Agreement with EAC Consulting, Inc DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-1 6 8-02
AGREEMENT BETWEEN
CITY OF MIAMI BEACH
AND
EAC CONSULTING, INC.
FOR
CONSTRUCTION ENGINEERING AND INSPECTION (CEI) SERVICES ON AN "AS NEEDED"
BASIS PURSUANT TO REQUEST FOR QUALIFICATIONS NO. 2022-168-ND
RSOLIaTVAO.202232282
1
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contract No. 22-168-02
TABLE OF CONTENTS
DESCRIPTION PAGE
ARTICLE 1. DEFINITIONS 4
ARTICLE 2. BASIC SERVICES 9
ARTICLE 3. THE CITY'S RESPONSIBILITIES 14
ARTICLE 4. RESPONSIBILITY FOR CONSTRUCTON COST 16
ARTICLE 5. ADDITIONAL SERVICES 16
ARTICLE 6. REIMBURSABLE EXPENSES 18
ARTICLE 7. COMPENSATION FOR SERVICES 18
ARTICLE 8. CONSULTANT'S ACCOUNTING AND OTHER RECORDS 19
ARTICLE 9.OWNERSHIP OF PROJECT DOCUMENTS 19
ARTICLE 10.TERMINATION OF AGREEMENT 20
ARTICLE 11. INSURANCE 21
ARTICLE 12. INDEMNIFICATION AND HOLD HARMLESS 24
ARTICLE 13. ERRORS AND OMISSIONS 24
ARTICLE 14. LIMITATION OF LIABILITY 24
ARTICLE 15. NOTICE 24
ARTICLE 16. FLORIDA PUBLIC RECORDS LAW 25
ARTICLE 17. INSPECTOR GENERAL AUDIT RIGHTS 27
ARTCILE 18. MISCELLANEUS PROVISIONS... 28
SCHEDULES:
SCHEDULE A 35
SCHEDULE B 44
SCHEDULE C 45
SCHEDULE D 46
2
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
ATTACHED SEPARATELY:
ATTACHMENT A: Resolution and Commission Award Memorandum
ATTACHMENT B:Addenda and Request for Qualifications(RFQ)Solicitation
ATTACHMENT C: Consultant Proposal Response to RFQ and Sunbiz
3
50
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
C.
Contact No. 22-i 8'O2
AGREEMENT
BETWEEN THE CITY OF MIAMI BEACH
AND
EAC'CONSUL T INV SERVICES INC.
FOR
CONSTRUCTION ENGINEERING AND INSPECTION (CEI) SERVICES ON AN "AS
NEEDED" BASIS
2/14/2023 1 8:58 EST
This Agreement made and entered into this ("Effective Date"), by and between
the CITY OF MIAMI BEACH, a municipal corporation existing under the laws of the State of
Florida,having its principal offices at 1700 Convention Center Drive,Miami Beach,Florida,33139,
(hereinafter referred to as "City"), and EAC CONSULTING SERVICES, INC., a Florida
corporation having its principal office at 5959 Blue Lagoon Drive, Suite 410, Miami, FL 33126
(hereinafter referred to as"Consultant").
WITNESSETH:
WHEREAS, on May 4, 2022, the City Commission approved the issuance of Request for
Qualifications No. 2022-168-ND Construction Engineering and Inspection("CEI")Services on an
"As-Needed Basis" (the"RFQ"); and
WHEREAS, the RFQ was intended to provide various CEI services to the City on an "as
needed" basis; and
WHEREAS,on September 14,2022,the City Commission approved Resolution No.2022-
32262, respectively,authorizing the City to enter into negotiations with EAC,Consulting Services,
Inc. and, if successful,execute an agreement with the Consultant pursuant to the RFQ; and
WHEREAS, City and the Consultant have negotiated the following agreement pursuant to
the RFQ; and
NOW THEREFORE, City and Consultant, in consideration of the mutual covenants and
agreement herein contained, agree as follows:
ARTICLE 1. DEFINITIONS
1.1 Definitions. The definitions included in this Section are not exhaustive of all definitions
used in this Agreement. Additional terms may be defined in other Contract Documents. The
following terms shall have the meanings specified herein unless otherwise stated herein:
ADDITIONAL SERVICES: "Additional Services" shall mean those services, in addition to the
Basic Services in this Agreement, as described in Article 5 and the Consultant Service Order,
which may be performed by the Consultant or by an approved subconsultant at the rates
established herein. Additional Services shall be solely at the City's option and must be duly
authorized,in writing, by the City Manager or an authorized designee, prior to commencement of
same.
4
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No. 22-168-02
Ancillary Services: "Ancillary Services" means any service performed by Consultant or
a subconsultant at rates other than those established herein.Ancillary Services in excess
of the formal bid threshold (in aggregate for the project) shall require prior City
Commission approval.
APPLICABLE LAWS: "Applicable Laws" means all laws, statutes, codes (including, but not
limited to, building codes), ordinances, rules, regulations, lawful orders and decrees of
governmental authorities having jurisdiction over the Project, the Project Site or the Parties.
Services for which an engineer or architect license is not required are exempt from the provisions
of Sec. 287.055, Florida Statutes.
BASE BID: "Base Bid" shall mean the elements contained in the Construction Documents
recommended by the Consultant(and approved by the City)as being within the Construction Cost
Budget. "Base Bid" shall not include additive alternates or deductive alternates.
BASIC SERVICES: "Basic Services"shall include those services which Consultant shall perform
in accordance with the terms of the Agreement, as described in Article 2 and the Consultant
Service Order. Any Services not specifically enumerated as Additional Services (as defined
herein) shall also be considered Basic.Services. Services for which an architect or engineer
license is required are not considered basic services.
CITY(OR OWNER): The "City" shall mean the City of Miami Beach, a Florida municipal
corporation having its principal offices at 1700 Convention Center Drive, Miami Beach, Florida,
33139. In all respects hereunder,City's obligations and performance is pursuant to City's position
as the owner of the Project acting in its proprietary capacity. In the event City exercises its
regulatory authority as a governmental body including, but not limited to, its regulatory authority
for code inspections and issuance of Building Department permits, Public Works Department
permits,or other applicable permits within its jurisdiction,the exercise of such regulatory authority
and the enforcement of any Applicable Laws.shall be deemed to have occurred pursuant to City's
regulatory authority as a governmental body and shall not be attributable in any manner to City
as a Party to this Agreement.
CITY COMMISSION: "City Commission" shall mean the governing and legislative body of the
City.
CITY MANAGER:The"City Manager"shall mean the chief administrative officer of the City. The
City Manager shall also be construed to include any duly authorized representatives designated
by the City Manager in writing, with respect to any specific matter(s) concerning the Services
and/or this Agreement(exclusive of those authorizations reserved to the City Commission under
this Agreement, or to regulatory or administrative bodies having jurisdiction over the Project).
CONSTRUCTION COST BUDGET: The "Construction Cost Budget" shall mean the amount
budgeted and established by the City to provide for the cost of construction of the Work for the
Project("Construction Cost"), as set forth in the Consultant Service Order.
CONSTRUCTION DOCUMENTS: "Construction Documents" shall mean the final (100%
completed) plans, technical specifications, drawings, schematics, documents, and diagrams
prepared by the architect/engineer of record for the Project,setting forth in detail the requirements
for the construction of the Project. The Construction Documents shall set forth in full all details
5
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-468-02
necessary to complete the construction of the Project in accordance with the Contract Documents.
Construction Documents shall not be part of the Contract Documents,until(a)the Consultant has
submitted completed Construction Documents to the City and (b)they have been reviewed and
approved by the City and any agencies having jurisdiction in accordance with the procedures as
otherwise provided by the Contract Documents.
CONSULTANT:The i arried-entity-oii_page-1 of_ihis dgreon„ment,_the_"ConsuitantlShaA_mean_-the
qualified and properly professionally licensed professional in the State of Florida and as otherwise
required by any entities,agencies,boards,governmental authorities and/or any other professional
organizations with jurisdiction governing the professional practice area for which the professional
has been engaged by City and who will perform(or cause to be performed through subconsultants
acceptable to the City) ail Services required under this Agreement and/or Consultant Service
Order. When the term "Consultant" is used in this Agreement it shall also be deemed to include
any officers, employees, or agents of Consultants, and any other person or entity acting under
the supervision, direction, or control of Consultant to provide any Services or similar professional
services with respect to a Project("subconsultants").The Consultant shall not be replaced by any
other entity, except as otherwise permitted in this Agreement. Further, any subconsaltant that
may perform Services on behalf of the Consultant shall be a qualified and properly professionally
licensed professional in the State of Florida and as otherwise required by any entities, agencies,
boards, governmental authorities and/or any other professional organizations with jurisdiction
governing the professional practice area for which the subconsultant has been engaged by
Consultant to perform professional services in connection with the Project.
CONSULTANT SERVICE ORDER: Consultant Service Order("CSO")shall mean the work order
issued by the City to Consultant (in substantial form as in Schedule A-1 attached hereto), that
specifically describes and delineates the particular Services (Basic Services and/or Additional
Services)which will be required of Consultant for the Project that is the subject of such Consultant
Service Order, and which may include studies or study activity, and/or professional services as
defined in Section 287.055 of the Florida Statutes.
CONTRACT AMENDMENT: "Contract Amendment" shall mean a written modification to the
Agreement approved by the City(as specified below)and executed between City and Consultant,
covering changes, additions, or reductions in the terms of this Agreement including, without
limitation, authorizing a change in the Services, or the method and manner of performance
thereof, or an adjustment in the fee and/or completion dates.
Contract Amendments shall be approved in accordance with Contract Approval Authority
Procedure 03.02.The City Manager reserves the right to seek and obtain concurrence of the City
Commission for approval of any such Contract Amendment.
CONTRACT DOCUMENTS: "Contract Documents"shall mean this Agreement(together with all
exhibits, addenda, Consultant Service Orders and written amendments issued thereto), and all.
Design Documents and Construction Documents. The Contract Documents shall also include,
without limitation (together with all exhibits, addenda, and written amendments issued thereto),
the Request for Qualifications (RFQ), instructions to bidders, bid form, bid bond, Design Criteria
Package (if any), the Contract for Construction, surety payment and performance bonds,
Conditions of the Contract for Construction (General, Supplementary, and other Conditions),
Divisions 0-17 specifications, an approved Change Order(s), approved Construction Change
Directive(s),and/or approved written order(s)for a minor change in the Work.
6
DocuSign Envelope ID:038F080E-52C7-4774-A746-11 C4DF95D136
Contact No. 22468.02
CONTRACT FOR CONSTRUCTION: "Contract for Construction"shall mean the legally binding
agreement between City and Consultant for performance of the Work covered in the Contract
Documents, including, without limitation, a general Consultant, construction manager, design-
builder or any other duly licensed construction Consultant selected pursuant to any other
procurement methodology available under Florida law.
CONTRACTOR: "Contractor" shall mean the individual or individuals, firm, company,
corporation,joint venture,or other entity contracting with City for performance of the Work covered
in the Contract Documents.
DESIGN CRITERIA PACKAGE or DCP: "Design Criteria Package" means concise,
performance-oriented drawings or specifications of a design-build Project, prepared for the
purpose of furnishing sufficient information to permit design-build firms to prepare a bid or a
response to a City request for proposal, or to permit the City to enter into a negotiated design-
build contract. The Design Criteria Package must specify performance-based criteria for the
design-build Project, including the legal description of the site, survey information concerning the
site, interior space requirements, material quality standards, schematic layouts and conceptual
design criteria of the project, cost or budget estimates, design and construction schedules, site
development requirements,provisions for utilities,stormwater retention and disposal,and parking
requirements applicable to the project. Design criteria package services may not be acquired
through this contract.
DESIGN DOCUMENTS: "Design Documents" means all plans, drawings specifications,
schematics and all other documents which set forth in full the design of the Project and fix and
describe in detail the size, configuration and character of the Project concerning all items of the
Project necessary for the final preparation of the 100% completed, permitted Construction
Documents in accordance with the requirements of the Contract Documents including, without
limitation,all architectural and engineering elements as may be appropriate. Design Documents
shall not be part of the Contract Documents, until (a) the Consultant has submitted completed
Design Documents to the City and (b) they have been reviewed and approved by the City and
agencies having jurisdiction in accordance with the procedures as provided by the Contract
Documents. However, approval by the City shall not in any way be construed, interpreted and/or
deemed to constitute a waiver or excuse Consultant's obligations to ensure the Design
Documents are constructible, in compliance with all Applicable Laws and in accordance with the
Contract Documents. Design documents may not be acquired through this contract.
PROJECT: The"Project"shall mean that certain City capital project described in the Consultant
Service Order.
Project Cost: The "Project Cost" shall mean the estimated total cost of the
Project, as described in the Consultant Service Order(CSO)
Project Scope: The "Project Scope" shall mean the description of the Project, as
described in the Consultant Service Order(CSO).
PROJECT ADMINISTRATOR: The"Project Administrator"shall mean the individual designated
by the City Manager who shall be the City's authorized representative to issue directives and
notices on behalf of the City with respect to all matters concerning the Services of this Agreement
(exclusive of those authorizations reserved to the City Manager or City Commission under this
Agreement, or to regulatory or administrative bodies having jurisdiction over the Project).
7
DocuSign Envelope ID:038F080E-52C7-4774-A746-11 C4DF95D136
Contact No.22-168-02
PROPOSAL DOCUMENTS: "Proposal Documents" shall mean the RFQ, together with all
amendments or addenda thereto (if any), which is incorporated by reference to this Agreement
and made a part hereof; provided, however, that in the event of an express conflict between the
Proposal Documents and this Agreement,the Agreement shall prevail. Consultant's proposal in
response to the RFQ is included for reference purposes only and shall not be incorporated as
part of this -Agreement, except with-respect to Consulter:t''s representations regarding__the
qualifications and experience of Consultant and its key personnel, its commitment to provide the
key personnel listed therein, and its capability to perform and deliver the Services in accordance
with this Agreement and consistent with the all representations made therein.
