) terminate all existing orders and subcontracts; and (4) promptly assemble all Project documents(for delivery to the Project Coordinator). ARTICLE 11. INSURANCE 11.1 At all times during the Term of this Agreement, Consultant shall maintain the following required insurance coverage in full force and effect. The Consultant shall not commence any work until satisfactory proof of all required insurance coverage has been furnished to the Project Coordinator: (a) Professional Liability Insurance, in the amount of one million dollars ($1,000,000.00), per occurrence, with a maximum deductible of$150,000 per occurrence, $450,000 aggregate. Consultant shall notify the Project Coordinator, in writing, within thirty (30) days of any claims filed or made against its Professional Liability Insurance policy. (b) Comprehensive General Liability Insurance, in the amount of one million dollars ($1,000,000.00), Single Limit Bodily Injury and Property Damage coverage, for each occurrence, which shall include products, completed operations, and contractual liability coverage. The City of Miami Beach, Florida must be named as an additional insured on this policy. (c) Worker's Compensation and Employer's Liability coverage within the statutory limits required under Florida law. 11.2 The Consultant must give the Project Coordinator at least thirty (30) days prior written notice of cancellation or of substantial modifications in any required insurance coverage. All certificates and endorsements shall contain this requirement. 11.3 The insurance must be furnished by an insurance company rated B+:VI or better, or its equivalent, according to Bests' Guide Rating Book, and by insurance companies duly authorized to do business in the State of Florida, and countersigned by the company's Florida resident agent. 11.4 Consultant shall provide the Project Coordinator with a certificate of insurance of all required insurance policies. The City reserves the right to require a certified copy of such policies, upon written request to Consultant. ARTICLE 12. INDEMNIFICATION AND HOLD HARMLESS 12.1 Pursuant to Section 725.08, Florida Statutes, the Consultant shall indemnify and hold harmless the City and its officers, employees, agents, and instrumentalities, from liabilities, damages, losses, and costs, including, but not limited to, reasonable attorneys' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Consultant and Y Y 9 other persons employed or utilized by the Consultant in the performance of this Agreement. The Consultant shall pay all claims and losses in connection therewith and shall investigate and defend all claims, suits, or actions of any kind or nature in the name of the City, where applicable, including appellate proceedings, and shall pay all costs, judgments, and attorney's fees which may issue thereon. Consultant expressly understands and agrees that any insurance protection required by this Agreement or otherwise provided by Consultant shall in no way limit its responsibility to indemnify, keep, and save harmless and defend the City or its officers, employees, agents, and instrumentalities as herein provided. 12.2 The Consultant agrees and recognizes that the City shall not be held liable or responsible for any claims which may result from any negligent, reckless, or intentionally wrongful actions, errors or omissions of the Consultant in which the City participated either through review or concurrence of the Consultant's actions. In reviewing, approving or rejecting any submissions by the Contractor, or other acts of the Consultant, the City in no way assumes or shares any responsibility or liability of the Consultant (including, without limitation its sub-consultants and/or any registered professionals (architects and/or engineers) under this Agreement). • ARTICLE 13. ERRORS AND OMISSIONS 13.1 ERRORS AND OMISSIONS: It is specifically agreed that any construction changes categorized by the City as caused by an error, an omission, or any combination thereof in the Contract Documents that were prepared by the Consultant will constitute an additional cost to the City that would not have been incurred without the error. The damages to the City for errors, omissions or any combinations thereof shall be calculated as the total cost of any damages or incremental costs to the City resulting out of the errors or omissions by the Consultant. Damages shall include delay damages caused by the error, omission, or any combination thereof. Should the Consultant disagree that all or part of such damages are the result of errors, omissions, or any combination thereof, the Consultant may appeal this determination, in writing, to the City's Capital Improvement Projects Director(the Director). The Director's decision on all claims, questions and disputes shall be final, conclusive and binding upon the parties hereto unless such determination is clearly arbitrary or unreasonable. In the event that the Consultant does not agree with the decision of the Director, the Consultant shall present any such objections, in writing, to the City Manager. The Director and the Consultant shall abide by the decision of the City Manager. This paragraph does not constitute a waiver of any party's right to proceed in a court of competent jurisdiction after the above administrative remedies have been exhausted. ARTICLE 14. LIMITATION OF LIABILITY The City desires to enter into this Agreement only if in so doing the City can place a limit on its liability for any cause of action for money damages due to an alleged breach by the City of this Agreement, so that its liability for any such breach never exceeds the "not to exceed" amount of the fee paid to Consultant under this Agreement, less any amount(s) actually paid to Consultant hereunder. Consultant hereby expresses its willingness to enter into this Agreement, with Consultant's recovery from the City for any damages for action for breach of contract to be limited to Consultant's"not to exceed"fee under this Agreement, less any amount(s) actually paid by the City to the Consultant hereunder. Accordingly, and notwithstanding any other term or condition of this Agreement, Consultant hereby agrees that the City shall not be liable to Consultant for money damages due to an alleged breach by the City of this Agreement, in an amount in excess of the "not to exceed amount" of Consultant's fees under this Agreement, which amount shall be reduced by any amount(s)actually paid by the City to Consultant hereunder. Nothing contained in this subsection, or elsewhere in this Agreement, is in any way intended to 9 � 9 � Y Y be a waiver of the limitation placed upon City's liability, as set forth in Section 768.28, Florida Statutes. ARTICLE 15. NOTICE All written notices given to City by Consultant shall be addressed to: City Manager's Office City of Miami Beach 1700 Convention Center Drive Miami Beach, Florida 33139 Attn: With a copy to: Capital Improvement Projects Office City of Miami Beach 1700 Convention Center Drive Miami Beach, Florida 33139 Attn: XXXXXXXXXXXXXX All written notices given to the Consultant from the City shall be addressed to: XXX XXXXXXXXXXXXXXX XXXX XX XXX)OCXX X XXXXXX)O<X)OO(X Attn: XXXXXXXXXXX All notices mailed to either party shall be deemed to be sufficiently transmitted if sent by certified mail, return receipt requested. ARTICLE 16. MISCELLANEOUS PROVISIONS 16.1 VENUE: This Agreement shall be governed by, and construed in accordance with, the laws of the State of Florida, both substantive and remedial, without regard to principles of conflict of laws. The exclusive venue for any litigation arising out of this Agreement shall be Miami-Dade County, Florida, if in state court, and the U.S. District Court, Southern District of Florida, in federal court. BY ENTERING INTO THIS AGREEMENT, CONSULTANT AND CITY EXPRESSLY WAIVE ANY RIGHTS EITHER PARTY MAY HAVE TO A TRIAL BY JURY OF ANY CIVIL LITIGATION RELATED TO, OR ARISING OUT OF, THIS AGREEMENT. 16.2 EQUAL OPPORTUNITY EMPLOYMENT GOALS: Consultant agrees that it will not discriminate against any employee or applicant for employment for work under this Agreement because of race, color, national origin, religion, sex, gender identity, sexual orientation, disability, marital or familial status, or age, and will take affirmative steps to ensure that applicants are employed and employees are treated during employment without regard to race, color, national origin, religion, sex, gender identity, sexual orientation, disability, marital or familial status, or age. 16.3 PUBLIC ENTITY CRIMES ACT: In accordance with the Public Entity Crimes Act(Section 287.133, Florida Statutes), a person or affiliate who is a consultant, who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to the City, may not submit a bid on a contract with the City for the construction or repair of a public building or public work, may not bid on leases of real property to the City, may not be awarded or perform work as a contractor, supplier, subcontractor, or subconsultant under a contract with the City, and may not transact business with the City in excess of the threshold amount provided in Section 287.017, Florida Statutes, for Category Two, for a period of 36 months from the date of being placed on the convicted vendor list. For violation o f th i s subsectio n by C i t shall I have the right to terminate the Agreement without any liability to City, and pursue debarment of Consultant 16.4 NO CONTINGENT FEE: Consultant warrants that it has not employed or retained any company or person, other than a bona fide employee working solely for Consultant, to solicit or secure this Agreement, and that it has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. For the breach or violation of this subsection, City shall have the right to terminate the Agreement, without any liability or, at its discretion, to deduct from the contract price (or otherwise recover) the full amount of such fee, commission, percentage, gift, or consideration. 16.5 LAWS AND REGULATIONS: 16.5.1 The Consultant shall, during the Term of this Agreement, be governed by Federal, State, Miami-Dade County, and City laws, ordinances, and codes which may have a bearing on the Services involved in the Project. 16.5.2 Project Documents. In accordance with Section 119.07 (3) (ee), Florida Statutes, entitled "Inspection, Examination, and Duplication of Records; Exemptions," all building plans, blueprints, schematic drawings, and diagrams, including draft, preliminary, and final formats, are exempt from the provisions of Section 119.07(1), Florida Statutes (inspection and copying of public records), and s. 24(a), Article I of the State Constitution. Information made exempt by this paragraph, with prior written approval from the City Manager, may be disclosed to another entity to perform its duties and responsibilities; to a licensed architect, engineer, or contractor who is performing work on or related to the Project; or upon a showing of good cause before a court of competent jurisdiction. The entities or persons receiving such information shall maintain the exempt status of the information. 16.5.2.1 In addition to the requirements in this subsection 16.5.2, the Consultant agrees to abide by all applicable Federal, State, and City procedures, as may be amended from time to time, by which the documents are handled, copied, and distributed which may include, but is not limited to, each employee of Consultant and sub-consultants that will be involved in the Project being required to sign an agreement stating that they will not copy, duplicate, or distribute the documents unless authorized by the City Manager, in writing. 16.5.2.2 The Consultant and its sub-consultants agree in writing that the Project documents are to be kept and maintained in a secure location. 16.5.2.3 Each set of the Project documents are to be numbered and the whereabouts of the documents shall be tracked at all times. 16.5.2.4 A log is developed to track each set of documents logging in the 9 P 99 9 date, time, and name of the individual(s)that work on or view the documents. 16.6 CORRECTIONS TO CONTRACT DOCUMENTS: The Consultant shall prepare, without added compensation, all necessary supplemental documents to correct errors, omissions, and/or ambiguities which may exist in the Contract Documents prepared by Consultant, including documents prepared by its sub-consultants. Compliance with this subsection shall not be construed to relieve the Consultant from any liability resulting from any such errors, omissions, and/or ambiguities in the Contract Documents and other documents or Services related thereto. 16.7 WARRANTY: The Consultant warrants that the Services furnished to the City under this Agreement shall conform to the quality expected of and usually provided by the profession in the State of Florida applicable to the design and construction of public and commercial facilities. 16.8 NON-EXCLUSIVITY: Notwithstanding any provision of this non-exclusive Agreement, the City is not precluded from retaining or utilizing any other architect, engineer, design professional or other consultant to perform any incidental Basic Services, Additional Services, or other professional services within the contract limits defined in the Agreement. The Consultant shall have no claim against the City as a result of the City electing to retain or utilize such other architect, engineer, design professional, or other consultant to perform any such incidental Services. g) 16.9 ASSIGNMENT: The Consultant shall not assign, transfer or convey this Agreement to any other person, firm, association or corporation, in whole or in part, without the prior written consent of the City Commission, which consent, if given at all, shall be at the Commission's sole option and discretion. However, the Consultant will be permitted to cause portions of the Services to be performed by sub-consultants, subject to the prior written approval of the City Manager. g) 16.10 SUCCESSORS AND ASSIGNS: The Consultant and the City each binds himself/herself, his/her partners, successors, legal representatives and assigns to the other party of the Agreement and to the partners, successors, legal representatives, and assigns of such party in respect to all covenants of this Agreement. The Consultant shall afford the City (through the City Commission) the opportunity to approve or reject all proposed assignees, successors or other changes in the ownership structure and composition of the Consultant. Failure to do so 9 P P constitutes a breach of this Agreement by the Consultant. 16.11 PROVISION OF ITEMS NECESSARY TO COMPLETE SERVICES: In the performance of the Services prescribed herein, it shall be the responsibility of the Consultant to provide all salaries, wages, materials, equipment, sub-consultants, and other purchased services, etc., as necessary to complete said Services. 16.12 INTENT OF AGREEMENT: g) 16.12.1 The intent of the Agreement is for the Consultant to provide design services, and to include all necessary items for the proper completion of such services for a fully functional Project which, when constructed in accordance with the design, will be able to be used by the City for its intended purpose. The Consultant shall perform, as Basic Services, such incidental work which may not be specifically referenced, as necessary to complete the Project. g) 16.12.2 This Agreement is for the benefit of the parties only and it does not grant rights to a third party beneficiary, to any person, nor does it authorize anyone not a party to the Agreement to maintain a suit for personal injuries, professional liability, or property damage pursuant to the terms or provisions of the Agreement. 16.12.3 No acceptance, order, payment, or certificate of or by the City, or its employees or agents, shall either stop the City from asserting any rights or operate as a waiver of any provisions hereof or of any power or right herein reserved to the City or of any rights to damages herein provided. 