SCHEDULES: "Schedules" shall mean the various schedules attached to this Agreement and
referred to as follows:
Schedule A—Scope of Services
Schedule A-1 — Consultant Service Order(CSO)
Schedule B— Consultant Compensation
Schedule C— Hourly Rate Schedule
Schedule D— Approved Subconsultants
SCOPE OF SERVICES:"Scope of Services"shall include.the Project Scope, Basic Services,and
any Additional Services(as approved by the City), all as described in Schedule"A" hereto.
SERVICES: "Services" shall mean all services, work, and actions by the Consultant performed
pursuant to or undertaken under this Agreement, including-services delineated as part of the
Scope of Services.
SOFT COSTS; "Soft Costs"shall mean costs related to the Project other than Construction Cost
including, without limitation, Consultant's Basic Services, Additional Services, surveys, testing,
general consultant, financing, permitting fees and other similar costs, as determined by the City,
that are not considered as direct costs for the construction of the Project.
STATEMENT OF PROBABLE CONSTRUCTION COST: The "Statement of Probable
Construction Cost" shall mean the detailed estimate prepared by Consultant in Construction
Standard Index(CSI)format or other format approved by the Project Administrator,which includes
the Consultant's estimated total construction cost to the City of the Work for the Project (as
established in the Contract Documents, as they may be amended from time to time). The
Statement of Probable Construction Cost shall be in sufficient detail to identify the costs of each
element of the Project and include a breakdown of the fees, general conditions and construction
contingency for the Project. Costs shall be adjusted to the projected bid date to take into account
anticipated price escalation.
WORK: "Work" shall mean all labor, materials, equipment, supplies, tools, machinery, utilities,
fabrication, transportation, insurance, bonds, permits and conditions thereof, building code
changes and government approvals, licenses, tests, quality assurance and/or quality control
inspections and related certifications, surveys, studies, and other items, work and secee that
are necessary or appropriate for the total construction, installation, and functioning of the Project,
together with all additional, collateral and incidental items, and work and services required for
delivery of a completed, fully functional and functioning Project as set forth in the Contract
Documents.
8
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
ARTICLE 2. BASIC SERVICES
2.1 The Consultant shall provide Basic Services for the Project, specifically described in the
Consultant Service Order.All basic services shall comply with the hourly rates established herein.
Any service for which the hourly rates established herein are not applicable shall be considered
ancillary services and must comply with Article 5 of this Agreement.
2.2 The Services will be commenced by the Consultant upon receipt of a written Consultant
Service Order signed by the City Manager or its designee. Consultant shall countersign the
Consultant Service Order upon receipt and return the signed copy to the City.
2.3 As it relates to the Services and the Project, Consultant warrants and represents to the
City that it is knowledgeable of and shall comply with all Applicable Laws. The Consultant agrees
to comply with all Applicable Laws,whether now in effect or as may be amended or adopted from
time to time and shall further take into account all known pending changes to the foregoing of
which it should reasonably be aware.
2.4 The Consultant warrants and represents to the City that all of the Services required under
this Agreement shall be performed in accordance with the standard of care normally exercised in
comparable projects in.South Florida. Consultant warrants and represents to the City that it is
experienced, fully qualified, and properly licensed (pursuant to Applicable Laws)to perform the
Services- Consultant warrants and represents to the City that it is responsible for the technical
accuracy of the Services.
2.5 The Consultant's Basic Services_to be provided under this Agreement shall (at a
minimum)consist of, but not be limited to the following:
2.5.1. Administer the Construction Contract and monitor and inspect the work performed by the
Contractor such that the project is constructed in reasonable conformity with the plans,
specifications, and special provisions of the Construction Contract.
2.5.2 Resident Engineering Services - Coordinate the Construction Contract administration
activities during construction with all utilities,testing companies,permitting agencies and the City
. Services shall include maintaining the required level of surveillance of Contractor activities,
interpreting plans, specifications, and special provisions for the Construction Contract. Maintain
complete, accurate records of all activities and events relating to the project and properly
document all project changes. Notwithstanding this Section 2.5, the Consultant Service Order
issued by the City to Consultant shall specifically delineate and describe the Services to be
provided by Consultant for the particular Project (that is the subject of such Order). include
maintaining the required level of surveillance of Contractor activities, interpreting plans,
specifications, and special provisions for the Construction Contract. Maintain complete, accurate
records of all activities and events relating to the project and properly document all project
changes.Notwithstanding this Section 2.5,and Schedule"A hereto,the Consultant shall provide
coordination with permitting agencies, coordination with utility companies, provide the daily
reports and construction progress documentation as required, estimate and verify construction
cost, review and respond to any claims from the project contractor.
2.6 RESPONSIBILITY FOR CLAIMS AND LIABILITIES: No action or omission by City shall
waive or excuse Consultant's obligations under the Agreement and/or other Contract Documents
9
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No..22-168,-02
and that Consuttant shall remain fully torah l work,performed by Consultant including.,without
limitation, any design errors or omissions(if applicable to the services performed by Consultant).
Written cledielons and/or approvals issued by the City shall not constitute nor be deemed a release
oft he responsibility and liability of the'Consultant(or any SubconSultaiita),for the accuracy and
competency of the Services, nor Shall.any City approval and/or decisions be deemed to be an
assumption of such,respOntibility by the City for a defect, error or omission in 'the Services,
Moreover, neither the-CiVainapectiOnTreviewi approVel-oracceptence-Ofi nor payment-for,,-any
Services required under the Agreement shall be construed to relieve the consultant (or any
subconatiltent)of its obligations and responsibilities under the Agreement,nor constitute a waiver
Of any Of the City's rights under the Agreement or of any cause of action arising•out of the
performance of the Agreement The Consultant shall be and remain liable to the City in
accordance with Applicable Laws for all damages to City caused by any failure of the Consultant
or to comply with the terms and conditions of the Agreement or by the'Consultants misconduct,
001(41 acts, negligent acts; error's or omissiona in,the performance of the Agreement.
2.7 lige It Is Understood that time is of the essence except due to Force Majeure as defined
herein. in the completion of the Project and,in this respeot,the parties agree askillowst
271 Term: The term of this Agreement shall comMence upon execution by the City
and Consultant,which Shall be the'Effective Date referred to on page 1 hereof, and shall
be in effect for three(3)years( InitialTertnn),plus two(2),one(1)year renewal optiOns,
to be exercised at the sole discretion of the City Manager(Initial Term and any renewals
shall be collectively referred to as the "Term'),. -Notwithstanding the preceding Term,
Consultant shall adhere to any and all timelines and/or deadlines as set forth in the
Consultant Service Order, including the time for completion of the work and/or services
for sUch Project(as set forth in the partitUlar Consults fit Service Order).
2,7,2 The Consultant shall perform the Services as expeditiously as is consistent with
the.standard of pfessicirial skiff,and care reqUired by this Agreement, and the orderly
progress of the Work.
2.7,3 Recognizing that the construction of other projeOts within the City may affect
scheduling of the construction for the Project the Consultant shall diligently coordinate.
performance of the Services with the City(through,the Project Administrator) in order to
provide for the safe, expeditious, economical and efficient completion of the Project,
without negatiVely iMpacting concurrent work by others.
2.7.4 'The SerViceS Shall be performed in a mannerthat shall conform,to,the Consultant
Service Order, The Consultant may submit requests for an'adjustment to the Consultant
Service Order Completion time,if,made necessary because of undue delays resulting from
untimely review taken by the City (or authorities having'jurisdiction over the Project)to
approve the Consultant's submissions, •or any other portion of the Services requiring
approval by the City (or other governmental authorities having jurisdiction over the
Project), Consultant shall immediately provide the Project Administrator with written notice
stating the reason for the particular delay;the requested adjustment(i.e.extension)to the
Project Schedule, and a revised anticipated schedule of completion, Upon receipt and
review of Consultant's:request(and such otherdocumentation as the Project Administrator
may require), the Project Administrator may grant a reasonable extension of time for
completion of the particular work invcilVed,and authorize that the appropriate adjustment
be,made to the Project Schedule. The Project Administrator's approval (if granted) shall
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
be in writing.
.2.8: Consultant shall use its.best efforts to,maintain a constructive,.professional, cooperative
workil ig relationship with the Project Administrator,, Design Consultant, and any and all. other
individuals and/or firms that have been contracted;or otherwise retained,to perform Work on the
Project:
2.9 The.Consultant shall perform its duties under this Agreement,: and'tinder a Consultant
Service Order, in a competent,, timely and professional manner,.and shall:be responsible to the
City for anyfailure in its'performance,except to the extent that acts or omissions by the City make
sueh;.pert-W(iance impossible:
2.16 The Consultant is respon;ibiefor:
,a.the professional quality
b,technical accuracy
c.:completeness
id;performance and:coordination of all Services required under the.Agreement and�under
the-CConsultant Service Order(including the services performed by subconsultarits),within
the specified time pried and specified cost
The Consultant shall,perform the Services utilizing the skill, kneWledge„and judgment ordinarily
possessed and used by a proficient consultant with respect to the disciplines required for the
performance of such Services in the State of Florida.The Consultant is responsible for and shall.
represent to.City that the Services conform to the.City's requirements, the Contract Documents
and.all Applicable Laws. The Consultant that{be and remain liable tothe City for all damages to
the.City caused by the Consultanf's negligent acts or errors or omissions in the performance of
the Services: In addition.to all other rights and remedies which the City may have,the Consultant
shall,at its expense,re-perform:all or any portion of the Services to correct any.deficiencies which
*tilt from the Consultant's failure'to perform`in accordance with the above standards. Neither
the City's inspection, review,approval or acceptance of, nor payment for, any of the Services
required under the Agreement shall be construed to relieve the Consultant(or any Subconsultant)
of its obligations and responsibilities under the Agreement,nor constitute a waiver of.any of the
City's,rights under the Agreement, or of any cause of action arising out of the performance of the
Agreement.. The Consultant and its Subconsultants shall be and remain liable; to the City in
accordance with Applicable'Laws for all damages to.City pouted'by any failure of the..Consultant
or its Subco nsultants to comply with the terms and conditions of the Agreement or by the
Consultant Cr any Subconsultants''misc_onduct,.unlawful acts,negligent acts, errors or omissions
in the performance of the Agreement. The Project Administrator shall notify the Consultant, in
writing,of any defciendes and shall approve the method and timing of the.corrections.
2:11 The City shall have the right at anytime, in its sole and absolute discretion,to submit
review to other consultants(engaged by the City at its expense) any or all parts of the Services
and the Consultant shall fully cooperate in such reviews) Whenever others are required to verify,
review, or consider any Services performed, by Consultant (including, without limitation,
Consultants, other design professionals, and/or other consultants retained by the City);the intent
of such requirement is to enable the Consultant to receive input from others' professional
expertise to identify any discrepancies, errors or omissions that are inconsistent with industry
standards relating to comparable projects, or which are inconsistent with Applicable Laws; or
which are inconsistent with standards; decisions or.approvals provided by the City under this
Agreement. Consultant will use reasonable care and skill, in accordance and consistent with
11
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
customary professional standards, in responding to items identified by other reviewers in
accordance with this subsection. Consultant shall receive comments from reviewers, in writing.
Consultant shalt address comments forwarded,:to it in.a Lithely manner, Theterrri"timely"shall be
defined to mean as..soon:as possible under the circumstances,,taking into account the timelines
of the Project,schedule.
2..11,1 The Consultant,is advised that a peifprrrrance evaluation.of the.Services rendered.
throughout this Agreement will:.be cotnpleted by the City and kept in the City files for
evaluation,of future solicitations.
2.12. Consultant agrees that•When any portion of the Services relates to a professional service
which,under Florida Statutes,requires a'license,certificate of'authorizationi or other form of legal
entitlement to practice and/or perform such Service(s),it shall employ and/or retain only qualified
duly licensed certified personnel to provide same.
2:13 Consultant agrees to designate., in writing, within five(b)calendar days after lfeceiuing a.
fully executed Consultant Service Order, a qualified licensed,professional to serve as•its project
manager (hereinafter referred to as the "Project Mattaget"). The Project Manager shall be
authorized and responsible to act on behalf of Consuitantwith respect to directing, coordinating
arid administrating all aspects of the Services Consultant's Project Manager(as well as any
replacement) shall be subject to the prior written approval of the City Manager or the Project
Administrator: Replacement(including reassignment)of an approved Project Manager shall not
.be made without the prior Written.appro\al of the, City Manager or designee (i.e. the Project
Admiinistrator).
2:131 Consultant agrees,,within seven(t)calendar days of receipt of written notice from
the City Manager .or the. ,Project Administrator (which notice shall' state the cause
therefore), to promptly retrieve and replace a Project Manager; or any other personnel
employed;or otherwise retained by Cpnsultantfor the Project(including,without limitation,
any.subconsuultants).
2.14 Consultant agrees not to divulge, furnish or make available to any,third:party(ies), any
non-public information concerning the,Services.or the Project,without the prior written consent of
the City Manager or the Project Administrator; unless such,disclosure is,incident to the proper
performance of the. Services; or the disclosure is requited pursuant"to Florida Public Records
laws; ,or;, in the course of judicial proceedings, where such information has been properly
subpoenaed:.Consultant Shall;also requite subconsuitai ts'to comply with this subsection:
2.15 The City and Consultant acknowledge that the Services, as described in the Agreement
and the Consultant Service Order,do not delineate every detail and minor work task required to
be performed.by Consultant to complete the work and/or services described and delineated under
a Consultant.Service Order issued to Consultant by the City for a particular Project. If, during the
course of performing 'work, services and/or tasks on a particular Consultant Service'Order,
Consultant determines that work and/Or services should,be.performed (to complete the Project
.delineated under such Order),which is, in the Consultant's reasonable opinion, outside the level
of effort originally anticipated in.the.Consultant Service Order, then Consultant shall promptly
notify the. Project Administrator, in writing, and shall obtain the Project Administrator's:written
consent before proceeding with such work and/or services, If Consultant proceeds with any such
additional work and/or ,service's without obtaining the prior written, consent of the Project
12
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
Administrator, said work and/or services shall be deemed to be a Basic Service under this
Agreement and shall also be deemed to be within the scope of services delineated in the
Consultant Service Order(whether or not specifically addressed in the Scope of Services). Mere
notice by Consultant to the Project Administrator shall not constitute authorization or approval by
the City to perform such work. Performance of any such work and/or services by Consultant
without the prior written consent of the Project Administrator shall be undertaken at Consultant's
sole risk and liability.
2.16 Consultant shall establish, maintain, and categorize any and all Project documents and
records pertinent to the Services and shall provide the City, upon request,with copies of any and
all such documents and/or records. In addition,Consultant shall provide electronic document files
to the City upon completion of the Project
2.17 THE CITY HAS NO OBLIGATION TO ASSIST, FACILITATE AND/OR PERFORM IN
ANY WAY THE CONSULTANTS OBLIGATIONS UNDER THE AGREEMENT OR OTHER
CONTRACT DOCUMENTS. THE CITY'S PARTICIPATION, FACILITATION AND/OR
ASSISTANCE TO THE CONSULTANT SHALL BE AT ITS SOLE DISCRETION AND SHALL
NOT, IN ANY WAY, BE CONSTRUED, ' INTERPRETED •ANDIOR CONSTITUTE AN
ASSUMPTION BY THE CITY OF CONSULTANT'S OBLIGATIONS, A WAIVER OF
CONSULTANT'S OBLIGATIONS ANDIOR EXCUSE ANY BREACH BY CONSULTANT OF ITS
OBLIGATIONS UNDER THE CONTRACT DOCUMENTS. THE PARTICIPATION IN THE
PERFORMANCE OF ANY OF CONSULTANT'S OBLIGATIONS SHALL NOT PRECLUDE THE
CITY FROM DECLARING CONSULTANT IN DEFAULT FOR CONSULTANT'S FAILURE TO
PERFORM'SUCH OBLIGATION, NOR SHALL IT LIMIT, IN ANY WAY, THE CITY'S RIGHTS
AND REMEDIES IN CONNECTION THEREWITH. THE CONSULTANT EXPRESSLY
ACKNOWLEDGES AND AGREES NOT TO RAISE OR ASSERT AS DEFENSE TO ANY
CLAIM,ACTION,SUIT AND/OR OTHER PROCEEDING OF A SIMILAR NATURE,THE CITY'S
PARTICIPATION, ASSISTANCE AND/OR FACILITATION IN THE PERFORMANCE OF
CONSULTANT'S. OBLIGATIONS. INCLUDING, WITHOUT LIMITATION, ASSISTING WITH
•
OBTAINING PERMITS OR WITH COORDINATION WITH UTILITIES, OR OTHER MATTERS
RELATED TO THE PROJECT. IN THE EVENT OF ANY CONFLICT BETWEEN THIS SECTION
AND/OR ANY OTHER PROVISION OF THIS AGREEMENT OR OTHER CONTRACT
DOCUMENTS,THIS SECTION SHALL GOVERN.
2.18 GREEN BUILDING STANDARDS: If applicable, the Consultant shall comply with the
requirements of Section 255:2575, Florida Statutes, and Chapter 100 of the City Code, as both
may be amended from time to time, addressing applicable Leadership in Energy and
Environmental Design(LEED)compliance requirements.
2.19 SUBCONSULTANTS: From time-to-time, it may be necessary to add a subconsultant(s)
to assist on a specific project. All services provided by subconsultants shall be consistent with
those commitments made by the Consultant in its Proposal and during th.e competitive solicitation
selection process and interview. Such services shall be undertaken and performed pursuant to
appropriate written agreements between the Consultant and the subconsultants, which shall
:contain provisions that preserve and protect the rights of the City under this Agreement. Nothing
contained in this Agreement shall create any contractual relationship between the City and the
subconsultants.
The Consultant shall not retain, add, or replace any subconsultant without the prior written
approval of the City Manager, in response to a written request from the Consultant stating the
13
DocuSign Envelope ID:038F080E-52C7-4774A746-11C4DF95D136
Contact No. 22-168-02
reasons for any proposed substitution.
The Consultant shall be ultimately responsible for ensuring the Consultant's and all of its
subconsultants' are in compliance with the requirements of this Section and any other provision
of the Agreement and/or Consultant Service Order. With respect to the performance of work by
subconsultants, the Consultant shall, in approving and accepting such work, ensure the
professional quality, completeness; :nd oor iination-of the.q'thrnnsultant-s work.
The Consultant shall, upon the request of the City, submit to the City such documentation and
information as the City reasonably requests to evidence the creation, standing, ownership and
professional licensure of the Consultant (and subconsultants), including organizational
documents, operating agreements and professional licensure documentation, and copies of the
Consultant's contracts with the subconsultant with respect to the Project. However, the City's
failure to request such documentation or evidence and/or failure to enforce in any way the terms
and provisions of this Section, the Agreement and/or any other Consultant Service Order during
the Project does not excuse, waive and/or condone in any way any noncompliance of the
requirements set forth therein including, without limitation, the professional licensure
requirements. Any approval of a subconsultant by the City shall in no way shift from the
Consultant to City the responsibility for the quality and acceptability of the services performed by
the subconsultant. Payment of subconsultants shall be the sole responsibility of the Consultant
and shall not be cause for any increase in compensation to the Consultant for payment of the
Services.
2.19.1 APPROVAL OF SUBCONSULTANTS: The City Manager or the City Manager's
designee must approve the use of any subconsultant. Sub.consultants performing workin
accordance with the contract rates may be approved by the City Manager or designee
even if the total cost exceeds the formal bid threshold.Work that:is not in accordance with
the contract rates shall be considered ancillary services and approved accordingly.
ARTICLE 3.THE CITY'S RESPONSIBILITIES
3.1 The City Manager shall designate a Project Administrator, who shall be the City's
authorized representative to act on City's behalf with respect to the City's responsibilities or
matters requiring City's approval under the Contract Documents. The Project Administrator shall
be authorized (without limitation)to transmit instructions, receive information, and interpret and
define City policies and decisions with respect to the Services and the. Project. The Project
Administrator shall have full authority to require the Consultant to comply with the Contract
Documents, provided, however, that any failure of the Project Administrator to identify any
noncompliance,or to specifically direct or require compliance, shall in no way constitute a waiver
of, or excuse, the Consultant's obligation to comply with the requirements of the Contract
Documents.
3.2 The City shall make available to Consultant, for the convenience of the Consultant.only,
information that the City has in its possession pertinent to the Project. Consultant hereby agrees
and acknowledges that, in making any such information available to Consultant, the City makes
no express or implied certification, warranty, and/or representation as to the accuracy or
completeness of such information and assumes no responsibility whatsoever with respect to,the
sufficiency, completeness or accuracy of such information. The Consultant understands, and
hereby agrees and acknowledges, that it is obligated to verify to the extent it deems necessary
all information furnished by the City, and that it is solely responsible for the accuracy and
14
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No. 22-168-02
applicability of all such information used by Consultant. Such verification shall include, without
limitation, visual examination of existing conditions in all locations encompassed by the Project,
`where such examination.can be,made without using destructive;measures. (:e. excavation..or
demolition): :Survey information.shall be•spot'checked.tO the extent that Consitttant has,satisfied
itself as to the reliability of the information.
3:3. At any time, in his/her sole discretion,. the City Manager may furnish accounting, and.
insurance counseling services for the-Proiect(including, without limitation, auditing services to
verify the Consultants applications for payment, or to ascertain that.Consultant has properly
remitted payment due to its subconsulfants or vendors.).
.3.4 if the City observes'Or.otherwise becomes aware of:any fault or defect in the'Project, or
non-conformarnce with the Contract Documents;the City,through the Project Administrator,shall
give prompt written notice thereof to the Consultant Such notice shall include (1.) the work
required to correct the fault,defect,or non-conformance and(2)the.allotted time for the correction,
which,unless Otherwise agreed upon by tha.Parties,shall be:no longer than fourteen,(14).days.
3.5 The City,acting in.its proprietary capacity as Owner and not in its regulatory capacity,shall
render any administrative approvals and decisions required under this Agreement, in writing, as
reasonably expeditious for the orderly progress of the Services and of the Work.
3.6. Ttie City Commission shall be:the finai authority to do or to approve the following actions.
or conduct,by passage.of an enablirtg.resolution or amendment to this Agreement:
3.0.1 lxcept where otherwise expressly noted in the Agreement or the.'Contract.
Documents, the City •Commission shall be the.body fo consider, comment upon, or
approve any amendments or modifications to this Agreement.
3,6.2 The City Commission shall be the body to consider, comment upon, or approve
any assignment, sale, transfer or subletting of this Agreement,Assignment and transfer
:shall be defined to also include sale of the majority of the stock of a corporate consultant.
35.2 Contract Amendments shall be approved in,accordance with Contract Approval
Authority Procedure 03.02 or as amended:
3,7 Except where otherwise expressly noted in this Agreement;the City Manager shall Serve
as the'City.'s,.primary representative to whom administrative(proprietary) requests'for decisions.
and approvals required hereunder by the.City shall be made. Except where otherwise expressly
noted in this Agreement or the Contract Documents; the City Manager shall issue decisions.and
authorizations which may include, without limitation, proprietary review, approval, or comment
Upon the schedules; plans, reports, estimates, contracts,and other documents submitted to,the
City by Consultant..
3.7.1 The City Manager,shall have prior review and approval of the Project Manager
(and any replacements)aid of-any subcorisultants(and any replacements).
3.7.2 The City Manager.shall decide and render administrative (proprietary) decisions_
on matters arising pursuant to this Agreement which are not otherwise expressly provided
for in this Agreement in his/her discretion,the City Manager may also consult with the
City.Commisslon on such matters.
15
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
3.7.3 At the request of Consultant, the City Manager shall be authorized, but not
required, to reallocate monies:already .budgeted toward payment Of the COnSulfark
provicted hoWever,,that the Consultant's CoMpertSetan(or other budgets established by
this Agreement)may not be increased without the prior approval of the City Commission,
Which approval(if granted,at all)shall be in its sole andreasonable discretion.
Contract Amendments shall be,approved in accordance with Contract Approval
AUthority Procedure tap of as amended,
3.7.5 The City Manager may,in nitthersole ditoretiOn,form a committee or conirnittees,
or inquire of, or consult with., persons for the ,purpose of receiving advice and
recommendations relating to the exercise of the,City's powers,duties,and responsibilities
kinder This Agmentent or the COntract Obdkirneritt,
3.7..6 The City'Manager shalt be the City CorritnitSion't authorized representative with
regard to acting on behalf of the City in the event of issuing any default notice(s) under
this Agreement,and, Should such default remain undurecli in terminating the Agreement
(pursuant toainci in acCordance with Article IQ hereOf)
.34 The City's,review, evaluation,or comment as to any documents prepared byor on behalf
Of the Consultant shall be solely for the pOrpose of the City%deterrnining Wits own satisfaction
the Suitability of the Project, or portions thereof, detailed in,such documents for the purposes
intended therefor by the City, and may not be relied upon in,any way by the Consultant or any
other third party:at asubatantive review thereof.
ARTICLE 4,INTENTIONALLY OMITTED
ARTICLE 5..ADDITIONALSERVICES
5.1 Additional Services shall only be performed by Consultant follOwing receipt of written
authorization, by the Project Administrator (which authorization must be obtained prior to
cornmencement of any such additional work by .Consultant):: The written authorization shall
contain a description of the Additional Services required,a lump sum to be negotiated at the time
of the request for additional.services ore fee(in accordance with the rates in Schedule"G"hereto),
with:a"Not to,EXceedu amount Reimbursable Expenses(if any)with,a"Not to Exceed",amount;
the amended Construction Cost Budget (if applicable); the time required to, complete the
Additional Services;and an amended Project Schedule(if applicable),"Not to Exceed"shall mean
the maximum cumulative fees allowable(or,in the case of Reimbursable Expenses,the maximum.
cumulative expenses allowable), which the Consultant shall not exceed.without further written.
authorization of the Project,AdMinistrater. The 'Not to Exceed" amount is not a guaranteed
maximum cost for the additional work requested (or, in the case of Reimburtablet, for the
expenses), and all costs applicable to same shall be verifiable through time sheets (and, for
Reimbursables,expense reViewt),
5.7 Additional SerVides include the following:
5.7.1. Unforeseen Conditions. Providing additional work relative tO the Project which
16
9)
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No. 22-168-02
arises from subsequent circumstances and causes which could not reasonably have been
foreseen at the time of execution of this Agreement(excluding conditions determined by
all prior studies available to Consultant and excluding circumstances and causes resulting
from error;,ornittionrinadvertence,or negligence of Obritultent).
522 .Expert Witness: Except insofar as.the Consultant is required by legal process or
subpoena to appear and give testimony,preparing to serve or serving as an expert witness
in connection with any state or federal court action to which the Consultant is not a party
hits own narriO that is not instituted by the Consultant Grin which.the performance of the
Consultant is not in issue.