16.13 This document incorporates and includes all prior negotiations, correspondence, conversations, agreements, or understandings applicable to the matters contained herein; and the parties agree that there are no commitments, agreements, or understandings concerning the subject matter of this Agreement that are not contained in this document. Accordingly, the parties agree that no deviation from the terms hereof shall be predicated upon any prior representations or agreements whether oral or written. It is further agreed that no modification, amendment or alteration in the terms or conditions contained herein shall be effective unless memorialized in written document approval and executed with the same formality and of equal dignity herewith. F:latto\AGUR\AGREEMENT FORMSIA&E AGREEMENTS\A&E Agreement-NEW BOILER PLATE(Clean Version 8-2-10).doc IN WITNESS WHEREOF, the parties hereto have hereunto caused these presents to be signed in their names by their duly authorized officers and principals, attested by their respective witnesses and City Clerk on the day and year first hereinabove written. Attest CITY OF MIAMI BEACH: CITY CLERK MAYOR CONSULTANT: XXXXXXXXXXXXXXX Attest Signature/Secretary Signature/President Print Name Print Name SCHEDULE A SCOPE OF SERVICES SCHEDULE B CONSULTANT COMPENSATION • Schedule of Payments Planning Services* $ 0.00 Design Services* $XX)UUUCXX Bidding and Award Services $XXJUUUCXX Construction Administration** $XXXXXXXX Reimbursable Allowance*** $XXXXXXXX Historic Preservation Board/Design Review Board (if required) $ 0.00 Note*: These services will be paid lump sum based on percentage complete of each phase as identified in the individual tasks. Note**: Construction Administration will be paid on a monthly basis upon commencement of construction. In the event that, through no fault of the Consultant, Construction Administration services are required to be extended, which extension shall be subject to prior City approval, and what shall be at the City's sole discretion, the Consultant agrees to extend said services for $XXXXXX, per month, for the duration required to complete the Project. Note***: The Reimbursable Allowance belongs to the City and must be approved in writing, in advance, by the Project Coordinator. Unused portions will not be paid to the Consultant. SCHEDULE C HOURLY BILLING RATE SCHEDULE SCHEDULE D COSTRUCTION COST BUDGET II SCHEDULE E PROJECT SCHEDULE SCHEDULE F GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT SCHEDULE G INSURANCE REQUIREMENTS AND SWORN AFFIDAVITS. SCHEDULE H BEST VALUE AMENDMENT The Consultant agrees to abide by all the required documentation of the City's Performance Information Procurement System and submit the weekly reports. ATTACHMENT C CONSULTANT'S RESPONSE TO THE RFQ 35 . . . . el miAmi .BEAcH .err ....,i, REQUEST FOR QUALIFICATIONS (RFQ) PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" RFQ 2014-346-YG Group A - ARCHITECTURE Inter4orDesign / SpaeeRng Nip '�-- 1 J I s 1, t _'. t i I i )., 1 . - fiii 7 --- ' .iiig ,.,- ----..n' - id. ; 41. „OM illii IC '-'17.' ' a 1 K, *104 ;:a.440,1111. \ . i V.4 ' M [Li A . .., „.., ..,........ri . r li ��� edward lewis �_ It � .," ■ •=' .� architects ' - ' i '- _/_ - ,T 1 ..,;. Prepared by r,_ EDWARD LEWIS ARCHITECTS, INC. 2100 Ponce de Leon BLVD,Suite 825 - `L Coral Gables, FL 33134 ' 0 .—ti 'as' _ -: 305.234.0576 =_. elewis @elamiami.com I I I ' I 1 1 -- CA M AM BEAc H REQUEST FOR QUALIFICATIONS(RFQ) PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN "AS-NEEDED-BASIS" RFQ 2014-346-YG Table of Contents • Cover Letter • Appendix A- Response Certification,Questionnaire& Requirements Affidavit • Architecture Licenses and Certifications • FORM 330 • Section A-Contract Information '� ""��y...'" • Section B-Architect Point of Contact • Section C-Proposed Team • Section D-Organization Chart(See Attached) • Section E-Resumes of Key Personnel • Section F- Examples Projects • Section G- Key Personnel Participation • Section H -Additional Information • Section I-Part II • Resume and Bios • Organizational Chart • Supplier Qualification Receipt • Approach and Methodology ARCHITECTURE re PLANNING INTERIOR CONSTRUCTION SERVICES 17 edward lewis architects mFIjlj\_ ARCHITECTURE PLANNING Alex Denis,Director INTERIOR DEPARTMENT OF PROCUREMENT CONSTRUCTION SERVICES 1700 Convention Center Drive edward lewis Miami Beach, FL 33139 architects 305.673.7490 I adenis @miamibeachfl.gov Dear Alex, Edward Lewis Architects, Inc.-ELA is pleased to submit this package "Group A-Architecture:General"to the RFQ 2014-346-YG. We are providing an executive summary of our qualifications for this continuing service contract as part of this cover letter. We are pleased and excited to highlight why ELA and our team should be selected for this assignment. Relevant Experience with Continuing Services Contracts-ELA-Edward Lewis Architects Inc. brings extensive design experience with Continuing Service Contracts,including over 600,000 square feet of projects in the last 7 years. In the past ELA was awarded the same Continuing Service Contract with the City of Miami Beach and successfully completed numerous projects with the City. ELA has the necessary past experience and expertise that The City of Miami Beach needs to support the diverse needs for general architecture and interior design/space planning services and the knowledge to guide each projects through the municipal approval process. ELA has successfully completed over 200 projects thru PSA or continuing service agreements with the following faculties agencies and municipalities: • Continuing Service Agreement with the State of Florida • Miami Dade County PSA-GSA • City of Miami Beach Continuing Services Contract • Miami Dade County PSA-Public Works • .GSA-Continuing Services-Contract for Miami Dade County • Coral Gables Continuing Service Agreement-•Public Works- • Miami Dade College Continuing Services Contract • Baptist Health of Florida Continuing Service Agreement • Broward County Public Schools Continuing Services Contract • Jackson Memorial Hospital Continuing Service Agreement • Miami Dade County Parks&Recreation Continuing Services Contract • Miami International Airport Continuing Services Contract Many of these projects are nut and bolt projects,each assignment is an important commission and we place a priority on complet- ing these projects. Most recently ELA has provided space planning and design services for the.60,000sf for the West Kendall Baptist Hospital-Medical Arts Building that consisted of programming,space planning,interior architectural services and construction administrative service. Recent Experiences-ELA is one of the leading architectural design firms in South Florida.We have been working with many private and public sector clients with continuing services agreement. ELA's experience stands on its own,theCity of Miami Beach can take comfort in knowing that due to the wealth of experience and a diverse range of projects that have been completed by ELA and our team,that each project will be a success.Our teams experience mirrors those projects found within a continuing services con- tracts.We have successfully completed these projects on time,budget and without significant problems due to the leadership within ELA,our team is qualified. Current and projected workloads of the firms-ELA's work load is moderate and we have the resources that will allow ELA to ac- complish your projects.ELA is a stable and strong firm that has the resources to provide the services required for a continuing ser- vice agreement.. Technical and Florida licensed professional staff-ELA has licensed architects and LEEDs AP-All ELA staff are trained to provide quality services to complete projects found with a continuing service contract. ELA and staff have a great working knowledge of the building codes and have good working relationships with the municipalities that make up South Florida. Our clients and projects benefit from the unselfish dedication and tireless effort that the team at ELA provides.Our clients can rely on our track record to produce quality designs and construction documents.Your projects and facilities deserve the hands-on at- tention that you will receive with our team. Sincerely, "4161St Edward Lewis,Al>LEE AP 2100 PONCE DE LEON BLVD, SUITE 825 - CORAL GABLES, FL 33134 ii1Li ARC HITECTURE A Alex Denis,Director �-� INTERIOR DEPARTMENT OF PROCUREMENT 1 CONSTRUCTION SERVICES 1700 Convention Center Drive edward lewis Miami Beach,FL 33139 architects 305.673.7490 I adenis @miamibeachfl.gov Dear Alex, Edward Lewis Architects, Inc.-ELA is pleased to submit this package "Group A-Architecture:Interior Design/Space Planning"to the RFQ 2014-346-YG.We are providing an executive summary of our qualifications for this continuing service contract as part of this cover letter.We are pleased and excited to highlight why ELA and our team should be selected for this assignment. Relevant Experience with Continuing Services Contracts-ELA-Edward Lewis Architects Inc.brings extensive design experience with Continuing Service Contracts,including over 600,000 square feet of projects in the last 7 years. In the past ELA was awarded the same Continuing Service Contract with the City of Miami Beach and successfully completed numerous projects with the City. ELA has the necessary past experience and expertise that The City of Miami Beach needs to support the diverse needs for general architecture and interior design/space planning services and the knowledge to guide each projects through the municipal approval process. ELA has successfully completed over 200 projects thru PSA or continuing service agreements with the faculties agencies and mu- nicipalities: • Continuing Service Agreement with the State of Florida • Miami Dade County PSA-GSA • City of Miami Beach Continuing Services Contract • Miami Dade County PSA-Public Works • GSA-Continuing Services Contract for Miami Dade County • Coral Gables Continuing Service Agreement•---0Public4Works-, • Miami Dade College Continuing Services Contract • Baptist Health of Florida Continuing Service Agreement • Broward County Public Schools Continuing Services Contract • Jackson Memorial Hospital Continuing Service Agreement • Miami Dade County Parks&Recreation Continuing Services Contract • Miami International Airport Continuing Services Contract Many of these projects are nut and bolt projects,each assignment is an important commission and we place a priority on complet- ing these projects. Most recently ELA has provided space planning and design services for the 60,000sf for the West Kendall Baptist Hospital-Medical Arts Building that consisted of programming,space planning,interior architectural services and construction administrative service. Recent Experiences-ELA is one of the leading architectural design firms in South Florida.We have been working with many private and public sector clients with continuing services agreement. ELA's experience stands on its own,the City of Miami Beach can take comfort in knowing that due to the wealth of experience and a diverse range of projects that have been completed by ELA and our team,that each project will be a success.Our teams experience mirrors those projects found within a continuing services con- tracts.We have successfully completed these projects on time,budget and without significant problems due to the leadership within ELA,our team is qualified. Current and projected workloads of the firms-ELA's work load is moderate and we have the resources that will allow ELA to ac- complish your projects.ELA.is a stable and strong firm that has the resources to provide the services required for a continuing ser- vice agreement.. Technical and Florida licensed professional staff-ELA has licensed architects and LEEDs AP-All ELA staff are trained to provide quality services to complete projects found with a continuing service contract. ELA and staff have a great working knowledge of the building codes and have good working relationships with the municipalities that make up South Florida. Our clients and projects benefit from the unselfish dedication and tireless effort that the team at ELA provides.Our clients can rely on our track record to produce quality designs and construction documents.Your projects and facilities deserve the hands-on at- tention that you will receive with our team. Sincerely, Edward Lewis,Al LEtED P 2100 PONCE DE LEON BLVD, SUITE 825 - CORAL GABLES, FL 33134 ARCHITECTURE , RI A PLANNING INTERIOR E CONSTRUCTION SERVICES edward lewls architects Solicitation No: Solicitation Title: RFQ 2014-346-YG PROFESSIONAL ARCHITECTURAL AND ENGINEERING SERVICES IN SPECIALIZED CATEGORIES ON AN°AS-NEEDED-BASIS° Procurement Contact Tel: Email: Yusbel Gonzalez 305.673.7000, Ext.6230 yusbelgonzalez aimiamibeachfl.gov STATEMENTS OF QUALIFICATIONS CERTIFICATION,QUESTIONNAIRE&REQUIREMENTS AFFIDAVIT Purpose: The purpose of this Response Certification, Questionnaire and Requirements Affidavit Form is to inform prospective Proposals of certain solicitation and contractual requirements, and to collect necessary information from Proposals in order that certain portions of responsiveness, responsibility and other determining factors and compliance with requirements may be evaluated. This Statement of Qualifications Certification, Questionnaire and Requirements Affidavit Form is a REQUIRED FORM that must be submitted fully completed and executed. 1. General Proposer Information. FIRM NAME: Edward Lewis Architects No of Years in Business: 35 I No of Years in Business Locally: 27 I No of Employees: 5 OTHER NAME(S)PROPOSER HAS OPERATED UNDER IN THE LAST 10 YEARS: FIRM PRIMARY ADDRESS(HEADQUARTERS):2100 Ponce de Leon BLVD,Suite 825 CITY: Coral Gables STATE: FL I ZIP CODE: 33134 TELEPHONE NO.: 305-234-0576 TOLL FREE NO.: FAX NO.: FIRM LOCAL ADDRESS: CITY: STATE: I ZIP CODE: PRIMARY ACCOUNT REPRESENTATIVE FOR THIS ENGAGEMENT:Edward Lewis ACCOUNT REP TELEPHONE NO.: (305)342-7893 ACCOUNT REP TOLL FREE NO.: (305) 234-0576x.111 ACCOUNT REP EMAIL: elewis @elamiami.com FEDERAL TAX IDENTIFICATION NO.: 65-0020959 The City reserves the right to seek adctitional information from proposer or other source(s),including but not limited to:any firm or principal information,applicable licensure,resumes of relevant individuals,client information,financial information,or any information the City deems necessary to evaluate the capacity of the proposer to perform in accordance with contract requirements. tFQ 2014-346-YG Appendix A— Page 1 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 ARCHITECTURE PLANNING E:10 INTERIOR CONSTRUCTION SERVICES edward levels architects 1. Veteran Owned Business.Is ro oser claiming a veteran owned business status? YES X NO SUBMITTAL REQUIREMENT: Proposals daiming veteran owned business status shall submit a documentation proving that firm is certified as a veteran-owned business or a service-disabled veteran owned business by the State of Florida or United States federal government,as required pursuant to ordinance 2011-3748. 2. Conflict Of Interest.All Proposals must disdose,in their Statement of Qualifications,the name(s)of any officer,director,agent,or immediate family member(spouse, parent, sibling,and child)who is also an employee of the City of Miami Beach. Further,all Proposals must disdose the name of any City employee who owns,either directly or indirectly,an interest of ten(10%)percent or more in the Proposer entity or any of its affiliates. SUBMITTAL REQUIREMENT: Proposals must disdose the name(s)of any officer,director, agent,or immediate family member (spouse,parent,sibling,and child)who is also an employee of the City of Miami Beach. Proposals must also disclose the name of any City employee who owns,either directly or indirectly,an interest of ten(10%)percent or more in the Proposer entity or any of its affiliates 3. Suspension,Debarment or Contract Cancellation.Has proposer ever been debarred,suspended or other legal vidation,or had a contract cancelled due to non-performance by a ublic sector agency? 1 YES II NO SUBMITTAL REQUIREMENT: If answer to above is'YES,'Proposer shall submit a statement detailing the reasons that led to action(s). 4. Vendor Campaign Contributions.Proposals are expected to be or become familiar with, the City's Campaign Finance Reform laws, as codified in Sections 2-487 through 2-490 of the City Code. Proposals shall be solely responsible for ensuring that all applicable provisions of the City's Campaign Finance Reform laws are complied with,and shall be subject to any and all sanctions, as prescribed therein,induding disqualification of their Statement of Qualifications,in the event of such non-compliance. SUBMITTAL REQUIREMENT: Submit the names of all individuals or entities(including your sub-consultants)with a contrdling financial interest as defined in solicitation. For each individual or entity with a controlling financial interest indicate whether or not each individual or entity has contributed to the campaign either directly or indirectly,of a candidate who has been elected to the office of Mayor or City Commissioner for the City of Miami Beach. 5. Code of Business Ethics.Pursuant to City Resolution No.2000-23879,each person or entity that seeks to do business with the City shall adopt a Code of Business Ethics(°Code°)and submit that Code to the Procurement Division with its proposal/response or within five(5)days upon receipt of request.The Code shall,at a minimum,require the Proposer,to comply with all applicable governmental rules and regulations inducing,.among others, the conflict of interest,lobbying and ethics provision of the City of Miami Beach and Miami Dade County. SUBMITTAL REQUIREMENT: Proposer shall submit firm's Code of Business Ethics. In lieu of submitting Code of Business Ethics,proposer may submit a statement indicating that it will adopt,as required in the ordinance,the City of Miami Beach Code of Ethics,available at www.miamibeachfl.gov/procurement/. 6. - • - .. ..