5.2.3 Procurement Assistance in connection with bid protests; re-bidding, or re-
negotiating contracts (except for Contract Document revisions and re-bidding services
required under Section 4.4 hereof,which shall be provided at no edditionel cost to City),
52.4. Threshold_ inspection/Materiel Testing 'arid Inspection: 'Providing threshold
inspeetioh services and material testing/special inspection services, provided that
Consultant,as part of the Betio Services,shall report On the progress the Work,including
any defects and deficienciet that may be observed in the Work.
6.26 Surveys &testing: Environmental investigations And site evaluations, prcivided,
however, that surveys of the existing structure required to complete as-built
dOCurnentatiOn are not additional seiVices.
5,2,6 Geotechnic,al engineering. Providing geotechnical engineering services or site
surveys:
5.3 Additionaltervices may be requested by the City using a ConsultantService Order(CSO),
Eor each proposed Consultant Service Order, Consultant shall provide the City with a cost
proposal on a lump,sum or not-to-exceed basis, based on the fee schedule set forth in Schedule
hereto.. Consultant Service Order shall be executed in accordance with Contract Approval
Authority Procedure 03.02 or as amended. Any CSO not executed in accordance herewith shall
be null and void.
Except as specified herein, services that •are required for completion of the Construction
Documents shell be part of C onsultarits,Sesto Services,
5.4 Reimbursable Expenses shall be authorized and,approved in accordance.with.Article 6
hereto.
516 Additional services not adhering, to the contract rates established herein shall be
considered ancillary serVice.s and approved accordingly.
ARTICLE 6.REIMBURSABLE EXPENSES
6.1 Reimbursable Expenses must be authorized, in advent.% in Writing, by the Project
AdMinistrator. Invoices or vouchers for Reimbursable Expenses shall be submitted to the Project
Administrator (along with any supporting receipts and other back-up material requested by the
Project Administrator). Consultant shall certify as to each such invoice and/Or voucher that the
amounts and items claimed as reimbursable are 'true and correct and in accordance with the
Agreement." Reimbursable Expenses may include, but not belimited to, the following:
17
512
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
• Cost of reproduction, courier, and postage and handling of drawings, plans,
specifications,and other Project documents(excluding reproductions for the office
use of the Consultant and its subconsultants, and courier, postage and handling
costs between the Consultant and its subconsultants).
• C__ts_for repro .ction.and..preparation .f graphics.f r.comm Iuni�Lworkshops.
l.rVbW lul IGiJ1ud4�.L{v��a��u Fnc�aicxuvi�a'�ryrc.Nn�iw-o%
• Permit fees required by City of Miami Beach regulatory bodies having jurisdiction
over the Project(i.e. City permit fees).
ARTICLE 7. COMPENSATION FOR SERVICES
7.1 Consultant's"Lump Sum"or"Not to Exceed"fee for provision of the•Services,or portions
thereof,as may be set forth and described in the Consultant Service Order(CSO)attached hereto
as Schedule "A-1", issued for a particular Project, shall be negotiated between the City and
Consultant, and shall be set forth in the Consultant Service Order.
7.2 Payments for Services shall be made within forty-five (45) calendar days of receipt and
approval of an acceptable invoice by the Project Administrator. Payments shall be made in
proportion to the Services satisfactorily performed, so that the payments for Services never
exceed the progress percentage noted in the Consultant's Progress Schedule (to be submitted
with each invoice). No mark-up shall be allowed on subcontracted work. In addition to the invoice,
the Consultant shall, for Hourly Rate authorizations, submit a progress report giving the
percentage of completion of the Project and the total estimated fee to completion.
7.3 Approved Additional Services shall be compensated in accordance with the hourly billing
rates set forth in Schedule"C,"attached hereto. Any request for payment of Additional Services
shall be included with a Consultant payment request. No mark-up shall be allowed on Additional
Services(whether sub-contracted or not).
7.4 Approved Reimbursable Expenses shall be paid in accordance with Article 6 hereto, up to
the "Not to Exceed" Reimbursable allowance amount set forth in the Consultant Service Order.
Any request for payment of Reimbursable Expenses shall also be included with Consultant's
payment request. No mark-up shall be allowed on Reimbursable Expenses.
7.5 ESCALATION: The initial hourly rates set forth in Schedule C shall remain constant for
the Initial Term of the agreement. Ninety(90)days prior to expiration of the Initial Term, the City
Manager may consider an adjustment to the preceding year's unit costs for the subsequent year.
Any such adjustments, if any, shall be based on a corresponding increase in the Consumer Price
Index for All Urban Consumers; U.S. City average (1982-84=100), as established by the United
States Bureau of Labor Statistics("CPI"), or material adjustments to the scope or requirements of
the RFQ by the City, including(but not limited to)living wage increases. In the event that the City
Manager determines that the requested increase is unsubstantiated, the Consultant agrees to
perform all duties at the current cost terms.
7.6 No retainage shall be made from the Consultant's compensation on account of sums
withheld by the City on payments to Consultant.
18
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136 •
Contact No. 22-168-02
7.7 METHOD OF BILLING AND PAYMENT. Consultant shall invoice the Project
Administrator in a timely manner, but no more than once on a monthly basis, per project. Invoices
shall identify/include the nature and extent of the work performed; the total hours of work
performed by employee category; and the respective hourly billing rate associated therewith. In
the event sub-consultant work is used,the percentage of completion shall be identified. Invoices
shall also itemize and summarize any Additional Services and/or Reimbursable Expenses. A
copy of the written approval of the Project Administrator for the requested Additional Service(s)
or Reimbursable Expenses)shall accompany the invoice.
Invoices shall be submitted to the City at the following address:
Accounts Payable: pavablesamiamibeachfl.gov
7.7.1 If requested, Consultant shall provide back-up for past and current invoices that
records hours for all work(by employee category), and cost itemizations for
Reimbursable Expenses(by category).
ARTICLE 8.CONSULTANT'S ACCOUNTING AND OTHER RECORDS
8.1 All books,records(whether financial or otherwise),correspondence,technical documents,
and any other records or documents related to the Services and/or Project will be available for
examination and audit by the City Manager,or his/her authorized representatives,at Consultant's
office(at the address designated in Article 15 Notices"]), during customary business hours. All
such records shall be kept at least for a period of three(3)years after Consultant's completion of
the Services. Incomplete or incorrect entries in such records and accounts relating personnel
services and expenses may be grounds for City's disallowance of any fees or expenses based
upon such entries. Consultant shall also bind its subconsultants to the requirements of this Article
and ensure compliance therewith.
ARTICLE 9. OWNERSHIP OF PROJECT DOCUMENTS
9.1 All notes, correspondence, documents, plans and specifications, designs, drawings,
renderings, calculations, specifications, models, photographs, reports, surveys, investigations,
and any other documents(whether completed or partially completed)and copyrights thereto for
Services performed or produced in the performance of this Agreement, or related to the Project,
whether in its native electronic form, paper or other hard copy medium or in electronic medium,
except with respect to copyrighted standard details and designs owned by the Consultant or
owned by a third party and licensed to the Consultant for use and reproduction, shall become the
property of the City. Consultant shall deliver all such documents to the Project Administrator in
their native electronic form, as required in the Consultant Service Order within thirty(30)days of
completion of the Services (or within thirty (30) days of expiration or earlier termination of this
Agreement as the case may be). However,the City may grant an exclusive license of the copyright
to the Consultant for reusing and reproducing copyrighted materials or portions thereof as
authorized by the City Manager in advance and in writing, In addition, the Consultant shall not
disclose, release,or make available any document to any third party without prior written approval
from the City Manager. The Consultant shall warrant to the City that it has been granted a license
to use and reproduce any standard details and.designs owned by a third party and used or
reproduced by the Consultant in the performance of this Agreement. Nothing contained herein
shall be deemed to exclude any document from Chapter 119, Florida Statutes.
19
59
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
9.2 The Consultant is permitted to reproduce copyrighted material described above subject to
prior written approval of the City Manager.
9.3 At the City's option, the Consultant may be authorized, as an Additional Service, to adapt
copyrighted material for additional or other work for the City; however, payment to the Consultant
foraucradaptations will be limited to-an amounii not greater than-50%of-the original fee earned
to'adapt the original copyrighted material to a new site.
9.4 The City shall have the right to modify the Project or any components thereof without
permission from the Consultant or without any additional compensation to the Consultant. The
Consultant shall be released from any liability resulting from such modification.
9.5 The Consultant shall bind all subconsultants to the Agreement requirements for re-use of
plans and specifications.
ARTICLE 10.TERMINATION OF AGREEMENT
10.1 TERMINATION FOR LACK OF FUNDS: The City is a governmental entity and is subject
to the appropriation of funds by its legislative body in an amount sufficient to allow continuation of
its performance in accordance with the terms and conditions of this Agreement. In the event there
is a lack of adequate funding either for the Services or the Project(or both),the City may terminate
this Agreement without further liability to the City.
10.2 TERMINATION FOR CAUSE: The City, through the City Manager, may terminate this
Agreement for cause, upon written notice to Consultant, in the event that the Consultant (1)
violates any provision of this Agreement or performs same in bad faith; (2)unreasonably delays
the performance of the Services or any portion thereof; or(3)does not perform the Services or
any portion thereof in a timely and satisfactory manner. In the case of termination for cause by
the City, the Consultant shall first be granted a thirty (30) day cure period (commencing upon
receipt of the initial written notice of default from the City).
10.2.1 In the event this Agreement is terminated for cause by the City,the City,at its sole
option and discretion, may take over the remaining Services and complete them by
contracting with another consultant(s), or otherwise. The Consultant shall be liable to the
City for any additional cost(s) incurred by the City due to such termination. "Additional
Cost" is defined as the difference between the actual cost of completion of the Services,
and the cost of completion of such Services had the Agreement not been terminated.
10.2.2 In the event of termination for cause by the City,the City shall only be obligated to
pay Consultant for those Services satisfactorily performed and accepted prior to the date
of termination (as such date is set forth in, or can be calculated from, the City's initial
written default notice). Upon payment of any amount which may be due to Consultant
pursuant to this subsection 10.2.2, the City shall have no further liability to Consultant.
10.2.3 As a condition precedent to release of any payment which may be due to
Consultant under subsection 10.2.2, the Consultant shall promptly assemble and deliver
to the Project Administrator any and all Project documents prepared (or caused to be
prepared) by Consultant(including,without limitation,those referenced in subsection 9.1
20
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
hereof). The City shall not be responsible for any cost incurred by Consultant for
assembly,copy,and/or delivery of'Project documents pursuant to this subsection.
M3 TERMINATION FOR CONVENIENCE: in addition to the. City's right to terminate,for
cause,the City through the City Manager.,mayalso terminatethis Agreement,upon fourteen(14)
days prior written notice to Consultant,for convenience•,without cause:,:and without penalty,,when
(in its•s'ole discretion)it deems such termination to be in the best interest of the City. In the event
the City terminates the Agreement for convenience, Consultant shill be compensated for all
Services satisfactorily performed and accepted up to the termination date.(as set.forth inthe City'.s
Written notice), and for Consultant's costs in assembly and delivery to the Project Administrator
of the Project documents(referenced in subsection 10:2.3 above).. Upon payment of any amount
which may be-due to Consultant pursuant this subsection 10':3, the City shall nave no further
liability to Consultant.
10.4 TERMINATION BY CONSULTANT The Consultant may only terminate.this Agreement
for cause, upon thirty(30)days prior written notice to the City, in,the event that.the City Willfully
violates.any provisions of this Agreement or unreasonably delays payment of'#he Services.Dr any
portion thereof.In the event of a termination for cause by Consultant,the City shall pay Consultant
for any.Services satisfactorily performed and accepted up to the date of termination; provided,
however,that the City shall first begranted a thirty,(30)daycure period'(commencing upon receipt
of Consultant's initial.written notice).
16.4,1 The Consultant shall have no right ta terminate this Agreement for convenience,
1,15 IMPLEMENTATION OF TERMINATION: In the event of'termination(Whetherfdr cause
or.roe convenience);:the.Consultant shalliimmediately, upon'receipt of the City's written notice of
termination: (1)stop the performance of Services;(2)place no further orders or issue any other
subcontracts,except for those which may have already been approved,in.writing, by the Project
Administrator, (3),terminate all existing orders and subcontracts; and (4)promptly assemble all
Project documents(for deliVery to the Project Administrator).
ARTICLE It INSURANCE
The Consultant shall maintain the below required irisurahce in effect prior tDawarding the contract
and for the duration of th contract. The maintenance of proper insurance coverage is a material
element of the contract and failure to Maintain or renew coverage may be treated as a material
breach of the contract, which could result in withholding of payments or termination of the
Agreement_
A. Workers'Compensation Insurance for all employees.of the Contractor as required
by Florida Statute Chapter 440 and Employer-Liability Insurance with a limit•of no
less than 000,000 per accident for bodily injury or disease. Should the
Contractor be exempt from this Statute, the Contractor and each employee shall
hold the City harmless from any injury incurred during performance of the Contract..
The exempt contractor shall also submit(i)a written statement detailing the number
of employees and that they are not required to carry Workers' Compensation
insurance and do not anticipate hiring any additional employees during the term of
this contract or(ii)a copy of a Certificate of Exemption.
21
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
B. Commercial General Liability Insurance on an occurrence basis,including products
and completed operations, property damage, bodily injury and personal &
advertising injury with limits no less than $1,000,000 per occurrence, and
$2,000,000 general aggregate. •
C. Automobile Liability insurance-covering-any-automobile,-if-vendor has no owned
automobiles, then coverage for hired and non-owned automobiles, with limit no
less than$1,000,000 combined per accident for bodily injury and property damage.
D. Professional Liability (Errors & Omissions) Insurance appropriate to the
Consultant's profession,with limit no less than $1,000,000.
11.1 The maintenance of proper insurance coverage is a material element of the Agreement
and failure to maintain or renew coverage may be treated.as a material breach of the Agreement,
which could result in withholding of payments or termination of the Agreement.
11.2 Additional Insured - City of Miami Beach must be included by endorsement as an
additional.insured with respect to all liability policies (except Professional Liability and Workers'
Compensation)arising out of work or operations performed on behalf of the Consultant including
materials, parts, or equipment furnished in connection with such work or operations and
automobiles owned, leased; hired or borrowed in the form of an endorsement to.the Consultant's
insurance.
11.3 Notice of Cancellation. - Each insurance policy required above shall provide that
coverage shall not be cancelled, except with.notice to the City of Miami Beach do EXIGIS
Insurance Compliance Services.
11.4 Waiver of Subrogation - Consultant agrees to obtain any endorsement that may be
necessary to affect the waiver Of subrogation on the coverages required. However,this provision
applies regardless of whether the City has received a waiver of subrogation endorsement from
the insurer.
11.5 Acceptability of Insurers - Insurance must be placed with insurers with a current A.M.
Best rating of A:VII or higher. If not rated, exceptions may be made`for members of the Florida
Insurance.Funds (i.e. FWCIGA, FAJUA). Carriers may also be considered if they are licensed
and authorized to do insurance business in the State of Florida.
11.6 Verification of Coverage- Consultant shall furnish the City with original certificates and
amendatory endorsements, or copies of the applicable insurance language, effecting coverage
required by this contract. All certificates and endorsements are to be received and approved by
the City before work commences. However,failure to obtain the required documents prior to the
work beginning shall not waive the Consultant's obligation to provide them. The City reserves the
right to require complete, certified copies of all required insurance policies, including
endorsements, required by these specifications, at any time.
CERTIFICATE HOLDER ON ALL COI MUST READ:
CITY OF MiAMI BEACH
c/o EXIGIS Insurance Compliance Services
22
DocuSign Envelope ID:038F080E-52C7-4774-A746-11 C4DF95D136
Contact No. 22-168-02
P.O. Box 947
Murrieta,,CA 92564
Kindly submit all certificates of insurance,endorsements,exemption letters to our servicing agent,
EXIGIS, at:
Certificates-miamibeachariskworks.com
11.7 Special Risks or Circumstances-The City of Miami Beach reserves the right to modify
these requirements, including limits, based on the nature of the risk, prior experience, insurer,
coverage, or other special circumstances.
Compliance with the foregoing requirements shall not relieve the vendor of his liability and
obligation under this section or under any other section of this agreement.
ARTICLE 12.INDEMNIFICATION AND HOLD HARMLESS
12.1 To the fullest extent permitted by Section 725.08, Florida Statutes, the Consultant shall
indemnify and hold harmless the City and its officers, employees, agents, and instrumentalities,
from liabilities, damages, losses, and costs; including, but not limited to, reasonable attorneys'
fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of
the Consultant and other persons employed or utilized by the Consultant in the performance of
this Agreement.
The Consultant shall pay all claims and losses in connection therewith and shall investigate and
defend all claims,suits,or actions of any kind or nature in the name of the City,where applicable,
including appellate proceedings, and shall pay all costs, judgments, and attomey's fees which
may issue thereon. Consultant expressly understands and agrees that any insurance protection
required by this Agreement or otherwise provided by Consultant shall in no way limit its
responsibility to indemnify, keep, and save harmless and defend the City or its officers,
employees,agents, and instrumentalities as herein provided.
12.2 The Consultant agrees and recognizes that the City shall not be held liable or responsible
for any claims which may result from any negligent, reckless, or intentionally wrongful actions,
errors or omissions of the Consultant in which the. City participated either through review or
concurrence of the Consultant's actions. In reviewing,approving or rejecting any submissions by
the Consultant, or other acts of the Consultant, the City in no way assumes or shares any
responsibility or liability of the Consultant(including, without limitation its subconsultants and/or
any registered professionals (architects and/or engineers)under this Agreement).
ARTICLE 13. ERRORS AND OMISSIONS
13.1 ERRORS AND OMISSIONS: It is specifically agreed that any construction changes
categorized by the City as caused by an error, an omission, or any combination thereof in the
Consultant's performance of the Services will constitute an additional cost to the City that would
not have been incurred without the error. The damages to the City for errors, omissions or any
combinations thereof shall be calculated as the total cost of any damages or incremental costs to
the City resulting out of the errors or omissions by the Consultant, including, without limitation,
the direct, indirect and/or consequential damages resulting from the Consultant's errors and/or
23
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
omissions or any combination thereof.
Damages shall include delay damages caused by the error,omission,or any combination thereof.
Should the Consultant disagree that all or part of such damages are the result of errors,omissions,
or any combination thereof,the Consultant may appeal this determination,in writing,to the Project
Administrator. The Project Administrator's decision on ail claims,questions and disputes shall be
final;Conclusive;and bindingupor thhe parties-hereto-unless such determination-is clearly arbitrary
or unreasonable. In the event that the Consultant does not agree with the decision of the Project
Administrator, the Consultant shall present any such objections, in writing, to the City Manager.
The Project Administrator and the Consultant shall abide by the decision of the City Manager.
This paragraph does not constitute a waiver of any party's right to proceed in a court of competent
jurisdiction after the above administrative remedies have been exhausted.
ARTICLE 14. LIMITATION OF LIABILITY
The City desires to enter into this Agreement only if in so doing the City can place a limit on its
gility for any cause of action for money-damages due town alleged breach by the City of this
; reement, so that its liability for any such breath never exceeds the'not to exceed"amount of
die Tee:paid to Consultant under this Agreement, less any amount(s)actually paid to Consultant
hereunder. Consultant hereby expresses its willingness to enter into. this Agreement, with
Consultant's recovery from the City for any damages for action for breach of contract to be limited
to Consultant's "not to exceed" fee under this Agreement, less any amount(s) actually paid by
the City to the Consultant hereunder.
Accordingly, and notwithstanding any other term or condition-of this Agreement, Consultant
hereby agrees that the City shall not be liable to Consultant for money damages due to an alleged
breach by the City of this Agreement, in an amount in excess of:the not to.exceed amount" of
Consultant's fees under this Agreement, which amount shall be reduced by any amount(s)
actually paid by the City to Consultant hereunder.
Nothing contained in this subsection, or elsewhere in this Agreement, is in any way intended to
be a waiver of the limitation placed upon City's liability, as set forth in Section 768.28, Florida
Statutes.
ARTICLE 15, NOTICE
Until changed by notice in writing, all such notices and communications shall be addressed as
follows:
All written notices given to City by Consultant shall be addressed to:
City Manager's Office
City of Miami Beach
1700 Convention Center Drive
Miami Beach, Florida 33139
Attn: Aline T. Hudak, City Manager
Email: a linathudakC3.miamibeachfl.gov
24
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-468-02
With a copy to:
Capital frnprOvernent Projects•Qfftce
Ctty of Miami Beach
1100 Convention Center Drive,
Miami beach, Fldrida 33139
Attri: Maria 1=1„ Ceuta, Divition Director
Capital Improvement Projects Office
Ph:305-03-7071 Ext 6431
marlacerneferniarnibeachfl.ociv
All Written nótióe ivefltd the Consultant from the:City Shall be addreated toe.
PAP CdnsOltIng,
5959 Blue Lagoon Drive„Suite 410.
ri.:33126
Paltn:Andrew Pierce, PE
.11::305-265-6400-
Erna:anierce@eaCconaultcOrn
All notices mailed eledrettically to either party shall be deemed to be Sufficiently tranSmitted.
ARTICLE 16.CONSULTANT'S COMPLIANCE.WITH FLORIDA PUBLIC RECORDS LAW
16.1 Consultant shall comply with Florida Public Recards law underChapter 119,.Florida
Statutes,es maybe amended from time to time:
16.2, The term"public records"shall have the meaning set forth in Section 119.011(12),which
means all docurnents,papers,letters,maps,bOoks,tapes photographs,films,sound recordings,
data processing software, or other ittateria regardless of the physical form, characteristics, or
Means of transmission, made or received pursuant to law or ordinance Cr in connection with the
transaction of official business of the City.
16.3 Pursuant to Section 119,0701 Of the Florida Statt_ftek if the Consultant meets the definition
of'Consultant'as defined in Section 119.0701(1)K the Consultant Shalt
(a) Keep and maintain public records required by the City to perform the service,
(b) Upon request from the City's custodian'of-public records, provide the City with a
copy of the requested records or allow the records to be inspected or copied within
a reasonable time at a cost that does not exceed the cost provided in Chapter 119,
'Florida Statiltes or as otherwise'provided by law;
(a) Ensure that public records that are exempt or Confidential and exempt from public
records disclosure requirements are not disclosed, except as authorized by law,
for the duration of the contract term and following completion of the Agreement if
the Consultant does not transfer the records to the City,
Upon completion of the Agreement, transfer, at no Cost to the City, all public
records in possession of the Consultant or keep and maintain public records
required by the City to perform the service. if the Consultant transfers all. public
25
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No. 22-168-02
records to the City upon completion of the Agreement,the Consultant shall destroy
any duplicate public records that are exempt or confidential and exempt from public
records disclosure requirements. If the Consultant keeps and maintains public
records upon completion of the Agreement, the Consultant shall meet all
applicable requirements for retaining public records. All records stored
electronically must be provided to the City, upon request from the City's custodian
of-public-records, in a format that is"compatiblewith_the_information.#echnology
systems of the City.
16.4 REQUEST FOR RECORDS; NONCOMPLIANCE.
16.4.1 A request to inspect or copy public records relating to the City's contract for
services must be made directly to the City. lithe City does not possess the requested
records,the City shall immediately notify the Consultant of the request, and the
Consultant must provide the records to the.City or allow the records to be inspected or
copied within a reasonable time.
16.4.2 Consultant's failure to comply with the City's request for records shall constitute
a breach of this Agreement, and the City, at its sole discretion, may: (1)
unilaterally terminate the Agreement; (2)avail itself of the remedies set forth
under the Agreement; and/or(3)avail itself of any available remedies at law or
in equity.
16.4.3 A Consultant who fails to provide the public records to the City within a
reasonable time may be subject to penalties under s. 119.10.
16.5 CIVIL ACTION.
16.5.1 If a civil action is filed against a Consultant to compel production of public records
relating to the City's contract for services, the court shall assess and award against the
Consultant the reasonable costs of enforcement, including reasonable attorneys'fees, if:
(a) The court determines that the Consultant unlawfully refused to comply with
the public records request within a reasonable time; and
(b) At least 8 business days before filing the action, the plaintiff provided written
notice of the public records request, including a statement that the Consultant
has not complied with the request, to the City and to the Consultant.
16.5.2 A notice complies with subparagraph(16.5.1)(b)if it is sent to the City's custodian
of public records and to the Consultant at the Consultant's address listed on its contract
with the City or to the Consultants registered agent. Such notices must be sent by
common carrier delivery service or by registered,Global Express Guaranteed,or certified
mail,with postage or shipping paid by the sender and with evidence of delivery, which
may be in an electronic format.
16.5.3 A Consultant who complies with a public records request within 8 business days
after the notice is sent is not liable for the reasonable costs of enforcement.
16.6 IF THE CONSULTANT HAS QUESTIONS REGARDING THE
APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE
CONSULTANT'S DUTY TO PROVIDE PUBLIC RECORDS
26
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
RELATING TO THIS AGREEMENT, CONTACT THE CUSTODIAN
OF PUBLIC RECORDS AT:
CITY OF MIAMI BEACH
ATTENTION: RAFAEL E. GRANADO; CITY CLERK
1700 CONVENTION CENTER DRIVE
MIAMI BEACH, FLORIDA 33139
E-MAIL: .RAFAELGRANADOt MIAMIBEACHFL.GOV
PHONE: 305-673-7411
ARTICLE 17. INSPECTOR GENERAL AUDIT RIGHTS
17.1 Pursuant to Section 2-256 of the Code of the City of Miami Beach, the City has
established the Office of the Inspector General which may, on a random basis, perform reviews,
audits, inspections, and investigations on all City contracts, throughout the duration of said
contracts. This random audit is separate and distinct from any other audit performed by or on
behalf of the City.
17.2 The Office of the Inspector General is authorized to investigate City affairs and
empowered to review past, present and proposed City programs, accounts, records, contracts
and transactions. In addition, the Inspector General has the power to subpoena witnesses,
administer oaths, require the production of witnesses and monitor City projects and programs.
Monitoring of an existing City project or program may include a report concerning whether the
project is on time,within budget and in conformance with the contract documents and applicable
law. The Inspector General shall have the power to audit, investigate, monitor, oversee, inspect
and review operations, activities, performance and procurement process including but not limited
to project design, bid specifications, (bid/proposal) submittals, activities of the Consultant, its
officers, agents and employees, lobbyists, City staff and elected officials to ensure compliance
with the contract documents and to detect fraud and corruption. Pursuant_to Section 2-378 of the
City Code, the City is allocating a percentage of its overall annual contract expenditures to fund
the activities and operations of the Office of Inspector General.
17.3 Upon ten(10)days written notice to the Consultant, the Consultant shall make all
requested records and documents available to the Inspector General for inspection and copying.
The Inspector General is empowered to retain the services of independent private sector auditors
to audit, investigate, monitor, oversee, inspect and review operations activities, performance and
procurement process including but not limited to project design, bid specifications, (bid/proposal)
submittals, activities of the Consultant its officers,agents and employees, lobbyists, City staff and
elected officials to ensure compliance with the contract documents and to detect fraud and
corruption.