• . • - = • - - - '• • o • ••• , . ••• ;. a • RFQ 201 4-346YG Appendix A—Page 2 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 aim.A ARCHITECTURE PLANNING INTERIOR CONSTRUCTION SERVICES edward Iewls architects 7. Equal Benefits for Employees with Spouses and Employees with Domestic Partners.When awarding competitively solicited contracts valued at over$100,000 whose contractors maintain 51 or more ful time employees on their payrolls during 20 or more calendar work weeks,the Equal Benefits for Domestic Partners.Ordinance 2005-3494 requires certain contractors doing business with the City of Miami Beach,who are awarded a contract pursuant to competitive proposals,to provide'Equal Benefits"to their employees with domestic partners, as they provide to employees with spouses. The Ordinance applies to all employees of a Contractor who work within the City limits of the City of Miami Beach,Florida;and the Contractor's employees located in the United States, but outside of the City of Miami Beach limits,who are directly performing work on the contract within the City of Miami Beach. A. Does your company provide or offer access to any benefits to employees with spouses or to spouses of employees? X YES NO B. Does your company provide or offer access to any benefits to employees with(same or opposite sex)domestic partners*or to domestic partners of employees? X YES I-1 NO C. Please check all benefits that apply to your answers above and list in the 'other" section any additional benefits not already specified.Note:some benefits are provided to employees because they have a spouse or domestic partner,such as bereavement leave;other benefits are provided directly to the spouse or domestic partner,such as medical nsurance. BENEFIT Firm Provides for Firm Provides for Firm does not Employees with Employees with Provide Benefit Spouses Domestic Partners Health X X Sick Leave X X Family Medical Leave X X Bereavement Leave X X • If Proposer cannot offer a benefit to domestic partners because of reasons outside your control, (e.g., there are no insurance providers in your area willing to offer domestic partner coverage)you may be eligible for Reasonable Measures compliance.To comply on this basis, you must agree to pay a cash equivalent and submit a completed Reasonable Measures Application (attached)with all necessary documentation.Your Reasonable Measures Application well be reviewed for consideration by the City Manager, or his designee.Approval is not guaranteed and the City Manager's decision is final.Further information on the Equal Benefits requirement is available at www.miamibeachfi.gov/procurement/. 8. Public Entity Crimes.Section 287.133(2)(a),Florida Statutes,as currently enacted or as amended from time to time,states that a person or affiliate who has been placed on the convicted vendor list fdlowing a conviction for a public entity crime may not submit a proposal, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a proposal, proposal,or reply on a contract with a public entity for the construction or repair of a public building or public work;may not submit proposals,Statement of Qualifications,or replies on leases of real property to a public entity;may not be awarded or perform work as a contractor,supplier,subcontractor,or consultant under a contract with any public entity;and may not transact business with any public entity in excess of the threshdd amount provided in s. 287.017 for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list. SUBMITTAL REQUIREMENT:No additional submittal is required.By virtue of executing this affidavit document,proposer agrees with the requirements of Section 287.133,Florida Statutes,and certifies it has not been placed on convicted vendor list. Appendix A—Page 3 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 ARCHITECTURE NIA PLANNING INTERIOR CONSTRUCTION SERVICES edward lewls erchltects 9. Acknowledgement of Addendum. After issuance of solicitation, the City may release one or more addendum to the solicitation which may provide additional information to Proposer or alter sdicitation requirements.The City will strive to reach every Proposer having received solicitation through the City's e-procurement system, PublicPurchase.com. However, Proposals are solely responsible for assuring they have received any and all addendum issued pursuant to solicitation. This Acknowledgement of Addendum section certifies that the Proposer has received all addendum released by the City pursuant to this solicitation.Failure to obtain and acknowledge receipt of all addendum may result in proposal disqualification. Initial to Confine Initial to Confirm Initial to Confirm Receipt Receipt Receipt ELA Addendum 1 Addendum 6 Addendum 11 ELA Addendum 2 Addendum 7 Addendum 12 ELA Addendum 3 Addendum 8 Addendum 13 ELA Addendum 4 Addendum 9 Addendum 14 Addendum 5 Addendum 10 _ Addendum 15 If additional confirmation of addendum is required,submit under separate cover. • II IFQ 2014-346-YG Appendix A—Page 4 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 E d.L ;,A PLANNINGTURE INTERIOR CONSTRUCTION SERVICES • edward lewis architects DISCLOSURE AND DISCLAIMER SECTION The solicitation referenced herein is being furnished to the recipient by the City of Miami Beach(the°City°)for the recipients convenience. Any action taken by the City in response to Statement of Qualifications made pursuant to this sdicitation,or in making any award,or in failing or refusing to make any award pursuant to such Statement of Qualifications,or in cancelling awards, or in withdrawing or cancelling this solicitation,either before or after issuance of an award,shall be without any liability or obligation on the part of the City. In its sole discretion,the City may withdraw the sdicitation either before or after receiving Statement of Qualifications,may accept or reject Statement of Qualifications,and may accept Statement of Qualifications which deviate from the solicitation,as it deems appropriate and in its best interest.In its sole discretion,the City may determine the qualifications and acceptability of any party or parties submitting Statement of Qualifications in response to this sdicitation. Following submission of Statement of Qualifications, the applicant agrees to deliver such further details, information and assurances, inducing financial and disclosure data, rdating to the Statement of Qualifications and the applicant inducing, without limitation, the applicant's affiliates,officers,directors,sharehdders,partners and employees,as requested by the City in its discretion. The information contained herein is provided solely for the convenience of prospective Proposals. It is the responsibility of the recipient to assure itself that information contained herein is accurate and complete.The City does not provide any assurances as to the accuracy of any information in this solicitation. Any reliance on these contents,or on any permitted communications with City officials,shall be at the recipient's own risk.Proposals should rely exdusively on their own investigations,interpretations,and analyses.The solicitation is being provided by the City without any warranty or representation,express or implied,as to its content,its accuracy,or its completeness.No warranty or representation is made by the City or its agents that any Statement of Qualifications conforming to these requirements will be selected for consideration, negotiation, or approval. The City shall have no obligation or liability with respect to this solicitation,the selection and the award process,or whether any award will be made.Any recipient of this sdicitation who responds hereto fully acknowledges all the provisions of this Disdosure and Disdaimer,is totally relying on this Disdosure and Disdaimer,and agrees to be bound by the terms hereof.Any Statement of Qualifications submitted to the City pursuant to this solicitation are submitted at the sole risk and responsibility of the party submitting such Statement of Qualifications. This solicitation is made subject to correction of errors,omissions,or withdrawal from the market without notice.Information is for guidance only,and does not constitute all or any part of an agreement. The City and all Proposals will be bound only as,if and when a Statement of Qualifications,as same may be modified,and the applicable definitive agreements pertaining thereto,are approved and executed by the parties,and then only pursuant to the terms of the definitive agreements executed among the parties.Any response to this sdicitation may be accepted or rejected by the City for any reason,or for no reason,without any resultant liability to the City. The City is go/erne-CI'bylhe_Government-in-the-Sunshin. Law, and all Statement of Qualifications and supporting documents shall be subject to disclosure as'tbquired by such law.All-Statement of Qualifications shall be submitted in sealed proposal form and shall remain confidential to the extelftiperrnitted by Florida Statutes;.'until the date and time selected for opening the responses. At that time, all documents received by the City'shall become;public recoris. Proposals are expected°to.make all disclosures ancclarations as requested in this solicitation. By submission of a Statement of Qualifications,the Proposer acknowledges and agrees that the City has the right to make any inquiry or investigation it deems appropriate to substantiate or supplement information contained in the Statement of Qualifications, and authorizes the release to the City of any and all information sought in such inquiry or investigation.Each Proposer certifies that the information contained in the Statement of Qualifications is true,accurate and compete,to the best of its knowledge,information,and belief. Notwithstanding the foregoing or anything contained in the solicitation,all Proposals agree that in the event of a final unappealatle judgment by a court of competent jurisdiction which imposes on the City any liability arising out of this sdicitation, or any response thereto,or any action or inaction by the City with respect thereto,such liability shall be limited to$10,000.00 as agreed-upon and liquidated damages.The previous sentence, however, shall not be construed to circumvent any of the other provisions of this Disclosure and Disclaimer which imposes no liability on the City. In the event of any differences in language between this Disdosure and Disdaimer and the balance of the solicitation,it is understood that the provisions of this Disclosure and Disclaimer shall always govern.The solicitation and any disputes arising from the sdicitation shall be governed by and construed in accordance with the laws of the State of Florida. P?FQ 2014-346YG Appenclix A—Page 5 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 1EJ ARCHITECTURE L+ PLANNING INTERIOR CONSTRUCTION SERVICES edward lewis architects PROPOSER CERTIFICATION I hereby certify that I,as an authorized agent of the Proposer,am submitting the following information as my firm's proposal; Proposer agrees to complete and unconditional acceptance of the terms and conditions of this document, inclusive of this solicitation, all attachments, exhibits and appendices and the contents of any Addenda released hereto, and the Disclosure and Disclaimer Statement;proposer agrees to be bound to any and all specifications,terms and conditions contained in the solicitation, and any released Addenda and understand that the following are requirements of this solicitation and failure to comply will result in disqualification of proposal submitted;Proposer has not divulged,discussed,or compared the proposal with other Proposals and has not colluded with any other proposer or party to any other proposal; proposer acknowledges that all information contained herein is part of the public domain as defined by the State of Florida Sunshine and Public Records Laws; all responses, data and information contained in this proposal, inclusive of the Statement of Qualifications Certification,Questionnaire and Re•uirements Affidavit are true and accurate. Name of Proposer's Authorized Representative: Title of Proposer's Authored Representative: Edward Lewis President Signature of Proposer' Au orized Representative: Date: 10/21/2014 O State of FLORIDA ) On this R day of k a ed,204 pesona*y appeared before me watu iir"�►�� who County of {u i A v1 -Or'-oi5 ) stated that (s)he is the ec:0(Kit- of f;+NIir_crl K ?'a corporation,and that the instrument was signed in behalf of the said corporation by authority of its board of directors and acknowledged said instrument to be its voluntary act and deed.Before me: N10.3 c-VLk . Ltit *gay P tht,Stile 4LFI tidL_ My Corn orb Ices AW +:o ee�': Pub •S o1 Fl $.e e•_My Notary Comm.Emplic ties Aar tate 20.201orida 6 ' ,-a o°= Commissloit 0 FF 904612 ���' , d`' Bonded Through Wand Notary Assn. /1 Appendix A—Page 6 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 • ,..„ . . c j • I 1 , 1:1 E I ,.. ...... ...... ..... ..... ..... ( I 0 0 0 os .0 0 0 ,,, 0 ,,, Q Q -v Q 2§1 ; T 0.. iZ: I. 1=. iz: F:. I■ ci'1 8 o co o . 0 . 41,-B. 1.6 , ."' - . .6 e E ta m ... . .0.. -- .1.§ ! ' 6 ; 0 4 i.0 z.. t.) . 1 0 4.). --. 0 ' m • 9 e .FI 6•-, . . - . • •F. ra E. 6 0 , < . , . Z E cil ,4 z _. , . 0.... c, ‹ g z 2 : 2 ' ui 0 EE 6,- - z pm , . „ W 0 W W 0 i W 0 LLJ Z LI , " t...- 5 ,,,- u • = 4. I . cs. I z •-• n (r c(k) w Li ,-'c 12 G < g; Li < et ,...1 , 2 ; 0 ., cA' 2 E2 , 0 . ti im E a › ta 1 ;-« i, z ...,E. u -I' 0 ri 03,. 2.8,_: . ...., LL., •cc . >. w , 0 0 _ _ <.-, I_ zLn 2 Lu 01- oi- u 1- r;t • W 0...-9, 0 g 2' 1-. 1.- 1-- ■ I:: W W I I F-- 4 i 0 ,_ 5 z z (1- u < Cl) R a — isz ..--z > LLI W CK re 0 "g 1.1.1 2 !.-, . • : ; Cif) . , . • ; z lisU . . . - t* t1 f, _, „,t,„....,_,...„ i,,,, 1 „::„,,,,, iti 1 i_„.1._,„,_ 4. 72: 73 sE P.Oi 2 6 o 0 g". '--s- =,ti:0 a -. 1 .s.. -65 '68<c) "I3 a.o. >, .% , MIN= , 1 --=',;•-•:if,' -, ', .0 To SI e a-'-p,,.: 4.2 all, -4 5 ri '; .2 - - -E Q, • -,F. 0 j I . I fW.",'-' 4 !:i;':='W' ;::= ,,f;•;':"-- ° ,.;;;- '? -. 0 g 2 8 a3 c.) ...., - S '.- a- c—' „.. !...!, ,--,e 2' A 0 0 9,,`- - •92 - E 'Al a's Tr'3 m .9. 'a ,-fg.,-., a --G. 6. •.9 L48. g -Ti 8 EV10 . - - ±.!---:,---:,..-.. ,---- 0:._ 9. . •• F,-;',., 0 g g'-'5 o ,g,St,L rise;s , _ . a15 W.:::-, :=-C, -''' wc. -.:-:-.",,,>•9 c 2--, ...2,T,,- , g : -.T"...' ,.., ,,,?.", 3-0 .0 .7,.,-. 5,,3- E 15.g,..c 9 5 . g c 0-JR - ! R i-f::,:r::-:i —-s' l'6 ?1 1 d :1-F,..--,,_, E. 0 -.''' i 1 0 ! . ir.-..--,..-.:-.-f- ,r; o .5 E .i.-,-•& ,g cci. .t.-.c o c .2E,,1,0,:2 re; t2,4203,8 _ E,'•\J-J? --'12--- "---8-ge 74!7.---, d 00 a 1 . 8§: L--"6 ,:-.41•2 -g,=.3 i'...e2 74v, •---!gyil-2' .,.%.2! ›..,(c E 2 t T) ■ -7 P.I 0.1 -1.5 mo t V, v. 5.-.9. . cl:ZE ..1 2- g c 2 00 - -g.o t*,- I g.;;:-..pl.-2 5:".=;%•.:CI `,,'-' a E V. •?••E e ce .9.41_4E <55 u.74.=---al mt811 - ° --- 8!sa 0'02 t; ,e, 2 A §i',, 2 12 ,-7,.....-,g ...)5 S.-,'S.9...c• IP:u c if cg 0.., >,-- - ,•, r.,0 0,,, (-)2, ,5_`Tg' `14%'‘ 2- n, 2---'C''•S..:625.71, Fai.73-9',.-76 , • ! 2 • 1 :;•,!--..r --;:‘z> ,..., -= 43& ,r,-; 2= 0-6 '3 a?.'.=-. -- '.g ___-0 aocc t0A - o- u > rn 8.9 '--- 0 c c.)- o.-- - '.§---=, . i 2?a,'75 I tiGui=.;11<i ifii `-' a, -s4 g ei g 5 ,cs-.....: .0. ..F.,g,iii 5 -. -i.... s.t-•,2 2-7.E g 2 74 2 ! 3 0 ca. , P;•-;-;Laclo =,,`1! e EL' ,5.§ t- -; 0 E a '8-6 .2• •'4"Fit2 t'''-.C.3 ' ..e; 't,•? 22i.4-23a‘ 4:- -a 0 1 !-_,-..:tz.:;-- g ..§. a) ,.4- u;. .2 -E.s -a-e a g t-,F.,-Z,.s-e.'--E- F...§-„,-3 ,,„5 731 L.-,_m-8-_,.. , .f,......,,,z E , -,„0--..- 2-E 1--t 3.9 . --'•,,, -2.. ...:-.-.-0! .8.i3- ''''''o).; 8= .8. ,1 _8 .-5 -3 m .'5 2 §:.2 .g:i-?,g ..r --eg 8.5. 2 --'76,s. i ,,,:•;i2:— ,-- . 0 _i 2.9. f.,.9 u e g 0;, 2 -6.-. (.?...L. .7.-7, l'-' - - g.,„';" ,--::-.--E ,51tiv--/- ,... — . - .c. t2-'•,-- a 4-g-,9,o c - o a a P 0. ,,,,.. 0 < ii rc - r.5- 15 '9- -m"' 9a5 -2° _-,,•-',-, '§' °2 g 70-g. 1.'0 . 3 --. €,o2; l 0•E,7.4 II .s 3,9 ilz.8 2.9. 1...-, 2-0- 2 ur.-.D ,- '4 2 51g —:-.-, "_-23,Tii :, - 32B.?ai aB.G? -6,,,f, "".. -E 0 .„,:,, , -.X.:f ui •,.• 1, !---z •23 r....-=', .m0a,- ?.....a 0.---,-•.8.z !a--;-:--.-0 d- ,,,a_ .It r,- TIE WC4Tell. :',4 ..` •75.P 1.7.:E c ro f_5 O!zi.2 .a,E..,.-0 0 0'F.n a 1:%.--w ,-%t ,''.1;',4.1.- , :°: f.,.E iii.= _.4.,T) 2 8 0—B. ....-. '6 g.`2=97.8 '01"-?...1 8: •-?.: Et.88 ...,...,..- 4. :!: ..i..--1:-. .-a.. ...,..-,2.. ,.,...,9-Fe,.- g et.E a) 5 . :,-3. -&-ce,-. mT;F! ,ual.-.9. :,..--hgE.:...- Q..52 )-,t p,•,,, >z,a) tyrk:::::-.-. •,,.- 2,T, z.g oR 5201 B2, ..1,?. 39-5.22 oz.-2.. g88c ro'17.-FT >!0r-g.-'2 t•ae851 8.E." itgo',.:a g,- 2f.: 2-7,3..{9 t ,B3t a- `,,..' t?f,1 '.4.-,■51 0 t ,--la.;:,,,,, a.> a :3,,:-.--: ::'.• ; Eg t-,-," - lig ,..>,0 u-,,m -.:9:72 27,2-,.--;',,-, k f:t--:,...,..6 9..2-0 ,...., „, 2' I; g ES FogdE e-.° 2R-8.?-a• ,4--'° ° !i t.-F3 0a.0e 0,. =29). 1'14 mt.g,2 Lii.. ,..F_ =,28 9 ,,,,T4 --• '-• c e ia g.6 S2 '. 4'8 a 2 Z O : n .s 4 m 6 _ a ca 0 Eff-.=,:',;.--• g =t 15 0-2 ,2(.()zi a ira.a uF!=Jo''a Lil <2 a.4..). ct a.''2 cc vg g t., m ...• .....c• .me-ci, Z- `44.-',24,...- if.T-'4 ,-: ,i ei <i ui c:i r■ G r ,� O W E a G 1 :!. F" b rn O o el .y ,y tit Iftaill4 41 LI 1. \, 3 O b y d O O v 0 a� i d u ® ill Q K.O iV w 'C r) a) Z u O O & 5'..' .2 02 1 N > rn �' _ t st a tit 1:Z b 0 "0 V N 'O I °ii .) I•. 0 . 011 cig.