17.4 The Inspector General shall have the right to inspect and copy all documents and records
in the Consultant's possession,custody or control which in the Inspector General's sole judgment,
pertain to performance of the contract, including, but not limited to original estimate files, change
order estimate files, worksheets, proposals and agreements from and with successful
subconsultants and suppliers, all project-related correspondence, memoranda, instructions,
financial documents, construction documents, (bid/proposal) and contract documents, back-
27
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
change documents, all documents and records,which involve cash, trade or volume discounts,
insurance proceeds,rebates,or dividends received,payroll and personnel records and supporting
documentation for the aforesaid documents and records.
17.5 The Consultant shall make available at its office at all reasonable times the records,
materials, and other evidence regarding the acquisition(bid preparation)and performance of this
g ,e ti t p .,:1ucti tit th -p years-after--final-paument undder
Agreement,for examination,-audit-or audir rur re rvuu�[[L'iirilnurcr rco ��
this Agreement or for any longer period required by statute or by other clauses of this Agreement.
In addition:
(a) If this Agreement is completely or partially terminated, the Consultant shall make
available records relating to the work terminated until three (3) years after any
resulting final termination settlement; and
(b) The Consultant shall make available records relating to appeals or to litigation or the
settlement of claims arising under or relating to this Agreement until such appeals,
litigation, or claims are finally resolved.
17.6 The provisions in this section shall apply to the Consultant, its officers, agents,
employees, subconsultants and suppliers.The Consultant shall incorporate the provisions in this
section in all subcontracts and all other agreements executed by the Consultant in connection
with the performance of this Agreement.
17.7 Nothing in this section shall impair any independent right to the City to conduct audits or
investigative activities. The provisions of this section are neither intended nor shall they be
construed to impose any liability on the City by the Consultant or third parties.
ARTICLE 18.MISCELLANEOUS PROVISIONS
18.1 VENUE AND WAIVER OF JURY TRIAL: This Agreement shall be governed by, and
construed in accordance with, the laws of the State of Florida, both substantive and remedial,
without regard to principles of conflict of laws. The exclusive venue for any litigation arising out
of this Agreement shall be Miami-Dade County, Florida, if in state court, and the U.S. District
Court, Southern District of Florida, in federal court. BY ENTERING INTO THIS AGREEMENT,
CONSULTANT AND CITY EXPRESSLY WAIVE ANY RIGHTS EITHER PARTY MAY HAVE TO
A TRIAL BY JURY OF ANY CIVIL LITIGATION RELATED TO, OR ARISING OUT OF, THIS
AGREEMENT.
18.2 EQUAL OPPORTUNITY EMPLOYMENT GOALS: Consultant agrees that it will not
discriminate against any employee or applicant for employment for work under this Agreement
because of race, color, national origin, religion,sex,gender identity,sexual orientation,disability,
marital or familial status, or age, and will take affirmative steps to ensure that applicants are
employed and employees are treated during employment without regard to race, color, national
origin, religion, sex,gender identity,sexual orientation, disability, marital or familial status,or age.
18.3 PUBLIC ENTITY CRIMES ACT: In accordance with the Public Entity Crimes Act(Section
287.133„Florida Statutes), a person or affiliate who is a consultant,who has been placed on the
convicted vendor list following a conviction for a public entity crime may not submit a bid on a
28
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No. 22-168-02
contract to provide any goods or services to the City, may not submit a bid on a contract with the
City for the construction or repair of a public building or public work, may not bid on leases of real
property to the City, may not be awarded or perform work as a Consultant, supplier,
subconsultant, or subconsultant under a contract with the City, and may not transact business
with the City in excess of the threshold amount provided in Section 287.017, Florida Statutes,for
Category Two, for a period of 36 months from the date of being placed on the convicted vendor
list. For violation of this subsection by Consultant, City shall have the right to terminate the
Agreement without any liability to City, and pursue debarment of Consultant
18.4 NO CONTINGENT FEE: Consultant warrants that it has not employed or retained any
company or person, other than a bona fide employee working solely for Consultant, to solicit or
secure this Agreement, and that it has not paid or agreed to pay any person, company,
corporation, individual or firm,other than a bona fide employee working solely for Consultant,any
fee, commission, percentage, gift, or other consideration contingent upon or resulting from the
award or making of this Agreement. For the breach or violation of this subsection, City shall have
the right to terminate the Agreement, without any liability or, at its discretion, to deduct from the
contract price(or otherwise recover)the full amount of such fee,commission, percentage, gift, or
consideration.
18.5 LAWS AND REGULATIONS:
18.5.1 The Consultant shall, during the Term of this Agreement, be governed by all
Applicable Laws which may have a bearing on the Services involved in the Project.
18.5.2 Project Documents. In accordance with Section 119.071 (3) (b)(2), Florida
Statutes,entitled"General exemptions from inspecting or copying public records,"
all building plans, blueprints, schematic drawings, and diagrams, including draft,
preliminary,and final formats,are exempt from the provisions of Section 119.07(1),
Florida Statutes(inspection and copying of public records), and s.24(a), Article I
of the State Constitution. Information made exempt by this paragraph, with prior
written approval from the City Manager, may be disclosed to another entity to
perform its duties and responsibilities; to a licensed architect, engineer, or
Consultant who is performing work on or related to the Project;or upon a showing
of good cause before a court of competent jurisdiction. The entities or persons
receiving such information shall maintain the exempt status of the information.
18.5.2.1 In addition to the requirements in this subsection 18.5.2,the Consultant
agrees to abide by all applicable Federal, State, and City procedures,
as may be amended from time to time, by which the documents are
handled, copied, and distributed which may include, but is not limited
to, each employee of Consultant and subconsultants that will be
involved in the Project being required to sign an agreement stating that
they will not copy, duplicate, or distribute the documents unless
authorized by the City Manager, in writing.
18.5.2.2 The Consultant and its subconsultants agree in writing that the Project
documents are to be kept and maintained in a secure location.
18.5.2.3 Each set of the Project documents are to be numbered and the
whereabouts of the documents shall be tracked at all times.
29
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No. 22-168-02
18.5.2.4 A log is developed to track each set of documents logging in the date,
time,and name of the individual(s)that work on or view the documents.
18.5.3. E-Verify,
1 o r 3 1 Consultant-t shalt o ply- Section 448.095, Florida_ Statuutes,
I O.aJ. 1 VC/I L7u1 O71 �jl �� comply -with - ,
"Employment Eligibility"("E-Verify Statute"), as may be amended from
time to time. Pursuant to the E-Verify Statute,commencing on January
1, 2021., Consultant shall register with and use the E-Verify system to
verify the work authorization status of all newly hired employees during
the Teo of the Agreement. Additionally, Consultant shall expressly
fair zany subconsultant performing work or providing services
flUrtudgi to the Agreement to likewise utilize the U.S. Department of
Homeland Security's E-Verify system to verify the employment
eligibility of all new employees hired by the subconsultant during the
contract Term. If Consultant enters into a contract with an approved
subconsultant, the subconsultant must provide,the Consultant with an
affidavit stating that the subconsultant does not employ, contract with,
or subcontract with an unauthorized.alien. Consultant shalt maintain a
copy of such affidavit for the duration of the Agreement or such other
extended period as may be required under this Agreement.
18.5.3.2 TERMINATION RIGHTS.
18.5.3.2.1 If the City has a good faith belief that Consultant has
knowingly violated Section 448,09(1), Florida Statutes, the City shall
terminate this Agreement with Consultant for cause, and the City shall
thereafter have or owe no further obligation or liability to Consultant.
1.8.3.5.2.2 If the City has a good faith belief that a subconsuttant
has knowingly violated the foregoing Subsection 18.5.3.1 but the
Consultant otherwise complied with such subsection, the City will
promptly notify the Consultant and order the Consultant to immediately
terminate the Agreement with the subconsultant. Consultant's failure
to terminate a subconsultant shall be an event of default under this
Agreement, entitling City to terminate the Consultant's contract for
cause.
18.5.3.2.3 A contract terminated under the foregoing Subsection
18.5.3.2.1 or 18.5.3.2.2 is not in breach of contract and may not be
considered as such.
18.5.3.2.4 The City or Consultant or a subconsultant may file an
action with the Circuit or County Court to challenge a termination under
the foregoing Subsection 18.5.3.2.1 or 18.5.3.2.2 no later than 20
calendar days after the date on which the contract was terminated.
18.5.3.2.5 If the City terminates the Agreement with Consultant under
the foregoing Subsection 18.5.3.2.1 Consultant may not be awarded a
public contract for at least 1 year after the date of termination of this
30 9)
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Cont ptg 22-168-02
Agreement,
18.5.3.2.6 Consultant is liable for any additional costs incurred by the
City as a result of the termination of this Agreement under this Section
18.5.3.
18.6 FORCE MAJEURE:
18.6.1 A "Force Majeure" event is an event that (i) in fact causes a delay in the
performance of the Contractor or the City's obligations under the Agreement, and (ii) is
beyond the reasonable control of such party unable to perform the obligation, and (iii) is
not due to an intentional act, error, omission, or negligence of such party, and (iv) could
not have reasonably been foreseen and prepared for by such party at any time prior to the
occurrence of the event. Subject to the foregoing criteria, Force Majeure may include
events such as war, civil insurrection, riot, fires, epidemics, pandemics, terrorism,
sabotage, explosions, embargo restrictions, quarantine restrictions, transportation
accidents, strikes, strong hurricanes or tornadoes, earthquakes, or other acts of God
which prevent performance. Force Majeure shall not include technological impossibility,
inclement weather, or failure to secure any of the required permits pursuant to the
Agreement.
18.6.2 If the City or Contractor's performance of its contractual obligations is prevented
or delayed by an event believed by to be Force Majeure, such party shall immediately,
upon learning of the occurrence of the event or of the commencement.of any such delay,
but in any case within fifteen (15) business days thereof, provide notice: (i) of the
occurrence of event of Force Majeure,(ii)of the nature of the event and the cause thereof,
(iii)of the anticipated impact on the Agreement,(iv)of the anticipated period of the delay,
and(v)of what course of action such party plans to take in order to mitigate the detrimental
effects of the event.The timely delivery of the notice of the occurrence of a Force Majeure
event is a condition precedent to allowance of any relief pursuant to this section; however,
receipt of such notice shall not constitute acceptance that the event claimed to be a Force
Majeure event is in fact Force Majeure, and the burden of proof of the occurrence of a
Force Majeure event shall be on the requesting party.
18.6.3 The City may, in its sole and absolute discretion, make amendment or equitable
adjustment in the contract terms and conditions and/or pricing to address very limited
unforeseen circumstances outside of the successful Bidder's control relating to certain
supply chain issues and extreme market volatility. The City may, but shall have no
obligation to consider or otherwise approve an adjustment,where pricing or availability of
supply is affected by extreme or unforeseen volatility in the marketplace satisfying, at a
minimum, all of the following criteria: 1) the volatility is due to causes wholly beyond the
successful Bidder's control; 2)the volatility affects the entire marketplace or industry, not
just the particular successful Bidder's source of supply; 3) the effect on pricing or
availability of supply is substantial; and 4)the volatility so affects the successful Bidders
that continued performance of the Contract would result in an excessive or unreasonable
substantial loss or financial hardship to the Bidders, such as, for example, an event
implicating insolvency or bankruptcy. Any adjustment would require irrefutable evidence
and written approval by the Director of Purchasing Services. For the avoidance of doubt,
this section does not in any way alter or affect the allocation of risk between the City and
31
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No. 22-168-02
the Bidders pursuant to the Contract, or Bidder's assumption_of all risks relating to its
performance in accordance with the Contract terms.
18.6.4 No party hereto shall be liable for its failure to carry out its obligations under the
Agreement during a period when such party is rendered unable, in whole or in part, by
Force Majeure to carry out such obligations. The suspension of any of the obligations
under_this_Agreement_due_to a_Force_Majeure event shall be of no greater scope and no
longer duration than is required.The party shall use its reasonable best efforts to continue
to perform its obligations hereunder to the extent such obligations are not affected or are
only partially affected by the Force Majeure event, and to correct or cure the event or
condition excusing_performance and otherwise to remedy its inability to perform to the
extent its inability to perform is the direct result of the Force Majeure event with all.
reasonable dispatch.
18.6.5 Obligations pursuant to the Agreement that arose before the occurrence of a Force
Majeure event, causing the suspension of performance, shall not be excused as a result
of such occurrence unless such occurrence makes such performance not reasonably
possible. The obligation to pay money in a timely manner for obligations and liabilities
which matured prior to the occurrence of a Force Majeure event shall not be subject to the
Force Majeure provisions.
18.6.6 Notwithstanding any other provision to the contrary herein, in the event of a Force
Majeure occurrence,the City may,at the sole discretion of the City Manager,suspend the
City'spayment obligations under the Agreement,and may take such action without regard
to the notice requirements herein. Additionally,in the event that an event of Force Majeure
delays a party's performance under the Agreement for a time period greater than thirty
(30) days, the City may, at the sole discretion of the City Manager, terminate the
Agreement on a given date, by giving written notice to Consultant of such termination. If
the Agreement is terminated pursuant to this Section, Consultant shall be paid for any
Services satisfactorily performed up to the date of termination; following which the City
shall be discharged from any and all liabilities, duties,and terms arising out of,or by virtue
of,this.Agreement. In no event will any condition of Force Majeure extend this Agreement
beyond its stated term. Any time extension shall be subject to mutual agreement and shall
not be cause for any claim by the Consultant for extra compensation, unless Additional
Services are required and approved pursuant to Article 5 hereof.
18.7 CORRECTIONS TO CONTRACT DOCUMENTS: If applicable to the performance of
Consultant's.Services,the Consultant shall prepare,without added compensation, all necessary
supplemental documents to correct errors, omissions, and/or ambiguities which may exist in the
Contract Documents prepared, by Consultant, including documents prepared by its
subconsultants,.Compliance with this subsection shall not be'construed to relieve the Consultant
from any liability resulting from any such errors, omissions, and/or ambiguities in the Contract
Documents and other documents or Services related thereto.
18.8 ASSIGNMENT:The Consultant shall not assign,,transfer or convey this Agreement to any
other person,firm,association or corporation, in whole or in part,without the prior written consent
of the City Commission, which consent, if given at all, shall be et the Commission's sole option
and discretion. However,the Consultant will be permitted to cause portions of the Services to be
performed by subconsultants, subject to the prior written approval of the City Manager.
32 9)
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact NO. 22-168-02
18.0 SUCCESSORS AND ASSIGNS: The.Consultant and the City each binds hirnself/hertelf,
ihis/her partners, successors, legal representatives and assigns to the other party of the
Agreethent and to the partners,successors, legal representatives,and assigns of such party in.
respect SO all covenants of this Agreement. The Consultant Shalt afford the City(through the City
Commission)the opportunity to approve or reject all proposed assignees, successors or other
changes in the ownership structure and dernpotition of the Consultant Failure to do so
constitutes a breach of this Agreement by thoCensUftant
18,4 PROVISION OF ITEMS NECESSARY TO'COMPLETE SERVICES: In the performance
Of the Services prescribed herein, it shall be the responsibility of the Consultant to provide all
salaries,wages, materials, equipment, subconsultants, and other purchased services, eta,as
necessary to complete said Services..
1,11.10 INTENT OF AGREEMENT:
111.10.1 The intent of the Agreement is for the Consultant to provide all necessary items
for the proper completion of the ServiCes.The Consultant shall perform,as Basic Services,
such incidental work which may not be specifieally referenced, as necessary to complete
the Project..
18.11).2 This Agreement•is for the benefit of the parties Only and it does not grant rights
to a third-party beneficiary,to any person, nor does it authorize anyone not a party to the
Agreement to maintain a suit for personal injuries, professional liability, or property
damage pursuant to the tents or prcivisiOns Of the Agreement
18.103 No acceptance; order.Payment or certificate of or by the City,or its employees
or agents shall either stop the City from asserting any rights or operate as a waiver of any
provisions hereof or of any power or right herein reserved to the City or of any rights to
damages herein provided.
1'8.10.4 This dcicUment incorporates and includes aliprier negetiatiens,correspondence,
conversationsi.agreements,or understandings applicable to the matters contained herein;
and the parties agree that there are no commitments, agreements, or understandings
concerning the subject matter of this Agreement that are not contained in this document:
Accordingly,the parties agree that no deviation from the terms hereof shall be predicated
upon any prior representations or agreements whether oral or written, It is further agreed
that no modification, amendment or alteration in the terms or conditions contained herein
shall be effective unless memorialized in written document approval and executed with
the same formality and of equal dignity hereWith,
•
33
DocuSign Envelope ID:038F080E-52C7-4774A746-11C4DF95D136
Contact No.22-168-02
•
IN WITNESS WHEREOF,the parties hereto have hereunto caused these presents to be
signed in their names by their duly authorized officers and principals,attested by their respective
witnesses and City Clerk on the day and year first hereinabove written.
Attest CITY OF MIAMI PEACH:
"^—DocuSigned by:
f:AV'i" tl tkANADO, CITY CLERK AL.I T. HUDAK, CI Y MANAGER
2/14/2023 18:58 EST
Date
APPROVED AS TO
FORM&LANGUAGE
&FOR E.. CUTION
941)16' 4
_r i City Attorney '•' Date
t
CONSULTANT:
EAC CONSLTING SERVICES, INC.
Signature
Andrew Pierce, PE/Vice President
Print Name
Date
01/27/2023
34
DocuSign Envelope ID:038F080E-52C7-4774-A746-11 C4DF95D136
Contact No.22468-02
SCHEDULE A
SCOPE OF SERVICES
The Consultant's Basic Services that may be provided under theAgreement entered into pursuant to this
RFQ shall(at a minimum)consistof,but net be limited to,the following:
1, Administer the Construction Contract and monitor and inspect the work performed by the Contractor
such that.the Project is constructed in reasonable conformity With the'plans, specifications, and
special.provisionsof the Construction Contract.
2. Resident Engineering Services-Coordinate the Construction Contract administration activities of all
parties other than the Contractor involved in completing the construction project. Services shall
include maintaining the required surveillance of Contractor activities, interpreting plans,
specifications, and special provisions for the Construction Contract. Maintain complete, accurate
(ecords of all activities and events relating to the Project and properly document all project changes.
Ttie following'servicesshah be,perf.ormed:•
a) General Coordination:TheConsultant'shall communicate daily or periodically with the City,the
Design Consultant, and Contractor, as needed, They shall report on concerns related to the
construction effort and activities, In addition,the Consultant shall also coordinate with the Public
information Officer(PIO)Where..notifcations such as utility outages,road closures,etc.,may be
required.The:Consultant,shall monitor and verify that the Contractor has made the required
notifications tp the utility owners, residents,and.businesses as may be.necessaty,
b) Estimating,Services e Provide accurate cost estimates and Schedules to avoid cost overruns
and schedule slips. Prepare.cost estimates and schedules by helping manage resources and
supporting assessment and decision:-makjng.Services may encompass a wide range of cost-
related aspects of engineering and program management, particularly cost estimating, cost
analysis/cost assessment,.design-to-cost,schedule analysislpianning,and risk assessment..
c) `Value Engineering,Meetnngs: The Consultant shall be:"expected to attend, participate; and
provide cost estimating information at Value Engineering meetings between the City;the Design
Consultant,and the Contractor for the Project.
d) Resident's .information Meetings;. The :Consultant shall be expected to attend, address
residents' concerns, participate, produce meeting minutes, and take a lead role in Resident
information Meetings with the City for the Project.
e) Pre-Construction°Meetings:The Consultant shall be expected to attend, participate,produce
meeting minutes and' take a lead idle in Pre-Construction Meetings with the City, Design
Consultant,,and Contractor for the Project. The Pre-construction.Meeting shall be scheduled
once the City*lies the first Notice-to-Proceed to the..Contractor.
Weekly Construction Progress Meetings:The Consultant shall attend,participate and take a
lead role in Weekly.construction project meetings with the City, PIG, Design Consultant, and
35
DocuSign Envelope ID:038F080E-52C7-4774A746-11C4DF95D136
Contact No.22-168-02
Contractor on the Project. These meetings shall serve as forums to review the status of
construction progress,discuss construction issues,schedule and/or cost concerns,and potential
changes or conflicts, review the status of shop drawing submittals and Construction Document
clarifications and interpretations and resolve problems before they become critical. Consultant
shall prepare weekly meeting minutes and distribute to all meeting attendees, review the two-
week look ahead provided by the Contractor and provide comments or objections to written
statements within the specified timeframe.The Consulfant§hall preparre detaird weekly reports
that describe the construction activities, progress, incidents, and issues that have occurred on
the construction site and distribute them to the attendees in advance of the weekly construction
progress meetings.
g) Field Observations: The Consultant shall conduct field observations daily, throughout the
duration of construction. Field observations may be provided jointly by the City and the
Consultant. If and when necessary, the City shall provide part-time construction inspectors for
the duration of the Project. The role of the City's construction inspectors shall be limited. The
Consultant shall be present at the construction site daily during the Project's construction phase
and shall be expected to be available,as needed,throughout the Contractor's workday.
h) Environment and Sustainability:
Stormwater Permit - Verify that the Contractor conducts inspections, prepares reports, and
monitors all stormwater pollution prevention measures associated with the Project. For each
project that requires the use of the National Pollutant Discharge Elimination System (NPDES)
General Permit, the inspector (at least one) should have completed the "Florida Stormwater,
Erosion, and Sedimentation Control Training and Certification Program for Inspectors and
Contractors."The Consultant's inspector shall be familiar with the requirements outlined in the
FEDERAL REGISTER, Vol. 87, No. 15, Monday, January 24, 2022, pages 3522 to 3532
°National Pollutant Discharge Elimination,System(NPDES)2022 Issuance of General Permit for
Stormwater Discharges From Construction Activities" and 62-621.300 F.A.C. The City's
regulations for sediment and erosion control and pollution prevention must be followed
regardless of NPDES General Permit status(See City of Miami Beach Municipal Code,Chapter
46,Article X).
Construction and Demolition Debris Management-The consultant shall help ensure proper
construction and demolition(C&D)debris management.
i) Specialty Design Consultant Site Visits:The Consultant shall monitor the number of specialty
site visits requested by the Contractor or City and conducted by the Design Consultant When it
becomes evident that a specialty site visit from the design Engineer of Record (EOR) shall be
required, the Consultant shall notify the EOR to discuss and schedule a mutually acceptable
time for meeting at the construction site.
j) Daily Reports: The Consultant shall prepare daily reports on the same date as construction
occurs to record the daily performance of the Contractor as well as other significant construction-
related matters. The Consultant shall upload daily reports to e-Builder m, the City's document
management system.At the end of each day or the beginning of the following day,the Consultant
36
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No. 22-168-02
shall forward the original daily reports to the City for review.The Consultant shall maintain and
electronically file of the daily reports for reference.The daily reports shall include records of when
. the Contractor is on the job-site,general field observations,weather conditions,change orders,
changed conditions, list of job site visitors, daily drilling and testing activities, testing results,
testing observations, and records of the outcome of tests and inspections. At a minimum, the
daily reports shall contain the following information:
• Weather and general site conditions
• Contractor's workforce counts by category and hours worked
• Description of Work performed,including location
• Equipment utilized
• Names of visitors to the jobsite and reason for the visit
• Tests made and results
• Construction difficulties encountered and remedial measures taken
• Significant delays encountered and apparent reasons why
• Description of(potential)disputes between the Contractor and City
• Description of(potential)disputes between the Contractor and residents
• Summary of additional directions that may have been given to the Contractor
• Detailed record of materials,equipment, and labor used in connection with extra work, or
where there is reason to suspect that the Contractor may submit a claim or request for
Change Order
• Summary of any substantive discussions held with the Contractor and/or City
• Summary of nonconforming work referenced to corresponding Non-Compliance Notice
• A log of photographs taken
k) Photographic Record: Consultant shall provide a y,pt9t9graahic r pr .,of the overall
construction progress, beginning with pre-construction:do imenl on .fa,)iot _bwith ongoing
construction documentation, and ending with post-constnicfion dOcurnentatTon7Photographs
shall be digital snapshot type taken to define the progress of the Project and shall be filed
electronically by month in e-BuilderTM, the City's document management system, labeled by
date, time, and location. The Consultant shall upload all photos to the e-BuilderT'" document
management system on a weekly basis.
I) Adherence to Construction Documents: The Consultant shall review materials and
workmanship of the projects and report to the City any deviations from the Construction
Documents that may come to the Consultant's attention. Consultant shall determine the
acceptability of the work and materials and, in concert with the Design Consultant (as
necessary), make recommendations to the City to reject items not meeting the requirements of
the Construction Documents.
m) Delivery of Unaccepted Materials to Jobsite: As new materials are delivered to the jobsite,
the Consultant shall check the material's certifications and samples and verify that an approved
shop drawing was submitted for the material in question. If it is determined that a submittal has
not been approved,the Consultant shall immediately notify the City and issue a Non-Compliance
Notice. In conjunction with the Design Consultant(as necessary),the Consultant shall direct and
supervise the sampling and testing of materials performed by the City's independent testing
37
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No. 22-168-02
laboratory.The Consultant shall maintain test report logs which shall be submitted to the City for
review and uploaded to e-BuilderTM, the City's document management system, on a weekly
basis. Consultant shall also review invoices submitted by the independent testing laboratories
and recommend payment by the City.
n) Shop Drawing Submittals:The Consultant shall have seven(7)days to review shop drawings
and product approvals throughout the construction period-for familiarity prior to delivery of
materials. Consultant shall verify that the Contractor maintains a submittal log, conducts timely
submittals, and uploads approved shop drawings to e-BuilderTM, the City's document
management system.
o) Issuance of Non-compliance Notices: The Consultant shall be responsible for notifying the
City when they become aware of a condition that is believed to be in non-compliance with
Construction Documents.Anytime the Consultant notices a potential construction problem or a
condition that could result in non-complying materials, equipment, or workmanship, the
Consultant will need to determine whether the condition poses an immediate threat to public
health or safety.
1) If a condition does not pose a threat to public health or safety, immediate verbal notification
or Pre-Noncompliance Notice" of the potential non-compliance should be made to the
Contractor and the City.This verbal notice shall be documented in the Consultants daily report,
as well as an email to the Contractor with a copy to the City's Project Coordinator advising the
Contractor of potential construction problems, errors, or deficiencies that can be promptly
resolved and do not warrant a Non-compliance Notice. If the Contractor fails to respond to the
verbal notification within a reasonable timeframe, the Consultant shall notify the City and the
City's Projects Coordinator and shall issue a written Non-compliance Notice.
2) If a condition poses an immediate threat to public health or safety, the Consultant shall notify
the Contractor and City immediately, and the City's Projects Coordinator shall issue a Non-
compliance Notice to the Contractor. Non-compliance Notices shall include a description of the
Work that does not meet the construction contract requirements,along with a required timetable
for corrective work to be implemented by the Contractor. Other items that should be included in
the Notice include a reference to the provision of the Construction Documents that have been
violated.
p) Damage to Existing Facilities: The Consultant shall identify any existing facilities damaged by
the Contractor and verify that the Contractor has notified the respective owner(s). The
Consultant shall include a record of such occurrences in the daily reports.
q) Change Orders: Consultant shall perform an independent review of any Change Orders
submitted by the Contractor and provide a written statement noting recommendation for approval
or denial of the Change Order to the City. If recommended for approval, the Consultant shall
note if the requested cost and schedule impacts are fair and reasonable. The Consultant shall
be responsible for maintaining a Change Order log and uploading approved Change Orders to
e-BuilderTM, the City's document management system. The Consultant shall also participate in
change request review meetings with City and Contractor to resolve and/or negotiate the
equitable resolution of request.