�'' O Hi ,fir,_yr,-p.:•z . ,. t=1 3 :'LY j CIO Cl) z Uml 0 _ 0 "'d e b a o asi 1 C n 1111 i::_i: M? Z ~ 'K 8 �L V IM H' ? `, 5 ° d R O 1[-,3 1 4 1 s , a F WOMJ % F KO f �— Z = 1x e 0 Y to ��AA 1. Z V� CSM z to m mN E �j:': s �a ' mo _ N = i� ' . Y a i .. -. = the az O _ E Oa ON m i 0 OH •.r r d V .- O m x) 2 wm fi , 7•77'7m i- W w of `a - O- v� a .3.3 s ,f h,4447' W 'H ,.. _e`' -m Ji{ m F-'.,e, pma.d_ a fl,;, V z 0 < 1°'rn m w ,�uryo Nf n z N `'`� y"I.:''..va a.. t D i E. ... a n O '3 m 'o I'M n W .' o D.00 ,�-� u'n ,F.''';', C 3 6.0 Oi a edn '� " OG m o mrF+oa. O a o co 'Dm I • ' V _ :_ u u z u o u % u m C g� 'r Hmwm Fm = A < qwm J _ _ 9 F i on N!. s 1-. 00 Oro qqc cqC ' y 003 '. W _ ' i % 'OH 2re E. I.400 '� 'o' _ 22.1'4' 400 ([+. {f U O f+. mm [�+. I CO 0 ' O E(8°4 O hm+0�£££pp to 00 I 3 Q M �.�i c, . 90 (i Z n�i"°wV C1 VAO N t"1:43 g '1 I 1 LJ.1 -..� _ C∎, n fm••O aC I. UO ,r) c'°F D 6C V crag i 111 l-� N M.-/O O a NV ■ .H4-1 O O IA.•0N HO. AP cr) UALY MV Act `o 1..42 CQn II —i -49NM MP I UQ Fill Q :via. ARCHITECT - ENGINEER QUALIFICATIONS PART I -CONTRACT-SPECIFIC QUALIFICATIONS A. CONTRACT INFORMATION 1.TITLE AND LOCATION (City and State) YG Professional Architectural and Engineering Services in Specialized Categories on an As-Needed Basis 2.PUBLIC NOTICE DATE 3.SOLICITATION OR PROJECT NUMBER RFQ 2014-346 B.ARCHITECT-ENGINEER POINT OF CONTACT 4.NAME AND TITLE Edward Lewis, Leeds, AIA President 5.NAME OF FIRM Edward Lewis Architects 6.TELEPHONE NUMBER 7.FAX NUMBER 8.E-MAIL ADDRESS 305-234-0576 elewis @elamiami.com C. PROPOSED TEAM (Complete this section for the prime contractor and all key subcontractors.) (Check) 2 >z01- 9. FIRM NAME 10.ADDRESS 11. ROLE IN THIS CONTRACT a aco,- Edward Lewis Architects 2100 Ponce de Leon BLVD Architecture, Interior Coral Gables, FL 33134 Architecture and Design a. Suite 825 ❑CHECK IF BRANCH OFFICE b. ❑CHECK IF BRANCH OFFICE C. ❑CHECK IF BRANCH OFFICE d. ❑CHECK IF BRANCH OFFICE e. ❑CHECK IF BRANCH OFFICE f. ❑CHECK IF BRANCH OFFICE D.ORGANIZATIONAL CHART OF PROPOSED TEAM [ (Attached) AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 330(REV.3/2013)PAGE 1 E.RESUMES OF KEY PERSONNEL PROPOSED FOR THIS CONTRACT (Complete one Section E for each key person.) 12.NAME— 13.ROLE IN THIS CONTRACT 14.YEARS EXPERIENCE Edward Lewis,AIA, Leeds AP Principal, Designer, Quality Controls a.TOTAL b.WITH CURRENT FIRM 35 years 27 years 15.FIRM NAME AND LOCATION(CITY and STATE) ELA-Edward Lewis Architects, Inc. -Coral Gables, FL 16.EDUCATION(DEGREE AND SPECIALIZATION) 17.CURRENT PROFESSIONAL REGISTRATION(STATE AND DISCIPLINE) Bachelor of Architecture, University of Tennessee Lisc. No. 9567 -State of Florida, 1982 LEEDs Accreditation-2008 Architecture,AAC1001678 Architecture, Interior Design, Interior Architecture, Cost Management. 18.OTHER PROFESSIONAL QUALIFICATIONS(Publications,Organizations,Training,Awards,etc.) Edward Lewis has practiced architecture in South Florida for over 35 years. Ed has manage many of IIIthe continuing services contracts with clients such as The City of Miami Beach, Miami Dade County, Miami Dade Aviation Department, Baptist Hospital, Jackson Memorial Hospital, and Miami Children's J Hospital, GSA and The City of Coral Gables. The types of continuing service projects that Ed has managed include General Architecture, Municipal buildings, Administrative Offices, Parks, Hospital Facilities, Helipads, Interior Design Services, Planning Studies, Space Planning and other tenant related services. Edward is a Past President of the Miami Chapter of the American Institute of Architects and State Director. He has been recognized by the AIA and the Building industry for his outstanding service to the profession. He has been a guest on the NBC morning news program and a guest on CBC (The Canadian Broadcast Network) and has been the focus of numerous newspaper and magazine special reports concerning construction and architecture. Ed study graphic art prior to architecture and brings a unique understanding of forms, texture and color to each project. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED Baptist Health BHE—Continuing Service Agreement `PROFESSIONAL SERVICES _CONSTRUCTION(if applicable) 2007-2014 a. (3)BRIEF DESCRIPTION(Bnef sco e,size,cost,etc.)AND SPECIFIC ROLE p � Check if project performed with current firm Ed has been the design architect and principal in charge for the 65 projects under this continuing service agreement.These projects include various Clinical, Medical • South Miami Hospital-CSA Office and Minor Hospital renovations, additions,ADA upgrades, and new construc- tion projects. • Baptist Hospital-CSA ELA has completed 64 projects under this agreement. • Operating rooms, patient wings, instrument processing and sterilization • West Kendal Hospital-CSA departments, and diagnostic and CT scan facilities are among the projects completed to date. • Homestead Baptist Hospital-CSA • ELA designed the office interiors for 24 tenants at the 50,000 SF West Kendall Baptist Hospital. • Doctors Hospital-CSA • 6 AHCA reviewable projects All assignments have been completed on time and in budget and required careful coordination with multiple contractors, consultants, and end user groups. Principal in Charge -Design,CA Services Quality Control—Leeds AP Architect E. RESUMES OF KEY PERSONNEL PROPOSED FOR THIS CONTRACT (Complete one Section E for each kev person.) b. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED Continuing Service Contract PROFESSIONAL SERVICES CONSTRUCTION(if applicable) Jackson Health Systems 2000-2013 (3)BRIEF DESCRIPTION(Brief scope,size,cost,etc.)AND SPECIFIC ROLE • Check if project performed with current firm Continuing Service Agreement projects included various alteration, expansions and modifications to the main cam- pus. Jackson's projects were complex and had very specific design challenges.The end users had unique require- ments with complex HVAC and mechanical systems, elaborate communication and security systems and other intri- cate engineering systems. Many of the projects included AHCA review that shaped many of the design solutions. Understanding the process was paramount in obtaining approvals in a timely manner. ELA's healthcare work at Jackson was diverse, and included alterations to hospital facilities, diagnostic facilities, lab facilities, ambulatory sur- gical centers, outpatient treatment facilities,emergency rooms and medical offices. Project Role: Principal in Charge - Design Architect—Quality Control C. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED PROFESSIONAL SERVICES CONSTRUCTION(if applicable) City of Miami Beach Professional Services Agreement 2002-2004 (3)BRIEF DESCRIPTION(Brief scope,size,cost,etc.)AND SPECIFIC ROLE • Check if project performed with current fine ELA served as architect to design alterations and code upgrades to their existing facilities, furthermore, the program required ELA to redesign certain facilities as multi-use buildings(i.e.Art Gallery, Meeting Space, Lecture and Theatrical uses). One project the refurbished Rotunda Building will provide the City of Miami Beach with flexible multi-use spaces that can be used by either the City or public community groups. Total Construction Cost$3 Million. Project Role: Principal in Charge -Design Architect—Quality Control d (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED Miami Dade County -GSA PROFESSIONAL SERVICES CONSTRUCTION(if applicable) Continuing Service Agreement 1998-2007 (3)BRIEF DESCRIPTION(Brief scope,size,cost,etc.)AND SPECIFIC ROLE • Check if project performed with current firm ELA held this Continuing Service Agreement from 1998 until 2007. Many of the projects had unique requirements with complex programming and planning requirements,some projects required approval from the historical boards, many of the projects included elaborate communication and security systems and other intricate engineering systems. The projects and scope of work ranged from ADA Compliance issues,ADA Audits,40 year recertification, conceptual designs, additional office spaces, remodeling, and new construction. Projects Include: Project Role: Principal in Charge -Design Architect—Quality Control e. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED City of Coral Gables PROFESSIONAL SERVICES CONSTRUCTION(if applicable) Continuing Service Agreement 2002-2012 - (3)BRIEF DESCRIPTION(Brief scope,size,cost,etc.)AND SPECIFIC ROLE •Check if project performed with current firm CSA 10 years-ELA was selected thru a short list process for a Continuing Service Contract with Public works, under this agreement ELA has performed over 30 municipal projects. Many of the projects have involved with working with local communities to to develop a consensus and include public participation during the process. ELA is also involved with the alterations to all the cities parking garages, nine ADA Improvement projects, including historical facilities, the City Hall and Commission Chambers, the redesign and remodeling of their downtown Police and Fire station.ELA provide space planning services for the first major remodeling of this 81,000 square foot Fire and Police space since its construction over 20 years ago. Project Role: Principal in Charge -Design Architect—Quality Control Section E Architect Completed GSA Standard Form 330 E. RESUMES OF KEY PERSONNEL PROPOSED FOR THIS CONTRACT (Complete one Section E for each key person.) 12.NAME— 13.ROLE IN THIS CONTRACT 14.YEARS EXPERIENCE Krista Lewis,VP Project Manager a.TOTAL b.WITH CURRENT FIRM 11 11 15.FIRM NAME AND LOCATION(CITY and STATE) Edward Lewis Architects,Inc. -Coral Gables, FL 16.EDUCATION(DEGREE AND SPECIALIZATION) 17.CURRENT PROFESSIONAL REGISTRATION(STATE AND DISCIPLINE) Miami Dade College - Associate in Arts Degree in Interior Design Interior Designer-Interior Architecture In training Florida International University - Bachelor of Arts in Art NCIDQ Registration in Process Minor:Art History 18.OTHER PROFESSIONAL QUALIFICATIONS(Publications,Organizations,Training,Awards,etc.) Krista is a project architect and design at ELA and has worked on over 120 projects at ELA. She is currently working with ELA staff on a variety of continuing service contract projects for both the health care and private sector. Krista main focus is on the design elements of the projects focusing on the interior elevations, millwork, finishes, tile patterns and other interior detailing for each project. 19. RELEVENT PROJECTS (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED PROFESSIONAL SERVICE CONSTRUCION(If applicable) Baptist Health BHE 2007-2011 2007-2011 a (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE ■Check if project performed with current firm Krista been a project architect and designer on over 30 projects under this agreement.These projects include various Clinical, Medical Office and Minor Hospital renovations,additions,ADA upgrades, and new construction projects. She has focused on the design ele- ments of each project, millwork, Each project has been completed with a minimum of change orders and within the established (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED Miami Children's Hospital PROFESSIONAL SERVICE CONSTRUCION(If applicable) Continuing Service Contract 2002-2008 b (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE ■Check if project performed with current firm Krista worked with the PM on renovations, additions, and ADA upgrades.Among the modified areas were the Research Building's boardroom, reception area, simulation emergency lab, monitoring rooms, and library. In the Annex Building the billing and account- ing, ophthalmology, office, radiology, neurology, and cottage#4 were modified. Interior renovations, a new stair Tower, and decon- tamination showers were also part of the project's scope. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED City of Coral Gables PROFESSIONAL SERVICE CONSTRUCION(If applicable) Continuing Service Agreement 1998-2008 c (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE ■Check if project performed with current firm CSA 10 years-Krista assisted the PM on the projects performed under this agreement. Many of the projects have involved with working with local communities to develop a consensus and include public participation during the process. ELA is also involved with the alterations to all the cities parking garages, nine ADA Improvement projects, including historical facilities, the City Hall and Commission Chambers. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED South Miami Hospital PROFESSIONAL SERVICE CONSTRUCION(If applicable) Annex NICU Interior Upgrades 2013-2014 d (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE •Check if project performed with current firm Krista was the Project Manager for SMH 3 Annex NICU Interior Upgrades project.This 5300sq Interior upgrade project included providing; interior renovations to the existing level II NICU, Programming, Space Planning and Interior Architectural Services. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED Cox Radio Headquarters- Broward County PROFESSIONAL SERVICE CONSTRUCION(If applicable) 2012-2014 e (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE In Check if project performed with current firm Krista is the PM for Cox Radio Headquarters in Broward County. The interior improvement project consist of; COX Media's new Performance Center, Creativity Rooms, New Lobby-Reception and Training Room projects are located within an four storey exist- ing office building. Section E Architect Completed GSA Standard Form 330 E. RESUMES OF KEY PERSONNEL PROPOSED FOR THIS CONTRACT (Complete one Section E for each key person.) 12.NAME— 13.ROLE IN THIS CONTRACT 14.YEARS EXPERIENCE Leslie Escobar Project Manager a.TOTAL b.WITH CURRENT FIRM Construction Administration 17 6 15.FIRM NAME AND LOCATION(CITY and STATE) Edward Lewis Architects, Inc. -Coral Gables, FL 16.EDUCATION(DEGREE AND SPECIALIZATION) 17.CURRENT PROFESSIONAL REGISTRATION(STATE AND DISCIPLINE) 1988-1993 Ponteficia Universidad Javeriana,Bogota,Colombia Architect Architecture and Design Bachelor of Arts Degree 1992 Universidad Javeriana,Cartagena,Colombia NCARB Registration in Process 2004 Miami Dade Community College, Miami, FL 2002-CADD 2001-3d Studio: Program Management 18.OTHER PROFESSIONAL QUALIFICATIONS(Publications,Organizations,Training,Awards,etc.) Leslie Escobar is a senior project manager, Leslie has worked on ELA continuing service contracts.Conscientious and detail ori- ented with a thorough understanding of design and construction practices,Leslie works closely with the expanded project team to ensure projects meet client's expectations.She is LEEDs trained architect and has exception computer and CADD skills. 19. RELEVENT PROJECTS (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED PROFESSIONAL SERVICE CONSTRUCION(If applicable) Baptist Health BHE -Continuing Service Agreement 2007-2011 a (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE •Check if project performed with current firm Leslie has been the project manager on over 30 projects under this agreement.These projects include various Clinical, Medical Of- fice and Minor Hospital renovations, additions,ADA upgrades, and new construction projects. Each project has been completed with a minimum of change orders and within the established budget. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED Miami Children's Hospital -Continuing Service Contract PROFESSIONAL SERVICE CONSTRUCION(If applicable) 2002-2008 b (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE ECheck if project performed with current firm Leslie was PM and managed various renovations, additions, and ADA upgrades.Among the modified areas were the Research Building's boardroom, reception area,simulation emergency lab, monitoring rooms, and library. In the Annex Building the billing and accounting,ophthalmology, office, radiology, neurology, and cottage#4 were modified. Interior renovations, a new stair Tower, and decontamination showers were also part of the project's scope. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED City of Coral Gables -Continuing Service Agreement PROFESSIONAL SERVICE CONSTRUCION(If applicable) 1998-2008 c (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE •Check if project performed with current firm CSA 10 years-Leslie was PM for many of the projects performed under this agreement. Many of the projects have involved with working with local communities to develop a consensus and include public participation during the process. ELA is also involved with the alterations to all the cities parking garages, nine ADA Improvement projects, including historical facilities, the City Hall and Commission Chambers. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED Baptist Health BHE—Prototype Family Clinic PROFESSIONAL SERVICE CONSTRUCION(If applicable) West Kendal Baptist Hospital,Miami Dade County 2010 2011 d (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE •Check if project performed with current firm Project Manager—The 5000sf facility is a"State of the Art Family Medicine Center"-FMC and is designed as a teaching facility that treats all groups of patients, Mother, Baby, Kids health, Teen Health,Adult Health and Senior Health. The facility incorpo- rates the ACGME–Accreditation Council for Graduate Council Medical Education and the Baptist Health Requirements into the (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED Park Plaza Medical Arts Office Building PROFESSIONAL SERVICE CONSTRUCION(If applicable) Park Plaza-Pembroke Pine Florida 2005-2006 e (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE ECheck if project performed with current firm PM - ELA provided the design, construction documents and will provide the Construction Administration Services for The project. The Park Plaza Medical Arts Building facilities is a 160,000 SF MAB with a 800 car parking garage. The building is designed with a steel reinforced structure and the parking garage is design with a concrete component systems. Section E Architect Completed GSA Standard Form 330 E. RESUMES OF KEY PERSONNEL PROPOSED FOR THIS CONTRACT (Complete one Section E for each key person.) 12.NAME— 13.ROLE IN THIS CONTRACT 14.YEARS EXPERIENCE Yolanda Frebres Project Architect a.TOTAL b.WITH CURRENT FIRM 18 4 15.FIRM NAME AND LOCATION(CITY and STATE) Edward Lewis Architects, Inc. -Coral Gables, FL 16.EDUCATION(DEGREE AND SPECIALIZATION) 17.CURRENT PROFESSIONAL REGISTRATION(STATE AND DISCIPLINE) Universidad del Zulia, Maracaibo,Venezuela. 1994-1996 Architect and Engineer Master of Architecture Universidad de los Andes,Merida NCARB Registration in Process Venezuela.1985-1990 Bachelor of Architecture 18.OTHER PROFESSIONAL QUALIFICATIONS(Publications,Organizations,Training,Awards,etc.) Yolanda is a project architect—project manager at ELA and has been working in a variety of Healthcare and Institutional projects. She is currently managing the development of construction documents of a variety of projects under our Continuing Service Agreements. including Medical Offices for West Kendall Medical Arts Building and other medical related projects.Yolanda has worked on ELA's continuing service agreements with Baptist Health,and the City of Coral Gables 19. RELEVENT PROJECTS (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED Baptist Health BHE—Continuing Service Agreement PROFESSIONAL SERVICE CONSTRUCION(If applicable) 2007-2014 2007-2011 a (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE •Check if project performed with current firm Yolanda has been the project manager and project architect over 15 projects under this agreement.These projects include various Clinical, Medical Office and Minor Hospital renovations, additions,ADA upgrades, and new construction projects. Each project has been completed with a minimum of change orders and within the established budget. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED City of Coral Gables PROFESSIONAL SERVICE CONSTRUCION(If applicable) Continuing Service Agreement 2002-2012 b (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE IIICheck if project performed with current firm CSA 10 years–Yolanda was PA for many of the projects performed under this agreement. Many of the projects have involved with working with local communities to to develop a consensus and include public participation during the process. ELA is also involved with the alterations to all the cities parking garages, nine ADA Improvement projects, including historical facilities, the City Hall and Commission Chambers. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED Baptist Health BHE—Prototype Family Clinic PROFESSIONAL SERVICE CONSTRUCION(If applicable) West Kendal Baptist Hospital, Miami Dade County 2010 2011 c (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE ■Check if project performed with current firm Project Architect—The 5000sf facility is a"State of the Art Family Medicine Center"-FMC and is designed as a teaching facility that treats all groups of patients, Mother, Baby, Kids health, Teen Health,Adult Health and Senior Health. The facility incorporates the ACGME–Accreditation Council for Graduate Council Medical Education and the Baptist Health Requirements into the program. (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED UHZ Sports Medicine Institute-Orthopedic Suite PROFESSIONAL SERVICE CONSTRUCION(If applicable) West Kendal Baptist Hospital-MAB 2010 2012 d (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE •Check if project performed with current firm Project Architect-The 6000sf orthopedic clinic includes 10 Exam Rooms with View Boxes, space for 6 Trainer,X Ray Room Area and X Ray Waiting Room, Cast Room, Centralize Storage Area, General storage through out,Administrative Area, Check Out Area, Operator Switch Board Room and 3 Physicians Office with Physicians Administrative Assistant (1)TITLE AND LOCATION(City and State) (2)YEAR COMPLETED ENT of South Florida PROFESSIONAL SERVICE CONSTRUCION(If applicable) West Kendal Baptist Hospital-MAB 2010 2011 e (3)BREIF DESCRIPTION(Brief Scope,size,cost,etc)AND SPECIFIC ROLE ECheck if project performed with current firm Project Architect—The offices are to be located at the West Kendal Baptist Hospital-Medical Arts Building. The clinic is 5459 sf and includes. Doctors Offices, Scheduling Offices, 4 Exam Rooms, 4 Microscope procedure Rooms, Internal waiting areas, scheduling areas, an Audio Testing Room, Nurses Station for 4 people adjacent to the exam rooms. Section E Architect Completed GSA Standard Form 330 F. EXAMPLE PROJECT WHICH BEST ILLUSTRATE PROPOSED TEAM'S 20.EXAPMPLE PROJECT KEY QUALIFICATIONS FOR THIS PROJECT NUMBER (Present as many projects as requested by the agency or 10 projects, if not specific 1 Complete one section F for each project) 21.TITLE AND LOCATION(City and State) 22.YEAR COMPLETED PROFESSIONAL SERVICES CONSTRUCTION Baptist Hospital of South Florida -Continuing Service Agreement 2007-2014 23.PROJECT OWNER'S INFORMATION A.PROJECT OWNER B.POINT OF CONTACT NAME C.POINT OF CONTACT TELEPHONE NUMBER Baptist Health of South Florida James Palmieri (786)596.6074 24.BRIEF DESCRIPTION OF PROJECT AND RELEVANCE TO THIS CONTRACT(Include scope,size and cost) Baptist Health Continuing Service Agreement ,-. South Florida Working under a CSA Continuing Service Agreement- ELA is providing architectural and engineering services for various Administrative, Clinical, ,�--- Medical Office and Minor Hospital renovations, additions,ADA upgrades, and Jak u� ��, �� ' ��t: new construction projects. I • e 1, x �„ ELA has completed 64 projects under this agreement. • Human Resource Departments for West Kendal Hospital and South e project 5, f Operating Miami Hospital—rooms, patient ach wingsis, instrument comprised of processing over 500sn ad sterilization = departments, and diagnostic and CT scan facilities are among the projects completed to date. • ELA designed the office interiors for 24 tenants at the 50,000 SF West 41: , .r Kendall Baptist Hospital. • 8 AHCA reviewable projects have been completed at Doctor's Renovations Rooms 3551-3552, Instruments Sterilization Rooms, and Surgical OR 1 and 2. ~ All assignments have been completed on time and within the project budget. In addition the project required careful coordination with multiple contractors at consultants, and end user groups. • _ 25. FIRMS FROM SELECTION INVOLVED WITH THIS PROJECT (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE a. Edward Lewis Architects, Inc. Miami Florida Architecture, Leeds AP (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE b. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE C. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE d. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE e. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE Architecture F. EXAMPLE PROJECT WHICH BEST ILLUSTRATE PROPOSED TEAM'S 20.EXAPMPLE PROJECT KEY QUALIFICATIONS FOR THIS PROJECT NUMBER (Present as many projects as requested by the agency or 10 projects, if not specific 2 Complete one section F for each project) _ 21.TITLE AND LOCATION(City and State) 22.YEAR COMPLETED PROFESSIONAL SERVICES CONSTRUCTION Miami Dade County -Continuing Service Agreement 2000-2013 23. PROJECT OWNER'S INFORMATION A.PROJECT OWNER B.POINT OF CONTACT NAME C.POINT OF CONTACT TELEPHONE NUMBER Jackson Memorial Hospital Asst to Director—Pauline Alvarenga 305-585-1302 24.BRIEF DESCRIPTION OF PROJECT AND RELEVANCE TO THIS CONTRACT(Include scope,size and cost) MIAMI Continuing Service Agreement COUNTY Edward Lewis Architects was retained by Jackson Memorial Hospital for this Continuing Jackson i e Service Agreement to provide architectural services for various alteration, expansions and modifications to the main campus. Jackson's projects were complex and had very specific 11tAM"'STF,'1 design challenges. The end users had unique requirements with complex HVAC and mechanical systems, elaborate communication and security systems and other intricate engineering systems. Many of the projects included AHCA review that shaped many of the design solutions. Understanding the process was paramount in obtaining approvals in a timely ... 7. manner. ELA's healthcare work at Jackson was diverse, and included alterations to hospital I• Apiti, facilities, diagnostic facilities, lab facilities, ambulatory surgical centers, outpatient treatment facilities, emergency rooms and medical offices. Samples of ELA's designs include: • Parking Garage Improvements Campus Wide • Emergency Room CT Scan Suite Special Immunology Care Unit •WW/DTC-2 CT Scan Alteration • Special Immunology Renovation & Sprinkler Upgrade •T-1 Temporary CT Scan • Connector Bridge Accessibility Renovations • ET-1 CT Scanner • Dental Clinic Renovations • Campus Wide ADA Survey • Pediatric Emergency Room Renovations •2nd. Fl Remodel So Wing-Gastroenterology Department • Dental Rooms Renovation •2nd. Fl. Remodel So Wing- Pulmonary Lab • Ear, Nose, and Throat Clinic Renovations •2nd. Fl Remodel So Wing- Radiology Department • Penalver Clinic Renovation •2nd. Fl Remodel So Wing- Patient Recovery Area • CT Scan Alteration 25. FIRMS FROM SELECTION INVOLVED WITH THIS PROJECT (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE a. Edward Lewis Architects, Inc. Miami Florida Architecture, Leeds AP (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE b. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE C. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE d. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE e. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE f. Architecture F. EXAMPLE PROJECT WHICH BEST ILLUSTRATE PROPOSED TEAM'S 20.EXAPMPLE PROJECT KEY QUALIFICATIONS FOR THIS PROJECT NUMBER (Present as many projects as requested by the agency or 10 projects,if not specific 3 Complete one section F for each project) 21.TITLE AND LOCATION(City and State) 22.YEAR COMPLETED PROFESSIONAL SERVICES CONSTRUCTION Services with PSA—Professional Service Agreements 1998-2012 23. PROJECT OWNER'S INFORMATION A.PROJECT OWNER B.POINT OF CONTACT NAME C.POINT OF CONTACT TELEPHONE NUMBER Miami Dade County Luis Millian Donovan, RA (305) 375-1100 24.BRIEF DESCRIPTION OF PROJECT AND RELEVANCE TO THIS CONTRACT(Include scope,size and cost) MIAMI•DIADE Continuing Service Agreement ' Y M_ COUNTY ` g.,21. kr 4,1 ELA held this Professional Service Agreement from 1998 until 2007. Many of the ., Owl wi' projects had unique requirements with complex programming and planning requirements, some projects required approval from the historical boards, many of the rojects included elaborate communication and security systems and other 1 Y Y Ie intricate engineering systems. The projects and scope of work ranged from ADA Compliance issues, ADA Audits, 40 year recertification, conceptual designs, additional office spaces, remodeling, and new construction. Projects Include: h „ • Parking Garage Alterations -County Wide • Culmer/Overtown Community Center Bldg Inspection • Miami Dade Fire Rescue Station of Pinecrest • DERM Building - Roof Investigative Study • Miami Dade County Courthouse ADA Survey • New Directions Residential Treatment Center 40-Year • Miami Dade Housing Authority, UFAS Guidelines Recertification • Miami Science Museum, Renovations Planetarium • Dade County Youth Hall 40-Year Recertification • North Dade Victim's Center, ADA Renovations • North-Dade Adult Day Care Center • South Dade Adult Day Care, ADA Renovations • Electrical Shop Building Report • North Dade Adult Day Care, ADA Renovations • West-Dade Regional Library ADA • Advocates for Victims, ADA Renovations • South-Dade Victim Center Reroofing Report • Miami Dade Fleet Shop • North-Dade Victim Center Reroofing Report • • Little River Library Reroofing Report South Dade Landfill rY 9 p • South Dade Government Center, 911 Phone • Fleet Shop Analysis and Report Improvements 25. FIRMS FROM SELECTION INVOLVED WITH THIS PROJECT (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE a. Edward Lewis Architects, Inc. Miami Florida Planner, Architecture, Leeds AP (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE b. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE C. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE d. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE e. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE Architecture F. EXAMPLE PROJECT WHICH BEST ILLUSTRATE PROPOSED TEAM'S 20.EXAPMPLE PROJECT KEY QUALIFICATIONS FOR THIS PROJECT NUMBER (Present as many projects as requested by the agency or 10 projects, if not specific 4 Complete one section F for each project) 21.TITLE AND LOCATION(City and State) 22.YEAR COMPLETED PROFESSIONAL SERVICES CONSTRUCTION Miami Dade College 2008-2012 23. PROJECT OWNER'S INFORMATION A.PROJECT OWNER B.POINT OF CONTACT NAME C.POINT OF CONTACT TELEPHONE NUMBER MDC Gloria Garzon (305) 876-7565 24.BRIEF DESCRIPTION OF PROJECT AND RELEVANCE TO THIS CONTRACT(Include scope,size and cost) li/r11 PSA ADA Restroom Alterations Miami Dade Rolle e And Expansion * g ELA performed 34 ADA restroom alteration projects through a Professional Service Agreement. ELA provided ADA studies and reports for the for the following cam- puses- Wolfson, Kendall, Hialeah, Homestead, Inter-American, North,West, and Medical School campus. The project,which included 34 restroom facilities, required reconfigurations to ad- just wall and partition heights and widths as well as new finishes. The assignment, 1,14%.„,",4 which represents one of several projects that ELA has designed for this owner,was * F completed on time and in budget and required careful coordination with multiple contractors, consultants, and end user groups. •, A i„ 25. FIRMS FROM SELECTION INVOLVED WITH THIS PROJECT (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE a. Edward Lewis Architects, Inc. Miami Florida Planner, Architecture, Leeds AP (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE b. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE c. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE d. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE e. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE f. Architecture F. EXAMPLE PROJECT WHICH BEST ILLUSTRATE PROPOSED TEAM'S 20.EXAPMPLE PROJECT KEY QUALIFICATIONS FOR THIS PROJECT NUMBER (Present as many projects as requested by the agency or 10 projects, if not specific 5 Complete one section F for each project) 21.TITLE AND LOCATION(City and State) 22.YEAR COMPLETED West Kendall Baptist Hospital -Medical Arts Building PROFESSIONAL SERVICES CONSTRUCTION 2010-2012 23.PROJECT OWNER'S INFORMATION A.PROJECT OWNER B.POINT OF CONTACT NAME C.POINT OF CONTACT TELEPHONE NUMBER Baptist Health James Palmieri (786) 374-3836 24.BRIEF DESCRIPTION OF PROJECT AND RELEVANCE TO THIS CONTRACT(Include scope,size and cost) Baptist Health Projects Completed South Florida • WK MAB OBGYN ELA was selected to provide programming, space planning and interior architec- • WK MAB Eye Care for excellence tural services for the 60,000sf interior project. • WK MAB Fertility Suite 306 • WK MAB Pulmonary Offices Suite 305 ELA provided designs for the placement of the buildings corridors and common • WK MAB Family Medicine Clinic areas.The design reduced the common area factor by 10%During the tenant plan- • WK MAB Time Share ping phase ELA preformed the programming and design for 22 unique tenants for the facility. • WK MAB Admin Office • WK MAB Pharmacy and Latte da The projects were designed and constructed in a fast pace manner during a one • WK MAB ENT of S.F year period.The phasing allowed for a number of projects to be designed and con- • WK MAB GI Care Center structed at the same time. The projects included a full range of medical office types • WK MAB Dr.Verdeja Surgery Group as listed • WK MAB Heartwell—Dr Fialkow • WK MAB Perinatal Suite Su to 301 • tr • WK MAB UHZ Sports Medicine• •Y g'� I. • WK MAB UHZ Rehab Clinic • WK MAB South Florida Center for Repro- •I ductive Medicine .4 i .. • WK MAB UHZ Sports Medicine Rehab B r . ;k; gip; • i _ i ti • WK MAB Pharmacy I I ~ ,` • WK MAB Coffee Shop _. _ f� ,t ,_�i 1-1, ' .