38
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
r) Requests for Information/Construction Document Clarification (RFIs/CDCs): When RFIs
and CDCs involve design issue interpretetions,the Consultant shall coordinate with the Design
Consultant, as needed; tO resolve the Contractor's Requests for Information, Construction
Document Clarifications, Field Orders, and other related correspondence.The Consultant shall
also be responsible for verifying that the Design Consultant is providing a written response to
RFis and CDCs in a timely manner and for processing,logging,and distributing all RFIs/CGCs.
Consultantshall have seven(7)calendar days to review and upload all RFI;and CDC responses
to e-Builderw,the City's document management systefn.
s) Schedule:Analyze the Contractor's schedule(S) (i.e,baseline(s), revised baseline(s), updates,
as-built, etc.)for compliance with the contract documents, Elements including,but not limited
to, completeness, logic., durations, activity, flow, milestone dates, concurrency, resource
allotment, and delays shall be reviewed. Verify the schedule conforms with the construction
phasing and MOT sequences, including all contract modifications, Provide a written review of
the schedule identifying significant omissions, improbable or unreasonable activity durations,
errors in logic,and any other concerns at,detailed in the contract documents.
t) Pay Requisitions:- Consultant shall verify Contractor's pay requisition quantities and Sign-off
on all pay requisition quantities in the field.:Consultant shall be responsible for reviewing with the
Contractor the monthly payment requisition to confirm the status of completed and uncompleted
work and stored materials.The Consultant shall advise the City:of quantities being approved for
subsequent concurrence for payment purposes. The review of payment requisitions shall not
exceed seven (7),calendar days,and only be approved by the City.
U) Equipment Teets and Systems Start7up: Consultant shall be responsible for Coordinating
various tests for quality control on the projects;verifying that equipment tests and systemestartL
up are conducted in the presence of appropriate personnel, and that the Contractor is
Maintaining adequate records thereof. Consultant shall observe,record,and report:appropriate
details relative to the test procedures and start-up
v) Record Drawings: Consultant shall monitor that record drawing mark-ups are properly
maintained by the Contractor. The Consultant shall review the record drawing mark-ups as
deemed necessary by the City.Contractors failure to maintain the record drawings in up-to-date
condition may be deemed grounds for withholding Contractor's monthly payment requisitions
until the record.drawings are brought up to date, The Consultant shall notify the City if it
Considers the mark-up documents inSuffitient. The City shall make the final determination of
payment withhOlding.
w) Safety: Consultants shall be expected to recognize a hazard that any reasonable non-safety
professional might be expected to recognize.In addition,those safety obligations extend only to
recognizable hazards that the Consultant may rtOte while in the normal conduct of onsite
business,
39
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-16$-02
It a situation presents itself,the following procedures should be followed:
• Immediately direct personnel to remove themselves from the apparent;danger.
• Notify the Contractor's superintendent of the apparent condition that caused the concern
and that thee fectec.personnel was_directed to remove themselves accor n ly.
• Notify the Contractor of the situation that arises concern,both in..writing;and.verbally,
• Issue a written Notice of Noncompliance stating that the Contractor should take immediate
action as it deems necessary to correct the deficiency/condition.
• Write.a full report in the Daily Report on,the condition found to be unsafe,all actions taken,
and correspondence written,,including times and names.
• Take photographs.of the concern.
• If the Contractor does'not make corrections,the Consultant should notify the City.
• The Consultant shall review the situation with_the City for further direction.
• The condition and all conversations and correspondence shag be recorded in the
Consultant's Daily Report.
• In thecase of a construction-related accident,Consultant.shall notify the City of the accident
Consultant shall direct the Contractor to prepare an accident report with_a copy forwarded
to the City.
X. Quality Control:The Consultant shall review and-monitor the Contractor's adherence to an
acceptable quality control program submitted by'the Contractor prior to the issuance of the
second Notice-toOroceed by the City.. This program shall describe the Contractor's quality
control, organizational procedures, documentation controls, and processes for each phase of
the work,Quality control:during construction shall be the Contractor's responsibility;however,
oversight and ensuring the Contractor complies with applicable jurisdictional construction
standard's-shall beenforced o'n.the City's behalf by*the Consultant.
y) Proceeding with Disputed Work: In the event that an'agreement cannot be.reached on a
Change Order,:the Contractor must carry on the work and adhere to the project schedule in
accordance with the construction contract general conditions.The Consultant shall log Olt forced
work efforttrelated to disputed change order on a Forced Work Daily Log Reports;which shall
be signed and dated by the Consultant and the Contractor's representative at the completion of
each.workday..The Consultant shall forward copies of this form to the City for.tecord.purpoSeS.
z) Maintenance of Traffic(MOTy The Contractor shall provide the Consultant,.City,.and'Design
Consultant with approved copies of its MOT at the Pre-Construction Meeting for general
information purposes. It shall be the Consultant's responsibility to verify compliance with the
MOT in'the"field.
aa) Contractor Request for Services: When the Contractor requires services from the City for
issues such as water main shutdowns, tie-ins to existing water mains, special regulatory
inspections, etc„ a request shall be made in writing by the Contractor and forwarded by the
Consultant to the City, a minimum of three working days prior to when required.
40
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
bb)Substantial Completion;When the Contractor considers that the Workbag reached Substantial
Completion, the Contractor shall notify the Consultant, who shall verify that. the work has
progressed to the Substantial Completion point in accordance with the Construction Documents.
If the Consultant agrees,.the Consultant shall contact the City to agree on a schedule for
conducting a Substantial Completion,"walk-through" inspection of the Work. Consultant shall
attend and participate in the Substantial Completion "Walk-through," perform a Substantial
Completion inspection with the Contractor, Design Consultant, and the City, and prepare a
master punch list that describes items remaining to be compieted.This master punch list shall
be attached to the certificate of Substantial Completion.
cc) Final Completion and Project Closeout: When the Contradtor considers that the Work has
reached Final Completion, the Contractor shall notify the Consultant, who shall verify that the
work has progressed to the Final Completion point in accordance with the Construction
Documents. If the Consultant agrees, the Consultant shall contact the City to agree on a
schedule for conducting a Final Completion"walk-through" inspection of the Work: Consultant
shall attend and participate in the Final Completion "walk-through" and perform a Final
Completion `inspection with the Contractor, Design Consultant, and the City. If the work is
determined to'be Incomplete, the Consultant and Other attendees shall each develop a punch
list of items requiring completion or correction prior to consideration of final acceptance of each
project which shall be forwarded to the Contractor by the Consultant for the Project.Consultant
shall complete all necessary close-out and construction completion forms and doeumentation'in
coordination with the City for the Project,The Consultant shall work.with the Design Consultant
and the Contractor, as necessary, to ascertain materials required for the closeout binder, as
required by the City,and review the Operation and Maintenance manuals and,As-Built Drawings
for each project for completeness prior to forwarding documentation to the City,Once all parties
determine the work_is complete and the Contractor has delivered all close-out documentation to
the City, the.Consultant shalt prepare a Final Certificate fix Payment. The Consultant shall be
responsible for providing final certifications based on the entire scope of Work for the Project.
dd) Consultant and Design Consultant Relationship:The services outlined herein are intended
to provide support to both the City and the Design Consultant during the Project's construction
phase: The Consultant shalt perform the services outlined in this Agreement under the
supervision and contractual directives of the Project Coordinator and,shall refer all matters
pertaining to this Agreement to the City. In matters relating to the design concept and
constructability thereof, the Consultant shall conduct this scope of services under the technic,!.
directives issued by the Design Consultant such that the DesignConsultant's FOR Van provide
final certification Of the design components at Project.Closeout..
3, Provide qualified personnel necessary to carry out its responsibilities efficiently and effectively under
this Agreement. The personnel shall be qualified by experience and education. Submit in writing to
the City for review and approval the names of personnel proposed for assignment to the Project,
including a detailed resume for each.The City reserves the right to have'Consultant`s personnel
removed and substituted from the Project if the employee's conduct or performance is detrimental to
the Project.The City reserves the right to request periodic rotation of field personnel.
4. The Consultant shall furnish the City with a Quality Assurance(QA) Plan within 15 calendar days
after the award of this agreement.The QA Plan shall detail the procedures, evaluation criteria, and
41
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No. 22-168-02
instructions of the Consultant's organization for providing services pursuant to this Agreement.
Significant changes to the work requirements may require the Consultant to revise the QA Plan.The
consultant shall be responsible for keeping the plan current with the work requirements. The Plan
shall include,but not be limited to:
• Consultants QA Organization and its functional relationship to the part of the organization
performing the wor c under the Agreement.-The authority, responsibilities, and autonomy of-the
QA organization shall be detailed as well as the names.and qualifications of personnel in the
quality control organization.
• Methods used to monitor and achieve organization compliance with Agreement requirements for
services and products.
• Outline the types of records which shall be generated and maintained during the execution of
the QA program.
• Methods used to control subconsultant and vendor quality.
• An officer of the Consultant firm shall certify that the inspection and documentation were done
according to specifications,plans,City standards,and City procedures.
• Maintain adequate records of the quality assurance actions performed by the organization
(including subcontractors and vendors)in providing services and products under this Agreement.
All records shall indicate the nature and number of observations made,the number and type of
deficiencies found, and the corrective actions taken.
5. Provide assistance in preparing for arbitration hearings or litigation during the Agreement time in
connection with the construction project covered by this Agreement.
6. Provide qualified engineering witnesses and exhibits for arbitration hearings or litigation in
connection with the Agreement.
7. Provide services determined necessary for the successful completion and closure of the
Construction Contract.
8. Provide Post construction claims review — The Consultant shall analyze the claim, engage in
negotiations leading to settlement of the claim,and prepare and process the required documentation
to close out the claim;
9. The Consultant may be asked to provide all or some construction engineering and inspection
services, including inspectors, construction managers, and/or construction administration staff for
City Right-of-Way construction projects.
42
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
•
Contact No.22-168-02
SCHEDULE.A
CONSULTANT SERVICE.ORDER
•
Contract# Dept. CSO# Change Order#
Contractor: Project Title:
Bye accepting this CSO,Consultant agrees to provide services`pursuant to the attached proposaldatel and.
the terms,conditions,and rates established in the above-referenced contract between the City and the Consultant.Consultant
oxplicitlyagrees-tbat no other terms and conditions shall applyto the-work rcga dless.otwhether said other terms and conditions
ate included'herein or in anyattachuent to this CSC).Anydeviation from thescope of work agreed to herein.shall require a change
ptder approved by the.City,.
Estimated calendar days to complete the work:
Total amount original CSO
Total amount this Amendment S
Total amount all previous Amendments $
Total Amount for Engagement $
Fee for ancillary items for this Service Order .$
Account Code:
•
•
•
•
For City(Name) Signature Date
Reviewed by Procurement:Alex.Denis-
Project Administrator:
Dept Director.
ACM:
CM:
For Contractor(Name) Signature Date
Lead.project Admin:
Notes:
43
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-Q2
EXHIBIT B
CONSULTANT COMPENSATION
Schedule of Payments
Planriirig Services*
Design Services*
Bidding and Award Services
Construction Administration**
$
Reimbursable Allowance*"
Note*:Theta services will be paid 10Mp sunl based en percentage dbmpleteof each phase
as identified in the individual tasks.
Note":Construction Adminittration Will be paid on&monthly basis upon commencement
of construction.
In the event that,through no fault of the Consultant,Construction Administration services
are required to be extended, which extension shall be subject to prior City approval, and
what shall be MO*CityYs•sofe discretion, the Consultant agrees to extend said services
for$ ,per month,for the duration required„to complete the.Project.
Note':The Reimbursable Allowance belongs to the City and must be approved in writing,
in advance, by the Project Administrator. Unused portions will not be paid to the
Consultant.
44
DocuSign Envelope ID:038F080E-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
SCHEDULE C
CONSULTANT HOURLY RATE SCHEDULES
POSITION TITLES HOURLY RATE
PROJECT PRINCIPAL 196.32
PROEJCT MANAGER 168.27
SENIOR COST ESTIMATOR 117.79
COST ESTIMATOR 84.14
SENIOR SCHEDULER 112.18
SCHEDULER $ 78.53
SR. INSPECTOR 112.18
INSPECTOR (CEI, FIELD OR CONSTRUCTION) $ 84.14
THRESHOLD INSPECTOR 117.79
SENIOR CIVIL ENGINEER $ 145.84
CIVIL ENGINEER 123.41
SENIOR ELECTRICAL ENGINEER S 145.84
ELECTRICAL ENGINEER 5 123.41
SENIOR MECHANICAL ENGINEER 145.84
MECHANICAL ENGINEER 123.41
SENIOR STRUCTURAL ENGINEER 145.84
STRUCTURAL SPECIAL INSPECTOR 123.41
CLERICAL/ADMINISTRATOR 44.88
RESIDENT COMPLIANCE SPECIALIST 90.00
For the avoidance of doubt, none of the above Consultant positions shall provide
any services other than the CEI services contemplated herein.
45
&41_
MA
DocuSign Envelope ID:038F08OE-52C7-4774-A746-11C4DF95D136
Contact No.22-168-02
SCHEDULE D
APPROVED'SUBCONSULTANTS
NO SUBCONSULTANTS SUBMITTED WITH PROPOSAL
•
46