`• • WK MAB Time Share I I -- /,. . • WK MAB FIU Medical Offices 25. FIRMS FROM SELECTION INVOLVED WITH THIS PROJECT (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE a. Edward Lewis Architects, Inc. Miami Florida Planner, Architecture, Leeds AP (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE b. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE c. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE d. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE e. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE f. Architecture F. EXAMPLE PROJECT WHICH BEST ILLUSTRATE PROPOSED TEAM'S 20.EXAPMPLE PROJECT KEY QUALIFICATIONS FOR THIS PROJECT NUMBER (Present as many projects as requested by the agency or 10 projects, if not specific 6 Complete one section F for each project) 21.TITLE AND LOCATION(City and State) 22.YEAR COMPLETED Continuing Service Agreement-Miami Children's Hospital PROFESSIONAL SERVICES CONSTRUCTION N/A 23. PROJECT OWNER'S INFORMATION A.PROJECT OWNER B.POINT OF CONTACT NAME C.POINT OF CONTACT TELEPHONE NUMBER Miami Children's Hospital Robert Nowlan (305) 668.5519 24.BRIEF DESCRIPTION OF PROJECT AND RELEVANCE TO THIS CONTRACT(Include scope,size and cost) ,rifir-11 !Air Continuing Service Agreement MIAMI r CHILDREN'S Working under a Continuing Services Agreement, ELA provided architectural and engineering services for various renovations, additions, and ADA upgrades. One of the HOSPITAL., goals of the hospital was to relocate administrative functions off site to free up areas for clinical operations, teaching, and research functions. Among the modified areas were the Research Building's boardroom, reception area, simulation emergency lab, monitoring rooms, and library. In the Annex Building the billing and accounting, ophthalmology, office, radiology,gy, gy, and cottage#4 were modified. Interior renovations, a new stair Tower, and decontamination showers were also part of the project's scope. All assignments were completed on time and within budget and i required careful coordination with multiple contractors, consultants, and end user I groups. • Research Building-Boardroom • Radiology • • Research Building-Reception Desk • Neurology • Research Building-Simulation Emergency Lab • Cottage#4 • Teaching Facility and Monitoring Rooms • S.Dade Master Site Plan • Research Building-Library • Campus Wide Hurricane Analysis • Annex Building Billing and Accounting • Neurology-Department Interior Renovations r 'S- • Miami Children's Annex • MRI Stair Tower • Ophthalmology Office • Decontamination Showers • 25. FIRMS FROM SELECTION INVOLVED WITH THIS PROJECT (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE a. Edward Lewis Architects, Inc. Miami Florida Architecture, Leeds AP (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE b. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE C. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE d. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE e. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE f. Architecture F. EXAMPLE PROJECT WHICH BEST ILLUSTRATE PROPOSED TEAM'S 20.EXAPMPLE PROJECT KEY QUALIFICATIONS FOR THIS PROJECT NUMBER (Present as many projects as requested by the agency or 10 projects,if not specific 7 Complete one section F for each project) 21.TITLE AND LOCATION(City and State) 22.YEAR COMPLETED PROFESSIONAL SERVICES CONSTRUCTION Continuing Service Agreement-City of Coral Gables, FL N/A 23. PROJECT OWNER'S INFORMATION A.PROJECT OWNER B.POINT OF CONTACT NAME C.POINT OF CONTACT TELEPHONE NUMBER City of Coral Gables Lis Ferrer (305)460-5080 24.BRIEF DESCRIPTION OF PROJECT AND RELEVANCE TO THIS CONTRACT(Include scope,size and cost) 441-0111* .. +' r, :i ^` ay ■ 1{�dl yam__ - ,� s Continuing Service Agreement - �=-° —: Edward Lewis Architects has worked with for the City of Coral Gables . for a period of over 10 years. ELA was selected thru a short list process a 1 for a PSA- Professional Service Contract with Public works, under this . agreement ELA has performed over 30 municipal projects. Many of the ■ = ,`. . projects have involved with working with local communities to develop a consensus and include public participation during the process. ELA is also involved with the alterations to all the cities parking garages, nine ADA Improvement projects, including historical facilities, the City Hall and Commission Chambers, the redesign and remodeling of their downtown Police and Fire station.ELA provide space planning services for the first major remodeling of this 81,000 square foot Fire and Police space since its construction over 20 years ago. This involves improving the existing security, and redesigning the space to function more efficiently and accommodate future growth. Projects Included: • Parking Garage-245 Andalusia-ADA Improvements • Coral Bay Park • Public Work Corporate Offices • Parking Garage 4 385 Andalusia-ADA Improvements • Coral Bay Park Shelter • Ruth B Owen Park • Coral Gables City Hall-ADA Historic Renovations • Jaycee Park • Youth Center ADA • Granada Pro-Shop-ADA Alterations • Fire& Police Station Alterations • Miracle Mile Due Diligence • 475 Biltmore Way Report • Police&Fire ADA(II) Report • 475-495 Biltmore Way Report • Kings Bay Guardhouse 25. FIRMS FROM SELECTION INVOLVED WITH THIS PROJECT (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE a. Edward Lewis Architects, Inc. Miami Florida Planner, Architecture, Leeds AP (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE b. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE C. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE d. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE e. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE f. Architecture F. EXAMPLE PROJECT WHICH BEST ILLUSTRATE PROPOSED TEAM'S 20.EXAPMPLE PROJECT KEY QUALIFICATIONS FOR THIS PROJECT NUMBER (Present as many projects as requested by the agency or 10 projects,if not specific 8 Complete one section F for each project) 21.TITLE AND LOCATION(City and State) 22.YEAR COMPLETED PROFESSIONAL SERVICES CONSTRUCTION PSA—Professional Service Agreement-Miami Beach, FL N/A 23. PROJECT OWNER'S INFORMATION A.PROJECT OWNER B.POINT OF CONTACT NAME C.POINT OF CONTACT TELEPHONE NUMBER City of Miami Beach Jorge Chartrand (305)673-7071 24.BRIEF DESCRIPTION OF PROJECT AND RELEVANCE TO THIS CONTRACT(Include scope,size and cost) MIAMIBEACH PSA 1 J /A I /7 IT Tc 41d ti! r1? The City of Miami Beach retained Edward Lewis Architects to provide Designs and Studies throughout the city of Miami Beach. Projects Include: • Miami Beach Rotunda Alterations • Miami Beach Miami Beach Library Demo fi • Miami Beach Bayshore Golf Course Fence ELA also served as architect to provide the$1.2 million dollar- Bayshore Golf Course Fence for The City of . r ' 4 v { nas Miami Beach. The project will be comprised of: The design of the fence with related landscaping around the perimeter of Bayshore Golf Course. The fence circumference is approximately 13,500 LF. • Miami Beach Rotunda Study ELA served as architect to provide alterations and code up-grades to the existing facility, furthermore, the program required ELA to redesign the facility as a multi-use building, i.e. Art Gallery, *- Meeting Space, Lecture use and for Theatrical usages. The refurbished Rotunda Building will provide the City of Miami Beach with a flexible multi use space that can be used by a number of City or public groups. 1 25. FIRMS FROM SELECTION INVOLVED WITH THIS PROJECT (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE a. Edward Lewis Architects, Inc. Miami Florida Planner, Architecture, Leeds AP (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE b. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE C. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE d. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE e. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE f. Architecture F. EXAMPLE PROJECT WHICH BEST ILLUSTRATE PROPOSED TEAM'S 20.EXAPMPLE PROJECT KEY QUALIFICATIONS FOR THIS PROJECT NUMBER (Present as many projects as requested by the agency or 10 projects, if not specific 9 Complete one section F for each project) 21.TITLE AND LOCATION(City and State) 22.YEAR COMPLETED GSA Continuing Services Contract PROFESSIONAL SERVICES CONSTRUCTION N/A 23.PROJECT OWNER'S INFORMATION A.PROJECT OWNER B.POINT OF CONTACT NAME C.POINT OF CONTACT TELEPHONE NUMBER GSA Luisa Milian (305) 375-1125 24.BRIEF DESCRIPTION OF PROJECT AND RELEVANCE TO THIS CONTRACT(Include scope,size and cost) Edward Lewis Architects was selected by the General Services Administration to perform architectural and engineering services throughout Miami Dade County. ELA held this continuing services contract from 1998 until 2007. The projects and scope of work ranged from ADA Compliance issues, 40 year recertification, additional office ii,inF CO( r^�r spaces, remodeling, and new construction. g ; FJRERESCLIEDE•Af?,Tr ylENT Project Cost: $5 Million Projects Include: I11!a s � • Miami Dade Fire Rescue Station of Pinecrest • Miami Dade County Courthouse ADA Survey • Miami Dade Housing Authority, UFAS Guidelines • Miami Science Museum,ADA Renovations Planetarium • North Dade Victim's Center,ADA Renovations miamdade • South Dade Adult Day Care,ADA Renovations • North Dade Adult Day Care,ADA Renovations • Advocates for Victims,ADA Renovations • Miami Dade Fleet Shop • South Dade Landfill • South Dade Government Center, Phone Improvements • 40 Year Recertification for Dade County Youth Hall • Disability Services and Independent Living,ADA Renovations 25. FIRMS FROM SELECTION INVOLVED WITH THIS PROJECT (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE a. Edward Lewis Architects, Inc. Miami Florida Planner, Architecture, Leeds AP (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE b. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE c. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE d. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE e. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE f. Architecture F. EXAMPLE PROJECT WHICH BEST ILLUSTRATE PROPOSED TEAM'S 20.EXAPMPLE PROJECT KEY QUALIFICATIONS FOR THIS PROJECT NUMBER (Present as many projects as requested by the agency or 10 projects, if not specific 10 Complete one section F for each project) 21.TITLE AND LOCATION(City and State) 22.YEAR COMPLETED Broward County Public Schools Continuing Services Contract PROFESSIONAL SERVICES CONSTRUCTION N/A 23.PROJECT OWNER'S INFORMATION A.PROJECT OWNER B.POINT OF CONTACT NAME C.POINT OF CONTACT TELEPHONE NUMBER Broward County Public Schools Shelley Meloni (954) 765-6387 24.BRIEF DESCRIPTION OF PROJECT AND RELEVANCE TO THIS CONTRACT(Include scope,size and cost) 1 ... I .- :-T ,_.7.4--. Broward Coun _-__ „ , ,..., F 1 - VW—Public SchaoIs , _ _...._ Edward Lewis Architects was selected by the School Board of Broward County for eight years to serve a continuing services r. contract providing architectural and engineering services for local Elementary, Middle School and High Schools. The pro- 4` jects included the renovation and upgrade of existing labora- Ir 4 tory facilities and the conversion of existing spaces into new state-of-the-art Educational Training Centers. ELA has reno- • : vated and adapted new uses to provided the school board with _.� `"' the most additional academic spaces available. The projects also involve general interior renovations including new class- rooms, storage rooms, ceiling systems, storage rooms, lighting and general interior finishes. x illik Project Cost: $3 Million 25. FIRMS FROM SELECTION INVOLVED WITH THIS PROJECT (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE a. Edward Lewis Architects, Inc. Miami Florida Planner, Architecture, Leeds AP (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE b. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE c. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE d. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE e. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE f. Architecture F. EXAMPLE PROJECT WHICH BEST ILLUSTRATE PROPOSED TEAM'S 20.EXAPMPLE PROJECT KEY QUALIFICATIONS FOR THIS PROJECT NUMBER (Present as many projects as requested by the agency or 10 projects, if not specific 11 Complete one section F for each project) 21.TITLE AND LOCATION(City and State) 22.YEAR COMPLETED Miami Dade County Parks& Recreation Continuing Services Contract PROFESSIONAL SERVICES CONSTRUCTION N/A 23.PROJECT OWNER'S INFORMATION A.PROJECT OWNER B.POINT OF CONTACT NAME C.POINT OF CONTACT TELEPHONE NUMBER Miami Dade County Bill Cutie (305) 533-2026 24.BRIEF DESCRIPTION OF PROJECT AND RELEVANCE TO THIS CONTRACT(Include scope,size and cost) MIAMI ' MtAM METRO cOUNTr ZOO4'r _ Edward Lewis Architects was selected by the Miami Dade County Parks Department to provide architectural and engineering services through a continuing services contract. Scope of • the services provided ranged from small to large scale park projects. 7. ,�— �- ,� Project Cost: $15 Million ti r-.*, !!• � Projects Included: ,A16. tri 110 National Football League YET Center at Gwen Cherry Park • Goulds Recreation Center ' Baseball Hall of Fame Carol City YET Center at Moore Park _ r MetroZoo PAWS • ..,� West Perrine Park ���� Jefferson Reaves Community Center Grapeland Park Devonaire Park 25. FIRMS FROM SELECTION INVOLVED WITH THIS PROJECT (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE a. Edward Lewis Architects, Inc. Miami Florida Planner, Architecture, Leeds AP (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE b. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE c. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE d. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE e. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE f. Architecture F. EXAMPLE PROJECT WHICH BEST ILLUSTRATE PROPOSED TEAM'S 20.EXAPMPLE PROJECT KEY QUALIFICATIONS FOR THIS PROJECT NUMBER (Present as many projects as requested by the agency or 10 projects, if not specific 12 Complete one section F for each project) 21.TITLE AND LOCATION(City and State) 22.YEAR COMPLETED Miami Dade County Parks & Recreation Continuing Services Contract PROFESSIONAL SERVICES CONSTRUCTION N/A 23.PROJECT OWNER'S INFORMATION A.PROJECT OWNER B.POINT OF CONTACT NAME C.POINT OF CONTACT TELEPHONE NUMBER Miami Dade County Bill Cutie (305) 533-2026 24.BRIEF DESCRIPTION OF PROJECT AND RELEVANCE TO THIS CONTRACT(Include scope,size and cost) ,m,1,11, MIAMI ,NITER NATIONAL AIRPORT St a Edward Lewis Architects was selected by the Miami Dade Aviation Department to provide architectural and engineering services under a professional services agreement on various projects througout Miami International Airport. The professional services agreement was completed in 2007. Project Cost: $90 Million Projects Include: • Comprehensive building analysis, code review, ADA analysis for Building 100 at MIA. • Design services for the$24 Million Dollar terminal modifications for security upgrades at MIA. • Sixteen new security equipment centers, connected by a new fiber option cabling system loop. 25. FIRMS FROM SELECTION INVOLVED WITH THIS PROJECT (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE a. Edward Lewis Architects, Inc. Miami Florida Planner, Architecture, Leeds AP (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE b. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE C. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE d. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE e. (1)FIRM NAME (2)FIRM LOCATION(City and State) (3)ROLE Architecture G.KEY PERSONNEL PARTICIPATION IN EXAMPLE PROJECTS 26. NAMES OF KEY 27. ROLE IN THIS 28. EXAMPLE PROJECTS LISTED IN SECTION F PERSONNEL CONTRACT (Fill in"Example Projects Key"section below before completing table. Place"X"under project key number for participation in same or similar role.) (From Section E, Block 12) (From Section E, Block 13) 1 2 3 4 5 6 7 8 9 10 Principal, Designer,Quality X X X/ X X/ X/ X X/ X/ X/ Edward Lewis,AIA LEEDS Controls /� /� /� /� /� /� Krista Lewis,VP Project Manager / \ \ X \ X\ / \ X \ X X Leslie Escobar Project Manager X\ X \ X\ \ X X X X X \ Yolanda Ferbes Project Architect X\ X X X X X X / \ X\ X 29. EXAMPLE PROJECTS KEY NO. TITLE OF EXAMPLE PROJECT(FROM SECTION F) NO. TITLE OF EXAMPLE PROJECT(FROM SECTION F) 1 Baptist Health of South Florida 6 Miami Childrens Hospital 2 Jackson Memorial Hospital 7 City of Coral Gables 3 Miami Dade County GSA 8 City of Miami Beach 4 Miami Dade College 9 GSA Miami Dade County 5 West Kendall Baptist Hospital -MAB 10 Broward County Public Schools STANDARD FORM 330(REV.3/2013)PAGE 4 H.ADDITIONAL INFORMATION 30.PROVIDE ANY ADDITIONAL INFORMATION REQUESTED BY THE AGENCY.ATTACHED ADDITIONA SHEETS AS NEEDED Interior Architecture ELA's has been recognized within the industry as a leader in facili- ties planning and interior architecture. ELA's Facilities Management, data gathering, fixed asset control process will support ongoing man- - agement requirements. This process allows each design project to I�' meet the client's program requirements,time schedules and budget. MThe firm's philosophy imbeds the ideas that the implementation of in- depth strategic plan, branding, streamline design programs, and __ . I good design practices reinforce long and short range planning ...-�` goals. From architectural space planning to color and materials se- .q;l lection, design excellence in interior spaces affects the functionality .:! of a company as well as the image the company and project wants E< t -. to convey. Whether a fortune 500 companies, a local corporation, health care facility, restaurant, retail space or school, interior design is the key to how the users of each space feels, acts and thinks. ELA Interiors utilizes a mix of creativity and understanding of func- tions and uses to create a look and layout that works, and works well. ELA designs millions of square feet annually for our institutional Iand commercial clients. ';iii_ I • ELA is an expert in facility designs and has a successful history of ;Al meeting schedules and deadlines •itii/iit. Ili l o/1oz; ..e� ELA. has designed millions square feet of interiors projects for fi- nancial, commercial and healthcare of building interiors. ELA design i4ialemr. .... .lorilti dirmr. projects includes: • Citibank Latin America Headquarters-Y2K and Communica- tions Center 46,000 square feet. • Washington Mutual Bank Regional Headquarters- 100,000 square feet, Lake Worth. • Gardner Group Headquarters-42,000 square feet software and data center. Illik • Cunard Cruise Line Corporate Headquarters-45,000 square feet. • MARS Musicians Planet Regional Distribution and Data Center- 20,000 square feet. • Kislak Bank-75,000 square foot Corporate Headquarters and 3,000 square foot Data Center. Architectural Interiors is a tool that many companies use to convey an image and assist in organizing their operations for effective and - efficient operations. ELA understands the principles behind good interior architecture and y.. implements special architectural space planning practices, the use of 1 color and material selections, and creative interior spaces to achieve the goals of the end users. ELA Interiors utilizes a mix of creativity and understanding of functions to create a look and layout that meets the parameters of excellent design and creativity. Section H Completed GSA Standard Form 330 H.ADDITIONAL INFORMATION 30.PROVIDE ANY ADDITIONAL INFORMATION REQUESTED BY THE AGENCY.ATTACHED ADDITIONA SHEETS AS NEEDED f _ a Specialty Interior Architecture Specialty Interior Architecture Many of ELA Interior architectural projects are complex and have very specific design challenges. They involve end users with unique requirements, complex HVAC and mechanical systems, elaborate communication and security systems and other intricate engineering systems. Understanding the process is paramount in obtaining approvals in a timely manner. Imo ELA believes that the implementation of in-depth strategic plan, branding, streamline design programs, and good design practices reinforce long and short range planning goals. From architectural space planning to color and materials selection, design excellence in interior spaces affects the functionality of a company as well as the image the company and project is to convey. Whether a fortune • 500 company, a local corporation, health care facility, restaurant, retail space or school, interior design is the key to how the users of your space feel, act and think. ELA Interiors utilizes a mix of creativity and understanding of func- tions and uses to create a look and layout that works, and works well. ELA designs millions of square feet annually for our institu- tional, and commercial clients. ELA is an expert in facility designs mA and has a successful history of meeting schedules and deadlines. I.AUTHORIZED REPRESENTATIVE The foregoing is a statement of facts 31. ATURE 32.DATE 10/25/2014 33.NAME AND TITLE Edward Lewis,Al , Leeds AP President/Secretary Section H Completed GSA Standard Form 330 1.SOLICITATION NUMBER (If any) ARCHITECT-ENGINEER QUALIFICATIONS PART II - GENERAL QUALIFICATIONS (If a firm has branch offices, complete for each specific branch office seeking work. 2a.FIRM(OR BRANCH OFFICE)NAME 3.YEAR ESTABLISHED 4.DUNS NUMBER Edward Lewis Architects, INC 1987 612784355 2b.STREET 5.OWNERSHIP 2100 Ponce de Leon BLVD, Suite 825 a.TYPE 2c.CITY 2d.STATE 2e.ZIP CODE Corporation Coral Gables FL 33134 b.SMALL BUSINESS STATUS 6a.POINT OF CONTACT NAME AND TITLE CBE Edward Lewis AIA LEED AP- Principal 7.NAME OF FIRM (If block 2a is a branch office) 6b.TELEPHONE NUMBER 6c.E-MAIL ADDRESS 305-234-0756 elewis @elamiami.com Edward Lewis Architects, INC 8a.FORMER FIRM NAME(S) (If any) 8b.YR.ESTABLISHED 8c.DUNS NUMBER 9. EMPLOYEES BY DISCIPLINE 10. PROFILE OF FIRM'S EXPERIENCE AND ANNUAL AVERAGE REVENUE FOR LAST 5 YEARS a.Function c. No.of Employees a.Profile c.Revenue Index b. Discipline b.Experience Number Code (1)FIRM (2)BRANCH Code (see below) 02 Administrator 1 06 Architecture 04 06 Architect 4 Interior Architecture Administration Other Employees Total 5 11.ANNUAL AVERAGE PROFESSIONAL PROFESSIONAL SERVICES REVENUE INDEX NUMBER SERVICES REVENUES OF FIRM FOR LAST 3 YEARS 1. Less than$100,000 6. $2 million to less than$5 million (Insert revenue index number shown at right) 2. $100,00 to less than$250,000 7. $5 million to less than$10 million a. Federal Work 3. $250,000 to less than$500,000 8. $10 million to less than$25 million b. Non-Federal Work 4. $500,000 to less than$1 million 9. $25 million to less than$50 million c.Total Work 5. $1 million to less than$2 million 10. $50 million or greater 12.AUTHORIZED REPRESENTATIVE The foregoing is a statement of facts. a.SIGN R b.DATE 10/24/2014 c.NAME AND TITLE Edward Lewis AIA LE D AP- Principal AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 330(REV.3/2013)PAGE 6 I E [ A ARCHITECTURE PLANNING INTERIOR CONSTRUCTION SERVICES edward lewls architects ARCHITECT EDWARD LEWIS ARCHITECTS, INC Edward Lewis Architects is based in Miami, Florida and is a multi disciplinary _ • design firm that has provided Architectural Services for more than 10 million ' 1 4 ----- `-'-- square feet of commercial and institutional projects in 7 countries. With over - I(' i ; -I 1 three decades of healthcare experience. ELA has specialized in long-term pro- 0 fessional service agreements and through Continuing Services Contracts with V the following faculties agencies and municipalities: 9 9 P s • Continuing Service Agreement with the State of Florida 'rte f - • City of Miami Beach Continuing Services Contract • GSA Continuing Services Contract for Miami Dade County s ''#, • Miami Dade College Continuing Services Contract • Broward County Public Schools Continuing Services Contract NAME OF FIRM • Miami Dade County Parks&Recreation Continuing Services Contract Edward Lewis Architects,Inc. LOCATION OF PRINCIPAL OFFICE • Miami Dade County PSA-GSA 2100 Ponce de Leon BLVD Coral Gables,FL 33134 y Suite 825 • Miami Dade County PSA-Public Works LENGTH OF TIME IN BUSINESS 27 YEARS • Coral Gables Continuing Service Agreement-Public Works OWNERSHIP STRUCTURE Sub Chapter S • Baptist Health of Florida Continuing Service Agreement NUMBER OF EMPLOYEES - 5 • Jackson Memorial Hospital Continuing Service Agreement COPY OF AUDITED FINANCIAL STATEMENT See attached LITIGATION HISTORY IN LAST FIVE YEARS • Miami International Airport Continuing Services Contract None y9 D) 40 IA ,tip w , ,, 4.,1„ ter r ,r KEY PERSONNEL ELA's staff and consultants have substantial experience with Health Care clinics. The team members understand the dynamics and regulations that drive the projects and the nuts and bolts aspects required to successfully complete the job. In addition, all team members are versed with the Florida Building Code, Grant Applications, NFPA Florida Fire Prevention Code, in- cluding the Broward County Amendments; all ADA requirements and local planning and development procedures. 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 A RCHITECTURE E LI A PLANNING INTERIOR CONSTRUCTION SERVICES R edward 'awls archit•ct■ ELA's staff and consultants have considerable experience with healthcare projects. The team members understand the dynamics and regulations that drive the projects and the nuts and bolts aspects required to successfully complete the job. In addition, all team members are versed with the Florida Building Code, the 2007 Florida Fire Prevention Code, including the Broward County Amendments; all ADA requirements and local planning and development procedures. Following is a brief introduction of the key team members. Detailed resumes are included in GSA Standard Form 330. Edward Lewis,AIA, LEED AP Principal in Charge,Design As Principal-in-Charge of ELA, Edward Lewis directs all day-to-day business activities of the firm in- cluding strategic planning, operations, finance, administration, technical training, and business devel- opment. He will be the primary point of contact for all design and construction administration, providing £' direction and oversight to the assigned staff, engineers, and accessibility consultant. Known as a hands-on leader, and commitment to exceptional client service, remain engaged through all phases of the project to ensure design, schedule, and quality expectations are met and contractual obligations are delivered. Professional Experience—Ed has more than 35 years of experience, working his way up the ranks to his current role as President of an 8 person design firm. Since 1978, he has been actively involved with designing a myriad of healthcare facilities including new hospitals, diagnostic facilities, laborato- ries, ambulatory surgical centers, outpatient treatment facilities, emergency rooms, and medical office buildings. This expertise, coupled with his thorough knowledge of the Florida Building Code, and cur- rent work on a number of AHCA projects for notable South Florida institutions and healthcare provid- ers, make him a valued team asset. Leslie Escobar Project Manager Leslie is a senior project manager at ELA and is responsible for managing the day to day activities of each project. She is one of the main contacts at ELA with the client and the construction manager. She is responsible for coordinating the project meetings with the consultants, and the contractor and documenting important project communications and the project meetings. Leslie is part of the staff assembling the contract documents and oversees the project architects within ELA. Professional Experience - Leslie has successfully managed a variety of Professional Service Agree- ment projects and Institutional projects. She is currently working with ELA staff on a variety of Projects for MDHA, Miami Dade Community College, Baptist Hospital, Miami Dade County and The School Board of Broward County. Krista Lewis,VP Project Manager Krista is trained and study as an interior designer. She has served as a project architect for a Profes- sional Service Agreements. During the last five years she has participated as designer or as project architect on over ELA 120 projects. Krista has successfully managed a variety of Professional Service Agreement projects and Institutional projects. She is currently working with ELA staff on a variety of Projects for MDHA, Miami Dade Community College, Baptist Hospital, Miami Dade County and The School Board of Broward County. Yolanda Frebres Project Architect Aft Yolanda is a senior project architect at ELA and is responsible for production drawings of each project. She is responsible for coordinating and producing the construction documents. Yolanda is part of the staff assembling the contract documents and oversees the project architects within ELA. Yolanda has successfully managed a variety of Professional Service Agreement projects and Institutional projects. She is currently working with ELA staff on a variety of Projects for MDHA, Miami Dade Community College, Baptist Hospital, Miami Dade County and The School Board of Broward County. 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 ELIA ARCHITECTURE PLANNING INTERIOR CONSTRUCTION SERVICES 1 edwsrd lards architects 03:1 EDWARD LEWIS ARCHITECTS Edward Lewis, AIA LEED Principal In Charge Architecture + QA/QC '{' Edward Lewis,AIA Leslie Escobar Cost Management ---- Project Manager LEED Documentation Edward Lewis Architects Yolanda Frebres Project Architect --_ 'I Krista Lewis,VP Project Manager ' `" 1111W W' 11111.11Wr WIMP IIF I- Structural Engineer MEP Engineer Landscape Architect 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 LELA ARCHITECTURE PLANNING LIDINTERIOR CONSTRUCTION SERVICES adwsrd lards srchlt•cts Supplier Qualification Receipt • Dun & Bradstreet Government Solutions D&B Contractor Management Portal Decide with Confidence smr► Step 3 of 3 View Registration Status 1 Find Your Company D&B Supplier Certification Receipt 2 Provide Payment Date Time Company 134J-N-S Product Cost information 11- 09:40:57 EDWARD 015570692 Supplier Sub $91.95 01- LEWIS Portal Total 3 View Registration Status 2014 ARCHITECTS Registration INC. Product- Yearly Tax $0.00 Total Cost $91.95 For further information or clarification Please contact our Customer Resource Group by clicking on the Customer Support link at the bottom of the page. Print Back Customer Support Privacy Policy Help To progress through the portal,use Powered By Dpi• the available navigation buttons.too not use the back or forward buttons on your browser window 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 ELIA ARCHITECTURE PLANNING Approach and Methodology 1r--1 INTERIOR CONSTRUCTION SERVICES edward !awls Urchltects a iii..i4 I - ,„, „I 11 1 . I ft I lr"dg___It— .11111161. = = -_ j - r Past Record Past Record on Ability to Perform Edward Lewis Architects, Inc is dedicated to providing quality designs and services. Our past record indicates that our services have continued to meet stringent schedules and design parameters. Our team has the requisite ex- perience and the capacity necessary to professionally execute the projects specified. Codes Knowledge of Laws, Codes and Permitting Procedures- Edward Lewis Architects has maintained a continuing educational process to remain current with the changes in the building code, the laws and proce- dures within building departments, and AHCA regulations. Edward Lewis was appointed Chairman of the Building Process Committee of the American Institute of Architects, part of his responsibilities included reviewing and rec- ommending changes to the Florida Building Code. Management Approach Management Approach Our organization for this project will be simple and direct each member team has unique responsibilities for their area of assignment during the project, coupled with overlapping reviews for quality control and construct-ability. This approach will clearly avoid the typical problems associated with a Design .10 Build project. Edward Lewis Architects, Inc and the team have managed similar projects and have integrated a full range of in-house resources to achieve efficient, viable solutions. The successes of our past projects, which have been com- pleted for public agencies including Municipalities, are testimony not only to our design, management and construction capabilities, but also to the quality of our people. The key individuals assigned to this project are professionals, who have managed similarly scaled projects with multi-disciplined teams. As such, they understand the needs of reviewing agencies and the client alike. We are highly confident in the Team's ability and dedication in achieving a successful completion of this project. 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 ELAARCHITECTURE PLANNING Approach and Methodology INTERIOR CONSTRUCTION SERVICES edward lewls architects PROJECTS CONTROLS PROJECT CONTROLS All phases of the project will be integrated by our Project Director, who along with the Co-Project Managers,will maintain centralized control over all design entities,as well as provide a central resource for functions common to all of the concurrent design and production efforts.Examples of such functions include: Design Management i l e n I tO r -H, Cost and Schedule Control Discipline Coordination Coordination with MDAD and other Agencies Value Engineering Early identification of interfaces between already established program and the de- sign team is critical.Communication and documentation must,and will flow continu- ously between all members of the team throughout the design process. This will be managed through regularly held coordination meetings, weekly status reports, proper distribution of all correspondence (letters, telephone memos, etc.), and im- mediate and timely issuing of meeting minutes. QUALITY CONTROL PLAN QUALITY CONTROL PLAN Edward Lewis Architects, Inc Quality Control program employs a two-tier procedure to insure quality documents without misdirected effort. The first tier of our quality control program is a set of procedures that must be followed by Edward Lewis Archi- tects, Inc Project Managers.They include the following: Scope of Work Defined:Working with the client,the Project Managers assemble all relevant materials such as project description, project requirements, design manuals, codes, standards, and support information, in order to clearly define the Scope of Work and to eliminate possible sources of misunderstanding. Establishment of Schedules and Methodology: The Project Managers, under the direction of Edward Lewis, will assemble all sub-consultants at an initial meet- - J; i ' ing,or group of meetings, in order to describe the Scope of Work and to estab- fi " • • lish schedules, specification formats, cost estimating methods, progress report t milestones,and all potential coordination problems. 111 Coordination of Progress: The Project Managers will maintain contact with all A disciplines and plan frequent, regularly scheduled meetings, both within the Team and with the owners Project Management Team,to discuss progress and potential difficulties.They will be responsible for maintaining full communication among groups and individuals in the various sub-consultant firms and will -4406 1 • schedule full-team meetings, as needed, depending on the complexity of the f • design task. Regular scheduled Coordination Meetings will be held regularly , with disciplines during all design and Construction Documents phases of the project. at,'. 0•1' Formal Review: Prior to any progress submission to the client, the Principals-In- Charge and Project Managers will review the entire package with the fully as- sembled design team.They will determine that the submission is complete and coordinated,that it meets all client criteria, including all additions to the original Scope of Work, and that it is consistent in presentation(drawings are checked for dimensional consistency, uniform terminology, cross references, interface connections between disciplines, etc.). It is further reviewed from a construct- Fr., ability point of view, i.e.,whether plans are clear end complete for the potential construction contractor to understand the intent of the design team and imple- ment their intentions with ease. The second tier of the Quality Control program consists of an independent review of the documents at the 30%, 80%, and 100% completion stages. This review is ac- complished under the supervision of Edward Lewis Architects, Inc Quality Control Team, comprised of Edward Lewis, AIA and Leslie Escobar. The review team con- sists of staff, who did not work on the project. The team checks the drawings for accuracy, completeness and build-ability, coordination with all disciplines, and con- sistency with the specifications. This Quality Control program, utilized by ELA, has proven highly successful in past projects. None of the firms comprising the Team have had a claim resulting from Errors or Omissions related to the construction documents prepared by their respec- tive firms. 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 ARCHITECTURE EL PLANNING Approach and Methodology "` INTERIOR CONSTRUCTION SERVICES sdward lards architects VALUE ENGINEERING COST CONTROLS AND VALUE ENGINEERING Our team's approach to value engineering can be summed up in the words COST CONTROL. It is a proven fact that as decisions are made later in the course of a project,there is considerably more effort required to produce any significant impact to cost.Therefore, it is vital to the success of a project that early design directives are formulated with cost impacts in mind before they are implemented. This starts with verification of project scope and budget at the onset of the project as discussed in our Project Management Approach. It is necessary that all parties,not just the designers, - 4 understand the budget that is available and the real needs of the program to be suc- cessful.Once the program is understood, the designers have to be willing to recon- cile the viability of the project program versus the budget and owner expectations and ,fl adjust as necessary before the design proceeds.After the budget and scope is veri- �F e4 1! fied, we see the following steps as key to successful COST CONTROL throughout ,, the project: Understand the owner's concept of Return on Investment-could a budget increase if the payback is a reasonable term'?Introduce cost savings measures as early as pos- .,. mow sible and adequately explain pros and cons of each option.Accurately evaluate first cost versus long term maintenance expenses.Identify any compromises in system durability or longevity that may occur when choosing cost savings measures.Outline impacts of decisions based on future flexibility needs of the facility Perform a con- structability review no later than design development with credible contractors or the owner's selected pre-construction service provider and adjust plans as needed.Sys- tematically reconfirm the budget and current cost estimate at the end of each project phase. Along with the estimating and scheduling functions,the Value Engineering effort is an + important part of the Pre-Construction process.The personnel available,experts in their own fields,based on extensive construction experience and their knowledge of design systems and parameters,work closely with the design team to evaluate alter- - ' nates,and subsequently recommend the best systems to be used,based on: • Quality/Durability 4: • Material Availability • L ' - • Constructability • First Cost and Life-Cycle Cost • Schedule/Material Availability • Maintenance and Operation Considerations It is important to keep in mind that this review process needs to be part of the con- ceptual and early design document development stages of the project,not after draw- "'�" _ ing and documents are complete. This approach eliminates costly rework to already completed design drawings, as well as potential delays to the ultimate start of con- struction. The Value Engineering process will identify areas where significant contributions can ligM dor "` be made to reduce costs, speed construction,and enhance the project's value.This• ._-"" I - _ is achieved by: = • - - • Meetings and discussions with the project team I -', • Establishing criteria for the different schemes '7, • Regular project meetings to discuss ideas and suggestions • Discussing alternatives with the specialty contractors and investigating current market trends • Extensive reporting and regular feedback to the project team 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 Ei . IL i ARCHITECTURE PLANNING Approach and Methodology INTERIOR 1 CONSTRUCTION SERVICES edwsrd lewls Urchltects ' a Al --1 Where appropriate,detailed reports and recommendations will be produced,so the - +'t j project team can consider the implications of the options and make the proper deci- ' „4• 1- '.--- , -- -t, t sion.Pre construction specialists will identify,review, research,and present all items, r,r x which may represent a value engineering opportunity for project savings.The design of the project will be reviewed on a continuous basis,throughout the production of j construction documents,to determine whether the design is the most cost-effective �, and is consistent with the project goals.At a minimum,via analyses of drawings, �; specification,mock-ups,and samples,the following areas are examined: 7,...7.0.--ili..., I lie4 -11111 • Security Systems ' _ • Communications Systems • Life Safety and Building Management Systems - — �,. _ • Material and Finishes Maintenance Capabilities -``_- • Specialized Work CONSTRUCTABLITIY REVIEW CONSTRUCT-ABILITY REVIEW p.1 1 Important to the project's success is a construct-ability review. Specialists assigned 1 � to this project will review the design with an eye toward construction efficiencies and viabilities. The project and site-specific issues will be approached during the con- , t - struct-ability review.These include but are not limited to: 4 — _ • Can the project be built on time and on budget? • Can it be built given the project constraints (i.e. codes, labor regulations, climate,etc.)? • Are there alternatives that will provide the same functional and aesthetic results,while offering savings in cost and time to the owner? CADD CADD&Other Computer Applications: The team assembled for this project is on r the forefront of computer applications in the A/E industry ranging from ELA's use of • T._ _ ' EQuest energy modeling software to the use of Revit technology for building infor- 4 - I mation modeling. ,. II -=s Building Information Modeling -(BIM)is the process of generating and managing a ,$ l� "smart"virtual,three-dimensional building model through a building's life cycle.BIM � _ , an a -r technology allows us to visualize the structure,in full 3-D color,as it is taking shape. r Visualization enables us to design mechanical chases,route ductwork and even l' " �, ari I illustrate how programmed space will actually look when built. In addition to visuali- zation, BIM provides for better engineering analysis,conflict analysis,code criteria checking,cost estimating,as-built product documentation,budgeting,and building management.There are numerous benefits to BIM including:Accurate building pro- gram verification Early multi-discipline collaboration in an integrated approach Com- munication tool that produces better visualization through the use of 3D views and fly -thru techniques Facilitates design simulation to enhance sustainability Real time design around other disciplines reduces conflicts Increased efficiency via link to energy modeling tools 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 1 ARCHITECTURE E L A PLANNING Approach and Methodology r 0 INTERIOR I CONSTRUCTION SERVICES edward law is architects SUSTAINABLE DESIGN SUSTAINABLE DESIGN: ' SUSTAINABILITY Our clients today are seeking and demanding spaces that en- '�' • - hance environmental health and administrators are committed to that goal.We share 1 !'' -i your goal and we're dedicated to serving our clients and endure in a way that bene- .` r fits our plans.Our environmental strategy focuses on three key areas: F b • Sustainable Design Many if not all of our design strategies have roots based in sustainable design and LEED certified criteria.Our team has been designing sustainable spaces for decades.Today we serve all of our clients-those that wish to pursue LEED certification and those that wish to incorporate green or ET sustainable strategies into their buildings with strategies that fit their goals and L bottom line. • Materials Chemistry: It's all about understanding the materials we use-down to the molecular level - and assessing them against 19 human and environ- mental health criteria. edward levels. • Life Cycle Assessment: This process measures the total environmental im- • architects I pact of our products throughout their lifecycle - from raw materials to produc- tion,transportation,use and end-of-use phases. .,;...4„,,,,,ii4.4. The right time • Recycling and Reuse: Our aim is to make the best decisionsAO*y g 'using ma- t o plan t a tree �� terials with recycled content with an eye toward ongoing reaydability. "`o that end we design for disassembly, because products that can'"be easily taken . - was-20 years ago. apart are more likely to be recycled. In 2008,loin us in planting trees • Lighting-While providing natural light is an important aspect of healthcare that can be'llljoyed for years to c. spaces,it is just as critical to control direct natural lighting.ELA`d$8ign spaces that provide uniforms,shadow-free illuminated work spaces:> , hting `.0 levels and proper fixture selection,including task lighting and inclinktiimbient light,will provide the correct intensity of light and glare-free conditions to allevi- ate eyestrain. j_4 Why are Green Buildings important: • Enhance the quality of work place • Reduce capital and operating costs J • Enhance the recruitment and retention of staff ..'i5 \ • Improve the public image and community relationships 1s • • Demonstrate corporate responsibility Tie rigi l • Manage risk to plant a as 20 ; e : . s 2100 PONCE DE LEON BLVD, SUITE 825, CORAL GABLES, FL 33134 - PH. 305.234.0576. Fx. 786.472.4193 EllE1 edward lewis architects EDWARD LEWIS ARCHITECTS, INC. 2100 Ponce de Leon BLVD,Suite 825 Coral Gables, FL 33134 www.elamiami.com • EDWALEW-01 CBARTON AC-CPR� CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) 12/14/2015 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS . CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: Zoraida Gonzalez Collinsworth,Alter,Fowler&French,LLC PHONE 305 822-7800 FAx 305 362-2443 8000 Governors Square Blvd (A/c,No,Ext): ) (A/C,No): ( ) Suite 301 E-MAIL Miami Lakes,FL 33016 ADDRESS: INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:Hartford Ins Co of the SE 38261 INSURED INSURER B:Hartford Underwriters Ins CO 30104 Edward Lewis Architects,Inc. INSURER C:Gemini Insurance Company 10833 2100 Ponce de Leon Blvd.,Suite 825 INSURER D: Coral Gables,FL 33134 INSURER E INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LIMITS LTR INSD WVD POLICY NUMBER (MM/DD/YYYY) (MM/DD/YYYY) A X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE X OCCUR X X 21SBMBX0628 01/19/2015 01/19/2016 DAMAGE TO RENTED 300,000 PREMISES(Ea occurrence) $ MED EXP(Any one person) _$ 10,000 PERSONAL&ADV INJURY $ 1,000,000 GE 'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY X jE� LOC PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER: $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ 1 000 000 (Ea accident) > > A ANY AUTO 21SBMBX0628 01/19/2015 01/19/2016 BODILY INJURY(Per person) $ ALL OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS AUTOS X X NON-OWNED PROPERTY DAMAGE $ HIRED AUTOS _ AUTOS (Per accident) X UMBRELLA LIAB X OCCUR EACH OCCURRENCE $ 1,000,000 A EXCESS LIAB CLAIMS-MADE 21SBMBX0628 01/19/2015 01/19/2016 AGGREGATE _ $ 1,000,000 DED X RETENTION$ 1 0,000 $ WORKERS COMPENSATION X PER 0TH- AND EMPLOYERS'LIABILITY STATUTE ER Y • B ANY PROPRIETOR/PARTNER/EXECUTIVE E N N/A 21 WECGA0533 04/01/2015 04/01/2016 E.L.EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ 1,000,000 C Professional Llab. HPMDP0011902 09/26/2015 09/26/2016 Each Claim 1,000,000 C Claims-Made Basis HPMDP0011902 09/26/2015 09/26/2016 Annual Aggregate 3,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Professional Liab Retro Date: 11/4/1987;Professional Liab Deductible Each Claim$5,000/ $15,000 Deductible Annual Aggregate RE:RFQ 2014-346-YG The City of Miami Beach,Florida is named additional insured on the General Liability,excluding Professional Services. General Liability contain a waiver of subrogation on behalf of the additional insured. 30 days written notice of cancellation,non-renewal of coverage/limits,except 10 days for non-payment. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE The City of Miami Beach,Florida THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. C/O Insurance Tracking Services,Inc.(ITS) P.O.Box 20270 Long Beach,CA 90801 AUTHORIZED REPRESENTATIVE ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25(2014/01) The ACORD name and logo are registered marks of ACORD • v\ n A\AA1 BEACH c C rLdi 7 INSURANCE REQUIREMENTS This document sets forth the minimum levels of insurance that the contractor is required to maintain throughout the term of the contract and any renewal periods. XXX 1. Workers' Compensation and Employer's Liability per the Statutory limits of the state of Florida. XXX 2. • Commercial General Liability on a comprehensive basis in an amount not less than $1,000,000 combined single limit per occurrence for bodily injury and property damage. City of Miami Beach must be shown as an additional insured with respect to this coverage. XXX 3. Automobile Liability Insurance covering all owned, non-owned and hired vehicles used in connection with the work, in an amount not less than $500,000 combined single limit per occurrence for bodily injury and property damage. XXX 4. Professional Liability Insurance in an amount not less than $1,000,000 with the deductible per claim, if any, not to exceed 10% of the limit of liability. XXX 5. The City must be named as and additional insured on the liability policies; and it must be stated on the certificate. 6. Other Insurance as indicated: Builders Risk completed value $ .00 Liquor Liability $ .00 Fire Legal Liability $ .00 Protection and Indemnity $ .00 Employee Dishonesty Bond $ .00 Other $ .00 XXX 7. Thirty (30) days written cancellation notice required. XXX 8. Best's guide rating "A" as to management and "Class V" as to financial strength or better, latest edition. XXX 9. The certificate must state the proposal number and title. The City of Miami Beach is self-insured. Any and all claim payments made from self-insurance are subject to the limits and provisions of Florida Statute 768.28, the Florida Constitution, and any other applicable Statutes. A waiver of subrogation in favor of the City must be included for the policies required above. The insurance coverage required shall include those classifications, as listed in standard liability insurance manuals, which most nearly reflect the operations of the vendor. CERTIFICATE HOLDER MUST READ: CITY OF MIAMI BEACH 1700 CONVENTION CENTER DRIVE 3rd FLOOR MIAMI BEACH, FL 33139 RFQ 2014-346-YG Appendix E — Page 1